Exhibit 10.20
LEASE AGREEMENT
THIS LEASE AGREEMENT is made this 30th day of March, 2001, between
ARE-500 ARSENAL STREET, LLC, a Delaware limited liability company ("LANDLORD"),
and ACUSPHERE, INC., a Delaware corporation ("TENANT").
ADDRESS: 000 Xxxxxxx Xxxxxx, Xxxxxxxxx, Xxxxxxxxxxxxx
PREMISES: That portion of the Project, containing approximately 47,500
rentable square feet, as determined by Landlord, as shown on
EXHIBIT A.
PROJECT: The real property on which the building (the "BUILDING") in
which the Premises are located, together with all improvements
thereon and appurtenances thereto as described on EXHIBIT B.
BASE RENT: $166,250, per month RENTABLE AREA OF PREMISES: 47,500 sq. ft.
RENTABLE AREA OF PROJECT: 92,500 sq. ft. TENANT'S SHARE OF OPERATING EXPENSES: 51.35%
SECURITY DEPOSIT: $997,500 TARGET COMMENCEMENT DATE: October 1, 2001
RENT COMMENCEMENT
DATE: Commencement Date
RENT ADJUSTMENT
PERCENTAGE: Greater of 3.5% or the CPI Adjustment Percentage, not
to exceed 5.0%
BASE TERM: Beginning on the Commencement Date and ending 120 months
from the first day of the first full month of the Term (as
defined in Section 2) hereof
PERMITTED USE: Research and development laboratory, office (up to 50% of
the Premises) and other related uses consistent with the
character of the Project and otherwise in compliance with
the provisions of Section 7 hereof.
ADDRESS FOR RENT PAYMENT: LANDLORD'S NOTICE ADDRESS:
000 X. Xxx Xxxxxx Xxxxxx, Xxxxx 000 000 X. Xxx Xxxxxx Xxxxxx, Xxxxx 000
Xxxxxxxx, XX 00000 Xxxxxxxx, XX 00000
Attention: Accounts Receivable Attention: General Counsel
TENANT'S NOTICE ADDRESS:
00 Xxxxxx Xxxxxx
Xxxxxxxxx, XX 00000
Attention: Xx. Xxxxxx X. Xxxxxxx
The following Exhibits and Addenda are attached hereto and incorporated herein
by this reference:
[X] EXHIBIT A - PREMISES DESCRIPTION [X] EXHIBIT B - DESCRIPTION OF PROJECT
[X] EXHIBIT C - WORK LETTER [X] EXHIBIT D - COMMENCEMENT DATE
[X] EXHIBIT E - RULES AND REGULATIONS [X] EXHIBIT F - TENANT'S PERSONAL PROPERTY
[X] EXHIBIT G - ESTOPPEL CERTIFICATE [X] EXHIBIT H - NONDISTURBANCE AGREEMENT
[X] EXHIBIT I - NOTICE OF LEASE [X] EXHIBIT J - NOTICE OF LEASE TERMINATION
[X] SCHEDULE I - TANK AREA
1. LEASE OF PREMISES. Upon and subject to all of the terms and
conditions hereof, Landlord hereby leases the Premises to Tenant and Tenant
hereby leases the Premises from Landlord. The portions of the Project which are
for the non-exclusive use of tenants of the Project are collectively referred to
herein as the "COMMON AREAS." Tenant shall have the appurtenant right to use, in
common with others entitled thereto, the Common Areas. Landlord reserves the
right to modify Common Areas, provided that such modifications do not materially
adversely affect Tenant's use of the Premises for the Permitted Use.
2. DELIVERY; ACCEPTANCE OF PREMISES; COMMENCEMENT DATE. Landlord shall
use reasonable efforts to deliver the Premises to Tenant on or before the Target
Commencement Date, in broom clean condition, free of all occupants and their
property, with Landlord's Work, if any, Substantially Completed ("DELIVERY" or
"DELIVER"). If Landlord fails to timely Deliver the Premises, Landlord shall not
be liable to Tenant for any loss or damage resulting therefrom, and this Lease
shall not be void or voidable except as provided herein. If the Landlord does
not Deliver the Premises by December 31, 2001 (as the same shall be extended for
Force Majeure Delays and/or Tenant Delays), then for each day beyond December
31, 2001 (as the same may be extended) that Delivery is so delayed, Tenant shall
receive one day of free Base Rent equal to the daily Base Rent which would have
accrued for each particular day after December 31, 2001 (as the same may be
extended) until the Premises are Delivered. If Landlord is unable to Deliver the
Premises within 120 days of the Target Commencement Date by reason of Force
Majeure Delays and/or Tenant Delays, this Lease may be terminated by Landlord by
written notice to Tenant, and if so terminated: (a) the Security Deposit, or any
balance thereof (i.e., after deducting therefrom all amounts to which Landlord
is entitled under the provisions of this Lease), shall be returned to Tenant,
and (b) neither Landlord nor Tenant shall have any further rights, duties or
obligations under this Lease, except with respect to provisions which expressly
survive termination of this Lease. If Landlord is unable to Deliver the Premises
within 150 days of the Target Commencement Date by any reason other than Tenant
Delays, this Lease may be terminated by Tenant by written notice to Landlord,
and if so terminated: (a) the Security Deposit, or any balance thereof (i.e.,
after deducting therefrom all amounts to which Landlord is entitled under the
provisions of this Lease), shall be returned to Tenant and (b) neither Landlord
nor Tenant shall have any further rights, duties or obligations under this
Lease, except with respect to provisions which expressly survive termination of
this Lease. As used herein, the terms "LANDLORD'S WORK," "TENANTS' WORK," "FORCE
MAJEURE DELAYS," "TENANT DELAYS" and "SUBSTANTIALLY COMPLETED" shall have the
meanings set forth for such terms in the Work Letter.
