Systems Installation Sample Clauses
The Systems Installation clause outlines the responsibilities and procedures for installing technical systems or equipment as part of a project or contract. It typically specifies who is responsible for providing, delivering, and setting up the systems, as well as any standards or timelines that must be met during installation. For example, it may require the contractor to install network infrastructure or security systems according to agreed specifications and within a certain timeframe. This clause ensures that all parties are clear on their obligations regarding installation, helping to prevent disputes and delays by setting clear expectations and accountability.
Systems Installation. EndoSonics shall support Distributor with the installation of the Systems at the location of the end-user. Such installation shall include the training of customers with respect to the Products sold. Distributor shall be responsible for all reasonable travel expenses and related disbursements incurred by EndoSonics in connection with said installations.
Systems Installation. Franchisee must, at its expense, purchase or lease, install, maintain, and use at the Hotel all Electronic Systems in accordance with specifications provided by or on behalf of Franchisor and may not use such Electronic Systems to process administrative functions not specifically related to the System.
Systems Installation. Franchisor will provide to Franchisee the specifications for the Electronic Systems and other systems required to be utilized at the Restaurant. Franchisee must, at its expense: purchase or lease, install, maintain, and use at the Restaurant all Electronic Systems necessary for the proper and efficient utilization and operation of such systems.
Systems Installation. A. Licensee will, as a cost of the MVW ▇▇▇▇-▇▇▇▇▇▇▇ Business, arrange for the purchase or lease, installation, maintenance, and use at the Projects of all Electronic Systems that Licensor reasonably requires or that Licensee chooses to use in connection with the MVW ▇▇▇▇-▇▇▇▇▇▇▇ Business, in accordance with the Brand Standards and specifications provided by or on behalf of Licensor and may not use such Electronic Systems for anything not specifically related to the Projects and the MVW ▇▇▇▇-▇▇▇▇▇▇▇ Business.
B. Notwithstanding the foregoing, Licensee may use any electronic system that, in Licensor’s judgment, is comparable to a particular required Electronic System and performs the same functions as such Electronic System and is compatible, and interfaces, with Licensor’s Electronic Systems.
Systems Installation. A. Licensee will, as a cost of the Licensed Business, arrange for the purchase or lease, installation, maintenance, and use at the Projects of all Electronic Systems that Licensor reasonably requires or that Licensee chooses to use in connection with the Licensed Business, in accordance with the Brand Standards and specifications provided by or on behalf of Licensor and may not use such Electronic Systems for anything not specifically related to the Projects and the Licensed Business.
B. Notwithstanding the foregoing, Licensee may use any electronic system that, in Licensor’s judgment, is comparable to a particular required Electronic System and performs the same functions as such Electronic System and is compatible, and interfaces, with Licensor’s Electronic Systems.
Systems Installation. (a) Licensor acknowledges that as of the Effective Date, there are no material items that are required to be purchased, leased, installed or upgraded in order for Licensee, its Permitted Affiliates or Permitted Sublicensees to use the Hotel Reservation System in connection with the Existing Projects, Existing Residential Projects and the Licensed Business on a Non-discriminatory Basis and in the same manner in which the Acquired Companies have used the Hotel Reservation System immediately prior to the Effective Date. Subsequent to the Effective Date, if any changes are required for Licensee to use the Hotel Reservation System or other of Licensor’s Electronic Systems for the required purposes, Licensee will provide written notice thereof to Licensor and, as a cost of the Licensed Business, arrange with Licensor or its Affiliates, for the purchase or lease, installation, maintenance, and use in connection with the Projects, on a Non-discriminatory Basis, of whatever is reasonably required to implement the specified changes. Licensee may not use such Licensor’s Electronic Systems for anything not specifically related to the Projects or the Licensed Business.
(b) Notwithstanding the foregoing to the contrary, Licensee may use any electronic system in the Licensed Business that, in Licensor’s commercially reasonable judgment, is comparable to a particular required Electronic System and performs the same functions as such Electronic System and is compatible, and interfaces, with Licensor’s Electronic Systems.