Construction Delay definition

Construction Delay means delays in construction of the Leasehold Improvements attributable to (i) strikes, lockouts, labor troubles, inability to procure materials, power failure, restrictive governmental laws or regulations, civil disturbances, war, acts of terrorism, failure to secure permits within the normal time frames, lightening, earthquake, fire, storm, hurricane, tornado, flood, explosion and any other similar cause beyond the reasonable control of Lessee, or (ii) material interference by Lessor; provided, however, as a condition to claiming the benefit of any extension of the Outside Request Date due to such Construction Delay, Lessee shall provide Lessor with written notice of such Construction Delay, within thirty (30) days of Lessee’s knowledge thereof and the nature of its impact upon Lessee’s completion of the Leasehold Improvements and Lessee shall thereafter keep Lessor regularly informed of the status of such Construction Delay and its impact upon the completion of the Leasehold Improvements.
Sample 1Sample 2Sample 3
Construction Delay means any of the following:
Sample 1Sample 2
Construction Delay has the meaning set forth in Paragraph 25.3.2 below. SCHEDULE 6 TO EXHIBIT B
Sample 1Sample 2

Examples of Construction Delay in a sentence

  • Investigating Causes of Construction Delay in Ethiopian Construction Industries.

  • Construction Delay Analysis Techniques—A Review of Application Issues and Improvement Needs.

  • Major Construction Delay Factors in Portugal, the UK, and the US.

  • In the event of a Construction Delay, the date for performance of the services will be extended by the time necessitated by the delay.

  • We discuss this risk in section 6.4 of this report.▪ Construction Delay Risk, which refers to the impact of unforeseen construction delays to the expected NPV of a project.

  • If Seller achieves Commercial Operation for the Facility to occur by the Guaranteed Commercial Operation Date, all Construction Delay Damages paid by Seller shall be refunded to Seller.

  • Construction Delay Risk Many respondents noted that the CfD regime increases risk in the event of construction delays relative to the RO, due to all projects being potentially subject to penalties for late delivery, or even loss of support.

  • An Investigation into the Use of Construction Delay and Disruption Analysis Methodologies (Doctoral dissertation).

  • Addis Ababa Ethiopia.Odeh, A.M. &Battaineh, H.T. (2002), Causes of Construction Delay: Traditional Contracts.International journal of project management 20,67-73Pickavance Keith (2005).

  • Patil (2014) “Identification of Critical Construction Delay Factors” International Journal of Latest Trends in Engineering and Technology, Vol.


