Line Item Breakdown definition

Line Item Breakdown means a detailed written estimate or schedule of values in the form set forth in AIA Form G702 (Application for Payment) and AIA Form G703 (Continuation Sheet), showing the various operations comprising the Work and allocating percentages and dollar amounts of the Work Order Price to the labor, materials, and
Sample 1Sample 2Sample 3
Line Item Breakdown means a detailed written estimate or schedule of values in the form set forth in AIA Form G702 (Application for Payment) and AIA Form G703 (Continuation Sheet), showing the various operations comprising the Work and allocating percentages and dollar amounts of the Work Order Price to the labor, materials, and other elements of each such operation, prepared and submitted by Contractor and approved by HTFC before the submission of Contractor's first Requisition, to be submitted thereafter by Contractor with all Requisitions.
Sample 1Sample 2Sample 3
Line Item Breakdown means a detailed written estimate or schedule of values in the form set forth in AIA Form G702 (Application for Payment) and AIA Form G703 (Continuation Sheet), showing the various operations comprising the Work and allocating percentages and dollar amounts of the Contract Price to the labor, materials, and other elements of each such operation, prepared and submitted by Contractor and approved by Owner before the submission of Contractor's first Requisition, to be submitted thereafter by Contractor with all Requisitions. "Loss-And-Expense" means loss, liability, obligation, damage, delay, penalty, judgment, cost, fee, claim, charge, tax, or expense of every kind (including related Fees-And-Costs).
Sample 1Sample 2

Examples of Line Item Breakdown in a sentence

  • Line Item Breakdown of All Charges All of this information must be included on the invoice when the vehicle is delivered.

  • Line Item Breakdown of All Charges INVOICING: (cont'd)All of this information must be included on the invoice when the vehicle is delivered.

  • Cost Report: A Cost Report generated from the cost loaded CPM Schedule is to be submitted 14 calendar days after approval of the Line Item Breakdown, in accordance with Paragraph F.(3).

  • State of New MexicoFederal GovernmentCity of Santa FeProgram Budget 2014-2015 Line Item Breakdown for proposed request: Current recipients: work from the current budget in your contract.

  • Pedestrian push-button assemblies shall be ADA compliant meet the standards of the MUTCD and Americans with Disabilities Act, ADA.

  • Line Item Breakdown of All ChargesAll of this information must be included on the invoice when the vehicle is delivered.

  • This schedule shall follow the Architects Budget Line Item Breakdown submitted for review and approved prior to the start of construction.

  • Line Item Breakdown - All line items are equally necessary for funding as all are necessary aspects of the rehabilitation project.

Related to Line Item Breakdown

  • Breakdown /“breaks down”/“broken down” means an event during the policy period, that stops the vehicle from being driven because of a mechanical or electrical failure including as a result of battery failure, running out of fuel, flat tyres, but not as a result of a mis-fuel, road traffic collision, fire, flood, theft, acts of vandalism, any driver induced fault, or any key related issue other than keys locked in your vehicle;

  • Line Item means a field of information (or a combination of fields of information) to be entered in a Settlement Schedule by any Participating Subscriber in relation to a Conveyancing Transaction.

  • Lockdown means the period between 23H59 on 26 March 2020, until 23H59 on 30 April 2020;

  • Punch List Items means such items (i) as are reasonably necessary or appropriate to fully complete the construction, equipping and furnishing of the Hotel in accordance with this Contract and (ii) that, unless otherwise agreed by Buyer in its sole discretion, (a) individually and in the aggregate do not and will not prohibit, cause a delay in or otherwise adversely affect, under applicable Legal Requirements, the Franchise Agreement or otherwise, the opening of the Hotel for business to the public or the continued occupancy and operation of the Hotel as contemplated under the Brand and (b) may be corrected or completed, subject to delays caused by Force Majeure, within not more than sixty (60) days.

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each, and clearly allocate requested grant funding and match contributions to each.

  • Outage has the meaning set forth in the CAISO Tariff.

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Data Collection System means software designed for collection, tracking and reporting 17 outcomes data for Resident enrolled in the FSP Programs.

  • The Contract Price/Project Cost means the price payable to the Vendor under the Contract for the full and proper performance of its contractual obligations.

  • Total Project Cost means all the funds to complete the effort proposed by the Applicant, including DOE funds (including direct funding of any FFRDC) plus all other funds that will be committed by the Applicant as Cost Sharing.

  • Project Cost means the costs incurred in connection with the

  • Unscheduled Downtime means any time when any or all of the applications and Services provided by the Supplier to the Customer shall be unavailable to the Customer due to unexpected system failures other than Scheduled Downtime or the downtime is attributable to events not under the control of the Supplier.

  • Vapor collection system means a vapor transport system which used direct displacement by the gasoline being transferred to force vapors from the vessel being loaded into either a vessel being unloaded or a vapor control system or vapor holding tank.

  • Unscheduled Outage means an outage that is not a result of a Scheduled Outage;

  • Materials recovery facility means a solid waste management facility that provides for the extraction from solid waste of recyclable materials, materials suitable for use as a fuel or soil amendment, or any combination of such materials.

  • Total Contract Price/Project Cost/TCO means the price payable to Service Provider over the entire period of Contract for the full and proper performance of its contractual obligations.

  • Total Project Costs means the total amount of money required to complete the Project.

  • Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).

  • Project Costs means all allowable costs, as set forth in the applicable Federal cost principles, incurred by a recipient and the value of the contribu- tions made by third parties in accom- plishing the objectives of the award during the project period.

  • Emergency Expenditure means with respect to Part 3.2 of the Project, any of the Eligible Expenditures set forth in the CERC Operations Manual in accordance with the provisions of Section I.A.3 of Schedule 2 to this Agreement and required for the activities included in the CERC Part of the Project.

  • BASE budget means the minimum general fund budget of a district, which includes 80% of the basic

  • Busy Line Verification (BLV) means a service whereby an End User requests an operator to confirm the busy status of a line.

  • Contract Cost means the Contract Sum plus Price Variation. This cost shall be included in the letter of acceptance.

  • Subprojects means more than one such Subproject.

  • Severity 1 means the unavailability of multiple service resources and redundant capability is not available or has been exhausted.