The "COMMENCEMENT DATE" shall be the earliest of: (i) the date Landlord
Delivers the Premises to Tenant; (ii) the date Landlord could have Delivered the
Premises but for Tenant Delays; and (iii) the date Tenant conducts any business
in the Premises or any part thereof. Upon request of Landlord, Tenant shall
execute and deliver a written acknowledgment of the Commencement Date and the
expiration date of the Term when such are established in the form attached to
this Lease as EXHIBIT D; provided, however, Tenant's failure to execute and
deliver such acknowledgment shall not affect Landlord's rights hereunder. The
"TERM" of this Lease shall be the Base Term and any Extension Terms which Tenant
may elect pursuant to Section 40 hereof.
Except as set forth in the Work Letter, if applicable: (i) Tenant shall
accept the Premises in their condition as of the Commencement Date, subject to
all applicable Legal Requirements (as defined in Section 7 hereof); (ii)
Landlord shall have no obligation for any defects in the Premises; and (iii)
Tenant's taking possession of the Premises shall be conclusive evidence that
Tenant accepts the Premises and that the Premises were in good condition at the
time possession was taken. Any occupancy of the Premises by Tenant before the
Commencement Date shall be subject to all of the terms and conditions of this
Lease, including the obligation to pay Rent; provided, however, that Tenant's
entry pursuant to Section 6(a) of the Work Letter shall not obligate Tenant to
pay Rent.
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 3
Office/Laboratory
Tenant agrees and acknowledges that neither Landlord nor any agent of
Landlord has made any representation or warranty with respect to the condition
of all or any portion of the Premises or the Project, and/or the suitability of
the Premises or the Project for the conduct of Tenant's business, and Tenant
waives any implied warranty that the Premises or the Project are suitable for
the Permitted Use. This Lease constitutes the complete agreement of Landlord and
Tenant with respect to the subject matter hereof and supersedes any and all
prior representations, inducements, promises, agreements, understandings and
negotiations which are not contained herein. Landlord in executing this Lease
does so in reliance upon Tenant's representations, warranties, acknowledgments
and agreements contained herein.
3. RENT.
(a) BASE RENT. The first month's Base Rent and the Security Deposit
shall be due and payable on delivery of an executed copy of this Lease to
Landlord. Tenant shall pay to Landlord in advance, without demand, abatement
(except as otherwise expressly set forth herein), deduction or set-off, monthly
installments of Base Rent on or before the first day of each calendar month
during the Term hereof, in lawful money of the United States of America, at the
office of Landlord for payment of Rent set forth above, or to such other person
or at such other place as Landlord may from time to time designate in writing.
Payments of Base Rent for any fractional calendar month shall be prorated. The
obligation of Tenant to pay Base Rent and other sums to Landlord and the
obligations of Landlord under this Lease are independent obligations. Tenant
shall have no right at any time to xxxxx, reduce, or set-off any Rent (as
defined in Section 5) due hereunder except for any abatement as may be expressly
provided in this Lease.
(b) ADDITIONAL RENT. In addition to Base Rent, Tenant agrees to pay to
Landlord as additional rent ("ADDITIONAL RENT"): (i) Tenant's Share of
"Operating Expenses" (as defined in Section 5), and (ii) any and all other
amounts Tenant assumes or agrees to pay under the provisions of this Lease,
including, without limitation, any and all other sums that may become due by
reason of any default of Tenant or failure to comply with the agreements, terms,
covenants and conditions of this Lease to be performed by Tenant, after any
applicable notice and cure period.