More Definitions of Construction Delay

Construction Delay means any delay caused by an act or omission of either party, any tenant, or their respective employees, agents, contractors or subcontractors in connection with the design and construction of the Mall Improvements that is deemed a Construction Delay under this Agreement.
Sample 1Sample 2
Construction Delay means the Construction Work is the discontinued due to acts or matters within Property Owner’s control for a period of fifteen (15) or more consecutive days.
Sample 1
Construction Delay means delays incurred by reason of Tenant's failure to deliver the Operation Plan by August 1, 1999, Tenant's failure to approve the Plans and Specifications as set forth in Section 17(a) or changes requested by Tenant in the Plans and Specifications after Tenant's approval thereof, and for such additional time as is equal to the time lost by Landlord or Landlord's contractors or suppliers in connection with the performance of Landlord's work and/or the construction of the Demised Premises and related improvements due to industry-wide strikes or other labor troubles that are not specific to Landlord or the Demised Premises, governmental restrictions and limitations not known to Landlord (or reasonably capable of being known to Landlord) as of the Lease Date, war or other national emergency, non-availability of materials or supplies, delay in transportation, accidents, floods, fire, damage or other casualties, weather or other conditions, acts or omissions of Tenant, or delays by utility companies in bringing utility lines to the Demised Premises to the extent not resulting from Landlord's failure to order or apply for the same in a timely manner. For purposes of this Lease, the term "substantial completion" or any grammatical variation thereof shall mean sufficient completion of construction of the Demised Premises in accordance with the Plans and Specifications (including the Performance Specifications) so that Tenant can lawfully occupy the Demised Premises for the uses permitted herein, subject only to minor punchlist items, the completion of which will not interfere with such permitted uses by Tenant, as evidenced by the delivery by Landlord to Tenant of (i) a Certificate of Occupancy or its equivalent (or Temporary Certificate of Occupancy or its equivalent) for the Demised Premises issued by the appropriate governmental authority if so required by applicable law, and (ii) a Certificate of Substantial Completion on standard AIA Form G-704 certified by Landlord's architect, working in good faith together with such duly licensed Tennessee architect, if any, as may be selected by Tenant as Tenant's architect by written notice to Landlord given, if at all, within thirty (30) days of the Lease Date.
Sample 1
Construction Delay means a material delay in the construction of the New Improvements for the Project that affects the Construction Timetable and is the result of (i) force majeure as described in Section 14.6, or (ii) the inability of the Company, through no fault of its own, to obtain the necessary permits and approvals of the City of Austin, or other governmental entity, in a timely manner.
Sample 1
Construction Delay shall have the meaning set forth on Schedule 1-1 attached hereto. Contiguous Remainder Space – “Contiguous Remainder Space” shall have the meaning set forth on Schedule 1-4 attached hereto. Delivery Date – “Delivery Date” shall mean the date that Landlord’s Work is substantially completed. Delay Inception Date – “Delay Inception Date” shall mean, in each applicable instance in this Lease where such term is expressly provided, the date on which an actual delay in Tenant’s performance of Tenant’s Initial Improvements or Tenant’s occupancy of the Demised Premises for the ordinary conduct of Tenant’s business occurs solely as a result of the situation (i.e., failure by Landlord to perform or a Construction Delay) set forth in the applicable instance; provided, however, that no such delay shall be deemed to have occurred prior to the date that is the earlier to occur of the date on which (x) Tenant delivers a notice to Landlord stating that Tenant’s performance of Tenant’s Initial Improvements or Tenant’s occupancy of the Demised Premises for the ordinary conduct of Tenant’s business is actually so delayed, which notice may be sent via e-mail to XXxxxxxx@xxxxxxxxxxx.xxx and XXxXxxxx@xxxxxxxxxxx.xxx, or any other e-mail address provided by Landlord to Tenant from time to time (the “Delay Inception Notice”), and (y) Landlord obtains actual knowledge of the delay; provided that with respect to clause (y) above, in no event shall such date be more than five (5) Business Days prior to Landlord’s receipt of the Delay Inception Notice. Demised Premises – “Demised Premises” shall mean, collectively, the entire rentable area of the FTI Units, as shown on the shaded portion of the plan annexed hereto as Exhibit “A” and made a part hereof. Designated Broker – “Designated Broker” shall collectively mean Colliers International NY LLC and JLL, Inc. Disabilities Act – “Disabilities Act” shall mean, collectively, The Americans with Disabilities Act of 1990, Public Law 101-336, 42 U.S.C. § 12101 et seq. and Local Law 58 of 1988, each as modified and supplemented from time to time, together with all regulations promulgated in connection therewith. Existing Lender – “Existing Lender” shall mean Xxxxx Fargo Bank, National Association. Expansion Notice Date – “Expansion Notice Date” shall have the meaning set forth on Schedule 1-5 attached hereto. Expiration Date – “Expiration Date” shall mean the date set forth in Subsection 2.01B below, as same may be extended pursuant to the ter...
Sample 1

Related to Construction Delay

  • Construction Work means all necessary action for the development, construction, renovation, furnishing, equipping and implementation of the Plans and Designs for the Hotel.

  • Construction project means an improvement that is constructed pursuant to an original contract.

  • Construction Period means the period commencing on the commencement date and ending on the date of practical completionClause 1.1 Definition of "Corrupt Practice" is added:

  • Construction activity means any clearing, grading or excavation associated with large construction activity or associated with small construction activity.

  • Tenant Delay means any delay in the completion of the Tenant Improvements attributable to Tenant, including, without limitation (i) Tenant’s failure to meet any time deadlines specified herein, (ii) Change Orders, (iii) the performance of any other work in the Leased Premises by any person, firm or corporation employed by or on behalf of Tenant, or any failure to complete or delay in completion of such work, (iv) Landlord’s inability to obtain an occupancy permit for the Leased Premises because of the need for completion of all or a portion of improvements being installed in the Leased Premises directly by Tenant, and (v) any other act or omission of Tenant.

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given piece of real property (including without limitation, the cost of acquiring such piece of real property (except to the extent any portion thereof is Unimproved Land), reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs), as reasonably determined by the Borrower in good faith. Real property under construction to be (but not yet) acquired by the Borrower or a Subsidiary upon completion of construction pursuant to a contract in which the seller of such real property is required to complete construction prior to, and as a condition precedent to, such acquisition, shall be subject to this definition.

  • Construction defect means a deficiency in or a deficiency arising out of the design, specifications, surveying, planning, supervision, or observation of construction or construction of residential improvements that results from any of the following:

  • construction site means a workplace where construction work is being performed;

  • Construction waste means solid waste that is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings and other structures. Construction waste consists of lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids, and garbage are not construction wastes and the disposal of such materials shall be in accordance with the regulations of the Virginia Waste Management Board.

  • Construction Plant means all machinery, appliances or things of whatsoever nature, required for the execution, completion or maintenance of the works, but does not include material or other things, intended to form or forming part of the permanent works.

