Delay in delivery definition

Delay in delivery means failure to make delivery (or partial delivery) on time, provided that such failure is not due to any act or omission on the part of the Buyer and that the Supplier is not entitled to relief in accordance with the rules in section 13 on force majeure.
Sample 1Sample 2Sample 3
Delay in delivery. LIQUIDATED DAMAGES: TERMINATION FOR DELAY IN DELIVERY............................................................31
Sample 1
Delay in delivery means the situation when the goods have not been delivered at the port of discharge provided for in the contract of carriage by sea within the time expressly agreed upon or, in the absence of such agreement, within the time which it would be reasonable to require of a diligent carrier, having regard to the circumstances of the case. The carrier shall not be responsible for delay in delivery due to the following reasons:
Sample 1Sample 2

Examples of Delay in delivery in a sentence

  • Delay in delivery of materials or equipment for any cause other than those specified in Paragraph 3.3.8.3. No claim will be approved if materials or equipment are delayed due to Contractor's tardy procurement or expediting.

  • Delay in delivery of any Products shall not relieve Customer of its obligation to accept delivery thereof, unless Customer cannot reasonably be expected to accept such late delivery.

  • Delay in delivery of any Goods shall not relieve Customer of its obligation to accept delivery thereof.

  • Delay in delivery of any installment shall not relieve Buyer of its obligations to accept remaining deliveries.

  • Delay in delivery of any installment shall not relieve Buyer of its obligation to accept remaining deliveries.

  • Delay in delivery of any installment shall not relieve Buyer of its obligation to accept remaining installments.

  • Fails to accept the purchase order within the specified time.2. Fails to sign the agreement within the specified time.3. Fails to deposit the Security deposit /performance Guarantee within the specified time.4. Delay in delivery beyond the specified period.5. Partial Delivery.6. Serious discrepancies noted in the items delivered.7. Breaches in the terms and conditions of the Order.

  • Delay in delivery shall be said to occur when the goods have not been delivered within the agreed time-limit or when, failing an agreed time-limit, the actual duration of the carriage having regard to the circumstances of the case, and in particular, in the case of partial loads, the time required for making up a complete load in the normal way, exceeds the time it would be reasonable to allow a diligent carrier.

  • Delay in delivery of any installment shall not relieve Purchaser of its obligation to accept remaining deliveries.

  • Delay in delivery of one installment shall not entitle Buyer to cancel other installments.


More Definitions of Delay in delivery

Delay in delivery means failure to make Delivery (or partial Delivery) on time, provided that such failure is not due to any act
Sample 1
Delay in delivery means failure to make delivery (or partial delivery) on time, provided that such failure is not due to any act or omission on the part of the Buyer and that the Supplier is not entitled
Sample 1

Related to Delay in delivery

  • Delay Delivery Certification A certification substantially in the form of Exhibit G-2.

  • Termination Delivery Unit means (A) in the case of a Termination Event, an Event of Default or an Extraordinary Event (other than an Insolvency, Nationalization, Merger Event or Tender Offer), one Share or (B) in the case of an Insolvency, Nationalization, Merger Event or Tender Offer, a unit consisting of the number or amount of each type of property received by a holder of one Share (without consideration of any requirement to pay cash or other consideration in lieu of fractional amounts of any securities) in such Insolvency, Nationalization, Merger Event or Tender Offer; provided that if such Insolvency, Nationalization, Merger Event or Tender Offer involves a choice of consideration to be received by holders, such holder shall be deemed to have elected to receive the maximum possible amount of cash.

  • Delivery Notice Has the meaning specified in the NPA.

  • Delayed Delivery Fee shall have the meaning specified in paragraph 2B(8)(iii).

  • Final Delivery Date means the date on which all of the Vessels shall have been transferred and delivered by the Builder to the Borrowers;

  • Grain dealer means a person engaged in the business of receiving, buying, exchanging, selling, or storing farm produce in this state. The term includes a farm produce trucker, grain merchandiser, or processor. The term does not include a person solely engaged in 1 of the following:

  • Delay Delivery Mortgage Loans The Mortgage Loans for which all or a portion of a related Mortgage File is not delivered to the Trustee or to the Custodian on its behalf on the Closing Date. The number of Delay Delivery Mortgage Loans shall not exceed 25% of the aggregate number of Mortgage Loans as of the Closing Date.

  • Underwritten Demand shall have the meaning given in subsection 2.1.3 of this Agreement.

  • Final delivery certificate means the document issued by the COE confirming that all the known defects have been rectified and that the works, goods or services appear in good order and have been accepted;

  • Delivery Day means a day other than a Saturday, a Sunday or any other day on which national banking associations are authorized to be closed. Any party may change its address for purposes of the receipt of notices and demands by giving notice of the change in the manner provided in this provision.

  • Share Delivery Date shall have the meaning set forth in Section 4(c)(ii).

  • Notice Delivery Period means the period from and including the Effective Date to and including the date that is fourteen calendar days after (a) the Scheduled Termination Date; (b) the Grace Period Extension Date if (i) Grace Period Extension is specified as applicable in the applicable Final Terms, (ii) the Credit Event that is the subject of the Credit Event Notice is a Failure to Pay that occurs after the Scheduled Termination Date and (iii) the Potential Failure to Pay with respect to such Failure to Pay occurs on or prior to the Scheduled Termination Date; or (c) the Repudiation/Moratorium Evaluation Date if (i) the Credit Event that is the subject of the Credit Event Notice is a Repudiation/Moratorium that occurs after the Scheduled Termination Date, (ii) the Potential Repudiation/Moratorium with respect to such Repudiation/ Moratorium occurs on or prior to the Scheduled Termination Date and (iii) the Repudiation/ Moratorium Extension Condition is satisfied.

  • First Delivery Date means the first date by which the commodity for a Futures Contract can be delivered in order for the terms of the Futures Contract to be fulfilled.

  • Initial Delivery Date means the date on which the conditions set forth in Section B of this Service Classification for an Energy Server have been satisfied or waived in writing by Company.

  • Exercise Notice means the notice respecting the exercise of an Option, in the form set out as Schedule “B” hereto, duly executed by the Option Holder;

  • Delivery Date means the date the City requires the Contractor to deliver the goods to the City’s Delivery Site;

  • Scheduled Delivery Date means the Date on which the Seller is required to start delivering the power at the Delivery Point as per the terms and conditions of the PPA;

  • Delivery sale means any sale of a vapor product to a

  • Xxxxx Notice means the Notice of Grant of Stock Option accompanying the Agreement, pursuant to which Optionee has been informed of the basic terms of the option evidenced hereby.

  • undertaking in difficulty means an undertaking in respect of which at least one of the following circumstances occurs:

  • Share Delivery Quantity For any Settlement Date, a number of Shares, as calculated by the Calculation Agent, equal to the Net Share Settlement Amount for such Settlement Date divided by the Settlement Price on the Valuation Date for such Settlement Date. Net Share Settlement Amount: For any Settlement Date, an amount equal to the product of (i) the number of Warrants exercised or deemed exercised on the relevant Exercise Date, (ii) the Strike Price Differential for the relevant Valuation Date and (iii) the Warrant Entitlement.

  • Responsible bidder or offeror means a person who at the time of Contract Award has the capability to perform the Contract requirements and the integrity and reliability which will assure good faith performance.

  • Underwritten Shelf Take-Down Notice has the meaning set forth in Section 3.1(d)(ii)(A).

  • Draw Down Notice shall have the meaning assigned to such term in Section 5.1(f) hereof.

  • Delivery ex stock means immediate delivery directly from stock actually on hand.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.