4. BASE RENT ADJUSTMENTS. Base Rent shall be increased on each annual
anniversary of the first day of the first full month during the Term of this
Lease (each an "ADJUSTMENT DATE") by multiplying the Base Rent payable
immediately before such Adjustment Date by the Rent Adjustment Percentage and
adding the resulting amount to the Base Rent payable immediately before such
Adjustment Date. Base Rent, as so adjusted, shall thereafter be due as provided
herein. Base Rent adjustments for any fractional calendar month shall be
prorated. "CPI ADJUSTMENT PERCENTAGE" means (i) a fraction, stated as a
percentage, the numerator of which shall be the Index for the calendar month 3
months before the month in which the Adjustment Date occurs, and the denominator
of which shall be the Index for the calendar month 3 months before the last
Adjustment Date or, if no prior Base Rent adjustment has been made, 3 months
before the first day of the first full month during the Term of this Lease, less
(ii) 1.00. "INDEX" means the "Consumer Price Index-All Urban Consumers-Boston
Metropolitan Area, All Items" compiled by the U.S. Department of Labor, Bureau
of Labor Statistics, (1982-84 = 100). If a substantial change is made in the
Index, the revised Index shall be used, subject to such adjustments as Landlord
may reasonably deem appropriate in order to make the revised Index comparable to
the prior Index. If the Bureau of Labor Statistics ceases to publish the Index,
then the successor or most nearly comparable index, as reasonably determined by
Landlord, shall be used, subject to such adjustments as Landlord may reasonably
deem appropriate in order to make the new index comparable to the Index.
Landlord shall give Tenant written notice indicating the Base Rent, as adjusted
pursuant to this Section, and the method of computation. Failure to deliver such
notice shall not reduce, xxxxx, waive or diminish Tenant's obligation to pay the
adjusted Base Rent. If such notice is delivered to Tenant on or after an
Adjustment Date, Tenant shall pay to Landlord an
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 4
Office/Laboratory
amount equal to any underpayment of Base Rent by Tenant within 15 days of
Landlord's notice to Tenant.
5. OPERATING EXPENSE PAYMENTS. Landlord shall deliver to Tenant a
written estimate of Operating Expenses for each calendar year during the Term
(the "ANNUAL ESTIMATE"), which may be revised by Landlord from time to time
during such calendar year. During each month of the Term, on the same date that
Base Rent is due, Tenant shall pay Landlord an amount equal to 1/12 of Tenant's
Share of the Annual Estimate. Payments for any fractional calendar month shall
be prorated.
The term "OPERATING EXPENSES" means all costs and expenses of any kind
or description whatsoever incurred or accrued each calendar year by Landlord
with respect to ownership, management, maintenance, operation, administration
and/or repair of the Project (including, without duplication, Taxes (as defined
in Section 9), reasonable reserves consistent with good business practice for
future repairs and replacements, capital repairs and improvements amortized over
the lesser of 7 years and the useful life of such capital items, and the costs
of Landlord's third party property manager or, if there is no third party
property manager, administration rent in the amount of 3.0% of Base Rent), all
to be determined by Landlord in good faith, excluding only:
(a) the original construction costs of Landlord's Work and of the
Project and renovation prior to the date of the Lease and costs of correcting
defects in such original construction or renovation;
(b) capital expenditures for expansion of the Project;
(c) interest, principal payments of Mortgage (as defined in Section 27)
debts of Landlord, financing costs and amortization of funds borrowed by
Landlord, whether secured or unsecured and all payments of base rent (but not
taxes or operating expenses) under any ground lease or other underlying lease of
all or any portion of the Project;
(d) depreciation of the Project (except for capital improvements, the
cost of which are includable in Operating Expenses);
(e) advertising, legal and space planning expenses and leasing
commissions and other costs and expenses incurred in procuring and leasing space
to tenants for the Project, including any leasing office maintained in the
Project, free rent and construction allowances for tenants;
(f) legal and other expenses incurred in the negotiation or enforcement
of leases;
(g) completing, filtering, improving, renovating, painting, redecorating
or other work, which Landlord pays for or performs for specific tenants within
their premises, and costs of correcting defects in such work;
(h) costs of utilities outside normal business hours sold to tenants of
the Project;
(i) costs to be reimbursed by other tenants of the Project or Taxes to
be paid directly by Tenant or other tenants of the Project, whether or not
actually paid;
(j) salaries, wages, benefits and other compensation paid to officers
and employees of Landlord who are not assigned in whole or in part to the
operation, management, maintenance or repair of the Project; provided, however,
if assigned in part, such portion of the foregoing not allocated by Landlord to
the Project;
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 5
Office/Laboratory
(k) general organizational, administrative and overhead costs relating
to maintaining Landlord's existence, either as a corporation, partnership, or
other entity, including general corporate, legal and accounting expenses;
(l) costs (including attorneys' fees and costs of settlement, judgments
and payments in lieu thereof) incurred in connection with disputes with tenants,
other occupants, or prospective tenants, and costs and expenses, including legal