  • Construction Debt means debt incurred to fund (a) all or a portion of a Capital Improvement, (b) interest payments (including periodic net payments under related interest rate swap agreements) and related fees on other Construction Debt or (c) distributions (including incremental Incentive Distributions) on Construction Equity.

  • Construction Completion Date means five (5) years from the date of this Agreement unless otherwise specified in writing by the Manager, Urban Development;

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Construction Costs means any and all costs incurred by the Contractor with respect to the construction and equipping, as the case may be, of the Project, whether paid or incurred prior to or after the date hereof, including, without limitation, costs for Site preparation, the removal or demolition of existing structures, the construction of the Project and related facilities and improvements, and all other work in connection therewith, security of the Site and Project, Contractors’ overhead and supervision at the Project site, all costs and expenses including any taxes or insurance premiums paid by the Contractor with respect to the Property, and administrative and other expenses necessary or incident to the Project, excluding Contractor’s home office overhead and field office overhead (which both shall be part of the Contractor’s General Conditions) and Contractor’s profit and fee. The term “Construction Costs” includes all Contractor’s costs associated with preparing or generating additional copies of any Contract Documents, as defined below, related to or required for the Project, including preparation or generation of additional plans and specifications for Contractor’s subcontractors. In no event shall Construction Costs exceed the Bid Proposal.

  • Construction Cost means and includes the cost of the entire construction of the Project, including all supervision, materials, supplies, labor, tools, equipment, transportation and/or other facilities furnished, used or consumed, without deduction on account of penalties, liquidated damages or other amounts withheld from payment to the contractor or contractors, but such cost shall not include the Consulting Engineer/Architect's fee, or other payments to the Consulting Engineer/Architect and shall not include cost of land or Rights-of-Way and Easement acquisition.

  • Landlord Delay means: (i) any actual delay in the completion of the work Tenant is required to perform hereunder which results from any failure of Landlord to act or provide approvals within five (5) business days; or (ii) the actual delay in the Substantial Completion of Landlord's Work due to any failure of Landlord, its agents, employees or contractors to perform the Base Building work or other work required to be provided by Landlord hereunder in compliance with the terms hereof and in compliance with applicable laws, rules and regulations or due to any other acts or omissions of Landlord, or its agents, or employees. Without limiting the generality of the foregoing, if Tenant has submitted its Final Design Drawings to Landlord in the form required by Section 2.2 above by the date set forth in Paragraph A of the Construction Schedule, the failure of Contractor's design/build contractors to complete their plans by the date set forth in Paragraph B on the Construction Schedule, for any reason other than a Tenant Delay, shall constitute a Landlord Delay for purposes hereof. Tenant shall provide prompt (within 48 hours of becoming aware of any such delay) written notice to Landlord ("Delay Notice") specifying the action or inaction which Tenant contends constitutes a Landlord Delay hereunder. The period of delay, however, shall commence to run on the date of the action or inaction and not on the date of the Delay Notice.

  • Direct Construction Cost means the sum of the amounts that the Construction Manager actually and necessarily incurs for General Conditions Costs, Cost of the Work and Construction Manager’s Contingency during the Construction Phase as allowed by this Agreement. Direct Construction Cost does not include Pre-Construction Phase Fees or Construction Phase Fees.

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Constructional Plant means all equipments, materials, appliances or things of whatsoever nature required for execution, completion or maintenance of the works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work.

  • Tenant Delays means any delay in the completion of the Tenant Improvements resulting from any or all of the following: (a) Tenant's failure to timely perform any of its obligations pursuant to this Work Letter Agreement, including any failure to complete, on or before the due date therefor, any action item which is Tenant's responsibility pursuant to the Work Schedule delivered by Landlord to Tenant pursuant to this Work Letter Agreement; (b) Tenant's changes to Space Plans or Final Plans after Landlord's approval thereof; (c) Tenant's request for materials, finishes, or installations which are not readily available or which are incompatible with the Standards; (d) any delay of Tenant in making payment to Landlord for Tenant's share of the Work Cost; or (e) any other act or failure to act by Tenant, Tenant's employees, agents, architects, independent contractors, consultants and/or any other person performing or required to perform services on behalf of Tenant.

  • Construction Completion means completion of construction with all support facilities for smooth functioning of the Project and Project Facilities.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Renovation Work means the renovation and/or construction work, as the context requires, including purchasing and/or leasing and installation of all [INSERT FOR RU] Packages, fixtures, equipment, furnishings, furniture, signs, computer terminals and related equipment, supplies and other items that would be required of a new System Hotel under the Manual, and any other [INSERT FOR RU] Packages, equipment, furnishings and supplies that we may require for you to operate the Hotel as set out in any PIP applicable to the Hotel.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Construction and Demolition Debris means and includes: