Initial Claim Post-Service Claims must be submitted to AvMed within 90 days from the date of service or within one year unless the Member was legally incapacitated; otherwise the Claim will be considered to have been waived.
Criminal Claims Notwithstanding any provision of this Article XII to the contrary, in the event that any Person being indemnified under this Article XII shall become involved in any criminal action, suit or proceeding, whether judicial, administrative or investigative, the Receiver shall have no obligation hereunder to indemnify such Person for liability with respect to any criminal act or to the extent any costs or expenses are attributable to the defense against the allegation of any criminal act, unless (i) the Person is successful on the merits or otherwise in the defense against any such action, suit or proceeding, or (ii) such action, suit or proceeding is terminated without the imposition of liability on such Person.
Final Claims 5.1 Provided all previous claims have been paid, the authority shall have no further liability to make payment of any kind to the contractor once the final claims have been paid. SCHEDULE 3 – MONITORING REQUIREMENTS This Schedule sets out the contract management requirements which are applicable to the delivery of the Services.
The Indemnified Person (a) shall give the Indemnifying Party notice of the Claim promptly after becoming aware thereof (including a statement of facts known to the Indemnified Person related to the Claim and an estimate of the amount thereof); (b) prior to taking any material action with respect to a Third Party Claim, shall consult with the Indemnifying Party as to the procedure to be followed in defending, settling, or compromising the Claim; (c) shall not consent to any settlement or compromise of a Third Party Claim without the written consent of the Indemnifying Party; (d) shall permit the Indemnifying Party to assume the defense of a Third Party Claim (including, except as provided below, the compromise or settlement thereof) at the Indemnifying Party’s own cost and expense, provided, however, that the Indemnified Person shall have the right to approve the Indemnifying Party's choice of legal counsel.
Losses in Excess of the Stated Threshold In the event that the sum of the Cumulative Loss Amount under this Single Family Shared-Loss Agreement and the Stated Loss Amount under the Commercial Shared-Loss Agreement meets or exceeds the Stated Threshold, the loss/recovery sharing percentages set forth herein shall change from 80/20 to 95/5 and thereafter the Receiver shall pay to the Assuming Bank, in immediately available funds, an amount equal to ninety-five percent (95%) of the Monthly Shared-Loss Amount reported on the Monthly Certificate. If the Monthly Shared-Loss Amount reported on the Monthly Certificate is a negative number, the Assuming Bank shall pay to the Receiver in immediately available funds ninety-five percent (95%) of that amount.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Indemnified Person If an Indemnified Person is entitled to indemnification under this Section 14 as a result of a claim by a third party, and the indemnifying Interconnection Party fails, after notice and reasonable opportunity to proceed under Section 14.2 of this Appendix 2, to assume the defense of such claim, such Indemnified Person may at the expense of the indemnifying Interconnection Party contest, settle or consent to the entry of any judgment with respect to, or pay in full, such claim.
No consequential claims Notwithstanding anything to the contrary contained in this Article 22, the indemnities herein provided shall not include any claim or recovery in respect of any cost, expense, loss or damage of an indirect, incidental or consequential nature, including loss of profit, except as expressly provided in this Agreement.
Indemnified Party If a Party is entitled to indemnification under this Article 18 as a result of a claim by a third party, and the indemnifying Party fails, after notice and reasonable opportunity to proceed under Article 18.1.3, to assume the defense of such claim, such Indemnified Party may at the expense of the Indemnifying Party contest, settle or consent to the entry of any judgment with respect to, or pay in full, such claim.
Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal.