fees, incurred in connection with negotiations or disputes with employees,
consultants, management agents, leasing agents, purchasers or mortgagees of the
Building;
(m) costs incurred by Landlord due to the violation by Landlord, its
employees, agents or contractors or any tenant of the terms and conditions of
any lease of space in the Project or any Legal Requirement (as defined in
Section 7);
(n) tax penalties, fines or interest incurred as a result of Landlord's
negligence, inability or unwillingness to make payment and/or to file any tax or
informational returns when due, or from Landlord's failure to make any payment
required to be made by Landlord hereunder before delinquency;
(o) overhead and profit increment paid to Landlord or to subsidiaries or
affiliates of Landlord for goods and/or services in or to the Project to the
extent the same exceeds the costs of such goods and/or services rendered by
unaffiliated third parties on a competitive basis;
(p) costs arising from Landlord's charitable or political contributions
or fine art maintained at the Project;
(q) costs in connection with services (including electricity), items or
other benefits of a type which are not standard for the Project and which are
not available to Tenant without specific charges therefor, but which are
provided to another tenant or occupant of the Project, whether or not such other
tenant or occupant is specifically charged therefor by Landlord;
(r) costs incurred in the sale or refinancing of the Project;
(s) net income taxes of Landlord or the owner of any interest in the
Project, franchise, capital stock, gift, estate or inheritance taxes or any
federal, state or local documentary taxes imposed against the Project or any
portion thereof or interest therein; and
(t) any expenses otherwise includable within Operating Expenses to the
extent actually reimbursed by persons other than tenants of the Project under
leases for space in the Project.
Within 90 days after the end of each calendar year (or such longer
period as may be reasonably required), Landlord shall furnish to Tenant a
statement (an "ANNUAL STATEMENT") showing in reasonable detail: (a) the total
and Tenant's Share of actual Operating Expenses for the previous calendar year,
and (b) the total of Tenant's payments in respect of Operating Expenses for such
year. If Tenant's Share of actual Operating Expenses for such year exceeds
Tenant's payments of Operating Expenses for such year, the excess shall be due
and payable by Tenant as Rent within 30 days after delivery of such Annual
Statement to Tenant. If Tenant's payments of Operating Expenses for such year
exceed Tenant's Share of actual Operating Expenses for such year Landlord shall
pay the excess to Tenant within 30 days after delivery of such Annual Statement,
except that after the expiration, or earlier termination of the Term or if
Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the
excess to Tenant after deducting all other amounts due Landlord.
The Annual Statement shall be final and binding upon Tenant unless
Tenant, within 60 days after Tenant's receipt thereof, shall contest any item
therein by giving written notice to Landlord,
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 6
Office/Laboratory
specifying each item contested and the reason therefor. If, during such 60 day
period, Tenant reasonably and in good faith questions or contests the
correctness of Landlord's statement of Tenant's Share of Operating Expenses,
Landlord will provide Tenant with access to Landlord's books and records
relating to the operation of the Project and such information as Landlord
reasonably determines to be responsive to Tenant's questions (the "EXPENSE
INFORMATION"). If after Tenant's review of such Expense Information, Landlord
and Tenant cannot agree upon the amount of Tenant's Share of Operating Expenses,
then Tenant shall have the right to have an independent public accounting firm
selected by Tenant from among the 5 largest in the United States, working
pursuant to a fee arrangement other than a contingent fee (at Tenant's sole cost
and expense) and approved by Landlord (which approval shall not be unreasonably
withheld or delayed), audit and/or review the Expense Information for the year
in question (the "INDEPENDENT REVIEW"). The results of any such Independent
Review shall be binding on Landlord and Tenant. If the Independent Review shows
that the payments actually made by Tenant with respect to Operating Expenses for
the calendar year in question exceeded Tenant's Share of Operating Expenses for
such calendar year, Landlord shall at Landlord's option either (i) credit the
excess amount to the next succeeding installments of estimated Operating
Expenses or (ii) pay the excess to Tenant within 30 days after delivery of such
statement, except that after the expiration or earlier termination of the Term
or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the
excess to Tenant after deducting all other amounts due Landlord. If the
Independent Review shows that Tenant's payments with respect to Operating
Expenses for such calendar year were less than Tenant's Share of Operating
Expenses for the calendar year, Tenant shall pay the deficiency to Landlord
within 30 days after delivery of such statement. If the Independent Review shows
that Tenant has overpaid with respect to Operating Expenses by more than 5% then
Landlord shall reimburse Tenant for all costs incurred by Tenant for the
Independent Review. Operating Expenses for the calendar years in which Tenant's
obligation to share therein begins and ends shall be prorated. Notwithstanding
anything set forth herein to the contrary, if the Project is not at least 95%
occupied on average during any year of the Term, Tenant's Share of Operating
Expenses for such year shall be computed as though the Project had been 95%
occupied on average during such year.
"TENANT'S SHARE" shall be the percentage set forth on the first page of
this Lease as Tenant's Share as reasonably adjusted by Landlord following a
measurement of the rentable square footage of the Project and the Premises to be
done by Landlord within 90 days of the Commencement Date, or as soon as
reasonably possible thereafter, and shall be subject to further adjustment for
changes in the physical size of the Premises or the Project occurring
thereafter. Any such measurement shall be performed in accordance with the 1996
Standard Method of Measuring Floor Area in Office Buildings as adopted by the
Building Owners and Managers Association (ANSI/BOMA 265.1-1996). Landlord may
equitably increase Tenant's Share for any item of expense or cost reimbursable
by Tenant that relates to a repair, replacement, or service that benefits only
the Premises or only a portion of the Project that includes the Premises or that
varies with occupancy or use. Base Rent, Tenant's Share of Operating Expenses
and all other amounts payable by Tenant to Landlord hereunder are collectively
referred to herein as "RENT."
6. SECURITY DEPOSIT. Tenant shall deposit with Landlord on the date of
this Lease security (the "SECURITY DEPOSIT") for the performance of all of its
obligations in the amount set forth in the Basic Lease Provisions, which
security shall be in the form of either cash or an unconditional and irrevocable
letter of credit (the "LETTER OF CREDIT"): (i) in form and substance reasonably
satisfactory to Landlord, (ii) naming Landlord as beneficiary, (iii) expressly
allowing Landlord to draw upon it at any time from time to time by delivering to
the issuer notice that Landlord is entitled to draw thereunder, (iv) drawable on
an FDIC-insured financial institution reasonably satisfactory to Landlord, and
(v) redeemable in the States of Massachusetts or California. If Tenant does not
provide Landlord with a substitute Letter of Credit complying with all of the
requirements hereof at least 10 days before the stated expiration date of the
then current Letter of Credit, Landlord shall have the right to draw upon the
current Letter of Credit and hold the funds drawn as the Security Deposit. Not
more than twice during the Term hereof, if, as described in the immediately
preceding
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 7
sentence, Landlord draws the Letter of Credit, Tenant may replace the Security
Deposit by providing Landlord with a replacement Letter of Credit (i.e., meeting
the requirements of this Section 6), whereupon Landlord shall return that
portion of the funds drawn by Landlord on the original Letter of Credit and not
applied to Tenant's other obligations under this Lease. The Security Deposit
shall be held by Landlord as security for the performance of Tenant's
obligations under this Lease. The Security Deposit is not an advance rental
deposit or a measure of Landlord's damages in case of Tenant's default. Upon
each occurrence of a Default (as defined in Section 20), Landlord may use all or
any part of the Security Deposit to the extent necessary to pay delinquent
payments due under this Lease, and the cost of any damage, injury, expense or
liability caused by such Default, without prejudice to any other remedy provided
herein or provided by law. Upon any such use of all or any portion of the
Security Deposit, Tenant shall pay Landlord on demand the amount that will
restore the Security Deposit to its original amount or, as applicable, shall
provide an amendment to the Letter of Credit increasing the amount thereof to
its original amount. Tenant hereby waives the provisions of any law, now or
hereafter in force, which provide that Landlord may claim from a security
deposit only those sums reasonably necessary to remedy defaults in the payment
of Rent, to repair damage caused by Tenant or to clean the Premises, it being
agreed that Landlord may, in addition, claim those sums reasonably necessary to
compensate Landlord for any other loss or damage, foreseeable or unforeseeable,
caused by the act or omission of Tenant or any officer, employee, agent or
invitee of Tenant. Upon bankruptcy or other debtor-creditor proceedings against
Tenant, the Security Deposit shall be deemed to be applied first to the payment
of Rent and other charges due Landlord for periods prior to the filing of such
proceedings. Upon any such use of all or any portion of the Security Deposit,
Tenant shall, within 5 days after demand from Landlord, restore the Security
Deposit to its original amount. The Security Deposit, or any balance thereof
(i.e., after deducting therefrom all amounts to which Landlord is entitled under
the provisions of this Lease), shall be returned to Tenant (or, at Landlord's
option, to the last assignee of Tenant's interest hereunder) within 60 days
after the expiration or earlier termination of this Lease.
If Landlord transfers its interest in the Project or this Lease,
Landlord shall either (a) transfer any Security Deposit then held by Landlord to
a person or entity assuming Landlord's obligations under this Section 6, or (b)
return to Tenant any Security Deposit then held by Landlord and remaining after
the deductions permitted herein. Upon such transfer to such transferee or the
return of the Security Deposit to Tenant, Landlord shall have no further
obligation with respect to the Security Deposit, and Tenant's right to the
return of the Security Deposit shall apply solely against Landlord's transferee.
The Security Deposit is not an advance rental deposit or a measure of Landlord's
damages in case of Tenant's default. Landlord's obligation respecting the
Security Deposit is that of a debtor, not a trustee and; no interest shall
accrue thereon.
7. USE. The Premises shall be used solely for the Permitted Use set
forth in the Basic Lease Provisions, in compliance with all laws, orders,
judgments, ordinances, regulations, codes, directives, permits, licenses,
covenants and restrictions now or hereafter applicable to the Premises, and the
use and occupancy thereof (collectively, "LEGAL REQUIREMENTS"). Tenant shall,
upon 5 days' written notice from Landlord, discontinue any use of the Premises
which is declared by any Governmental Authority (as defined in Section 9) having
jurisdiction to be a violation of any Legal Requirement. Tenant will not use or
permit the Premises to be used for any purpose or in any manner that would void
Tenant's or Landlord's insurance, increase the insurance risk, or cause the
disallowance of any sprinkler or other credits. Tenant shall reimburse Landlord
promptly upon demand for any additional premium charged for any such insurance
policy by reason of Tenant's failure to comply with the provisions of this
Section or otherwise caused by Tenant's use and/or occupancy of the Premises.
Tenant will use the Premises in a careful, safe and proper manner and will not
commit waste, overload the floor or structure of the Premises, subject the
Premises to use that would damage the Premises or obstruct or interfere with the
rights of Landlord or other tenants or occupants of the Project, including
conducting or giving notice of any auction, liquidation, or going out of
business sale on the Premises, or using or allowing the Premises to be used for
any unlawful purpose. Tenant shall cause any equipment or machinery to be
installed in the Premises
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 8
so as to reasonably prevent sounds or vibrations from the Premises from
extending into Common Areas, or other space in the Project. Tenant shall not
place any machinery or equipment weighing 1,000 pounds or more in or upon the
Premises or transport or move such items through the Common Areas of the Project
or in the Project elevators without the prior written consent of Landlord, which
shall not be unreasonably withheld or delayed. Except as may be provided under
the Work Letter, Tenant shall not, without the prior written consent of
Landlord, use the Premises in any manner which will require ventilation, air
exchange, heating, gas, steam, electricity or water beyond the existing capacity
of the Project as proportionately allocated to the Premises based upon Tenant's
Share as usually furnished for the Permitted Use.
Landlord shall be responsible for the compliance of the Common Areas of the
Project with the Americans With Disabilities Act, 42 U.S.C. Section 12101, et
seq. (together with regulations promulgated pursuant thereto, "ADA") as of the
Commencement Date. Tenant, at its sole expense, shall make any alterations or
modifications to the interior or the exterior of the Premises or the Project
that are required by Legal Requirements (including, without limitation,
compliance of the Premises with ADA) related to Tenant's use or occupancy of the
Premises. Notwithstanding any other provision herein to the contrary, Tenant
shall be responsible for any and all demands, claims, liabilities, losses,
costs, expenses, actions, causes of action, damages or judgments, and all
reasonable expenses incurred in investigating or resisting the same (including,
without limitation, reasonable attorneys' fees, charges and disbursements and
costs of suit) (collectively, "CLAIMS") arising out of or in connection with
Legal Requirements, and Tenant shall indemnify, defend, hold and save Landlord
harmless from and against any and all Claims arising out of or in connection
with any failure of the Premises to comply with any Legal Requirement
(including, without limitation, compliance of the Premises with ADA).
8. HOLDING OVER. If, with Landlord's express written consent, Tenant
retains possession of the Premises after the termination of the Term, (i) unless
otherwise agreed in such written consent, such possession shall be subject to
immediate termination by Landlord at any time, (ii) all of the other terms and
provisions of this Lease (including, without limitation, the adjustment of Base
Rent pursuant to Section 4 hereof) shall remain in full force and effect
(excluding any expansion or renewal option or other similar right or option)
during such holdover period, (iii) Tenant shall continue to pay Base Rent in the
amount payable upon the date of the expiration or earlier termination of this
Lease or such other amount as Landlord may indicate, in Landlord's sole and
absolute discretion, in such written consent, and (iv) all other payments shall
continue under the terms of this Lease. If Tenant remains in possession of the
Premises after the expiration or earlier termination of the Term without the
express written consent of Landlord, (A) Tenant shall become a tenant at
sufferance upon the terms of this Lease except that the monthly rental shall be
equal to 150% of the Rent in effect during the last 30 days of the Term, and (B)
Tenant shall be responsible for all damages suffered by Landlord resulting from
or occasioned by Tenant's holding over, including consequential damages. No
holding over by Tenant, whether with or without consent of Landlord, shall
operate to extend this Lease except as otherwise expressly provided, and this
Section 8 shall not be construed as consent for Tenant to retain possession of
the Premises. Acceptance by Landlord of Rent after the expiration of the Term or
earlier termination of this Lease shall not result in a renewal or reinstatement
of this Lease.
9. TAXES. Landlord shall pay, as part of Operating Expenses, all taxes,
levies, assessments and governmental charges of any kind (collectively referred
to as "TAXES") imposed by any federal, state, regional, municipal, local or
other governmental authority or agency, including, without limitation,
quasi-public agencies (collectively, "GOVERNMENTAL AUTHORITY") during the Term,
including, without limitation, all Taxes: (i) imposed on or measured by or
based, in whole or in part, on rent payable to Landlord under this Lease and/or
from the rental by Landlord of the Project or any portion thereof, or (ii) based
on the square footage, assessed value or other measure or evaluation of any kind
of the Premises or the Project, or (iii) assessed or imposed by or on the
operation or maintenance of any portion of the Premises or the Project,
including parking, or (iv) assessed or imposed by, or at the direction of, or
resulting from statutes or regulations, or
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 9
interpretations thereof, promulgated by, any Governmental Authority, or (v)
imposed as a license or other fee on Landlord's business of leasing space in the
Project. Landlord may contest by appropriate legal proceedings the amount,
validity, or application of any Taxes or liens securing Taxes. Taxes shall not
include any net income taxes imposed on Landlord unless such net income taxes
are in substitution for any Taxes payable hereunder. If any such Tax is levied
or assessed directly against Tenant, then Tenant shall be responsible for and
shall pay the same at such times and in such manner as the taxing authority
shall require. Tenant shall pay, prior to delinquency, any and all Taxes levied
or assessed against any personal property or trade fixtures placed by Tenant in
the Premises, whether levied or assessed against Landlord or Tenant. If any
Taxes on Tenant's personal property or trade fixtures are levied against
Landlord or Landlord's property, or if the assessed valuation of the Project is
increased by a value attributable to improvements in or alterations to the
Premises, whether owned by Landlord or Tenant and whether or not affixed to the
real property so as to become a part thereof, higher than the base valuation on
which Landlord from time-to-time allocates Taxes to all tenants in the Project,
Landlord shall have the right, but not the obligation, to pay such Taxes.
Landlord's determination of any excess assessed valuation shall be binding and
conclusive, absent manifest error. The amount of any such payment by Landlord
shall constitute Additional Rent due from Tenant to Landlord immediately upon
demand. Notwithstanding anything to the contrary herein, if a special tax or
assessment included in Taxes and payable by Landlord hereunder (other than Taxes
assessed on Tenant's personal property or trade fixtures) may be paid in
installments, Landlord shall be deemed to have elected to pay such special tax
or assessment on an installment basis over the longest period allowed and Taxes
shall include any interest and other payments that would be payable as a result
of an election to pay such special tax or assessment on an installment basis. If
Landlord receives a refund of Taxes attributable to the Term, Tenant's Share of
such refund, less Landlord's costs in collecting such refund, shall be credited
against Tenant's Share of Operating Expenses.
10. PARKING. At no additional cost to Tenant during the Base Term (but
without limitation upon Section 5), Tenant shall have the right to park in
common with other tenants of the Project pro rata in accordance with the
rentable area of the Premises and the rentable areas of the Project occupied by
such other tenants in those areas designated for non-reserved parking, subject
in each case to Landlord's reasonable rules and regulations. Landlord may
allocate parking spaces among Tenant and other tenants in the Project pro rata
as described above if Landlord determines that such parking facilities are
becoming crowded. Notwithstanding the foregoing, but subject to Force Majeure, a
Taking and the exercise by Landlord of its rights under this Lease, Tenant shall
have the right to use 2 parking spaces at the Project for each 1,000 square feet
of Rentable Area of the Premises from time to time demised hereunder. Tenant's
use of all or any portion of a parking space located in the Tank Area (as
hereinafter defined), shall be charged against Tenant's rights hereunder on the
basis of one parking space for each parking space or portion thereof so used by
Tenant. Landlord shall not be responsible for enforcing Tenant's parking rights
against any third parties, including other tenants of the Project.
11. UTILITIES, SERVICES. Landlord shall provide, subject to the terms of
this Section 11, water, electricity, hvac, light, power, telephone, sewer, and
other utilities (including gas and fire sprinklers to the extent the Project is
plumbed for such services), refuse and trash collection and janitorial services
(collectively, "UTILITIES"). Landlord shall pay, as Operating Expenses or
subject to Tenant's reimbursement obligation, for all Utilities used on the
Premises, all maintenance charges for Utilities, and any storm sewer charges or
other similar charges for Utilities imposed by any Governmental Authority or
Utility provider, and any taxes, penalties, surcharges or similar charges
thereon. Except as set forth in the Work Letter, Landlord may cause, at Tenant's
expense, any Utilities to be separately metered or charged directly to Tenant by
the provider. Tenant shall pay directly to the Utility provider, prior to
delinquency, any separately metered Utilities and services which may be
furnished to Tenant or the Premises during the Term. Tenant shall pay, as part
of Operating Expenses, its share of all charges for jointly metered Utilities
based upon consumption, as reasonably determined by Landlord. No interruption or
failure of Utilities, from any cause
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 10
whatsoever other than Landlord's willful misconduct, shall result in eviction or
constructive eviction of Tenant, termination of this Lease or the abatement of
Rent. Tenant agrees to limit use of water and sewer with respect to Common Areas
to normal restroom use.
12. ALTERATIONS AND TENANT'S PROPERTY. Any alterations, additions, or
improvements made to the Premises by or on behalf of Tenant, including
additional locks or bolts of any kind or nature upon any doors or windows in the
Premises, but excluding installation, removal or realignment of furniture
systems (other than removal of furniture systems owned or paid for by Landlord)
not involving any modifications to the structure or connections (other then by
ordinary plugs or jacks) to Building Systems (as defined in Section 13)
("ALTERATIONS") shall be subject to Landlord's prior written consent, which may
be given or withheld in Landlord's sole discretion if any such Alteration
affects the structure or Building Systems. Tenant may construct nonstructural
Alterations in the Premises without Landlord's prior approval if the aggregate
cost of all such work in any 12 month period does not exceed $50,000 (a
"NOTICE-ONLY ALTERATION"), provided Tenant notifies Landlord in writing of such
intended Notice-Only Alteration, and such notice shall be accompanied by plans,
specifications, work contracts and such other information concerning the nature
and cost of the Notice-Only Alteration as may be reasonably requested by
Landlord, which notice and accompanying materials shall be delivered to Landlord
not less than 15 business days in advance of any proposed construction. If
Landlord approves any Alterations, at the time of Landlord's approval, Landlord
may impose such conditions on Tenant in connection with the commencement,
performance and completion of such Alterations as Landlord may deem appropriate
in Landlord's reasonable discretion. Any request for approval shall be in
writing, delivered not less than 15 business days in advance of any proposed
construction, and accompanied by plans, specifications, bid proposals, work
contracts and such other information concerning the nature and cost of the
alterations as may be reasonably requested by Landlord, including the identities
and mailing addresses of all persons performing work or supplying materials.
Landlord's right to review plans and specifications and to monitor construction
shall be solely for its own benefit, and Landlord shall have no duty to ensure
that such plans and specifications or construction comply with applicable Legal
Requirements. Tenant shall cause, at its sole cost and expense, all Alterations
to comply with insurance requirements and with Legal Requirements and shall
implement at its sole cost and expense any alteration or modification required
by Legal Requirements as a result of any Alterations. Tenant shall pay to
Landlord, as Additional Rent, on demand an amount equal to the lesser of (i) 3%
of all charges incurred by Tenant or its contractors or agents in connection
with any Alteration to cover Landlord's overhead and expenses for plan review,
coordination, scheduling and supervision and (ii) $15,000. Before Tenant begins
any Alteration, Landlord may post on and about the Premises notices of
non-responsibility pursuant to applicable law. Tenant shall reimburse Landlord
for, and indemnify and hold Landlord harmless from, any expense incurred by
Landlord by reason of faulty work done by Tenant or its contractors, delays
caused by such work, or inadequate cleanup.
Tenant shall furnish security or make other arrangements satisfactory to
Landlord, in Landlord's reasonable determination, to assure payment for the
completion of all Alterations work free and clear of liens, and shall provide
certificates of insurance for workers' compensation and other coverage in
amounts and from an insurance company satisfactory to Landlord protecting
Landlord against liability for personal injury or property damage during
construction. Upon completion of any Alterations, Tenant shall deliver to
Landlord: (i) sworn statements setting forth the names of all contractors and
subcontractors who did the work and final lien waivers from all such contractors
and subcontractors; and (ii) "as built" plans for any such Alteration.
Other than (i) the items, if any, listed on EXHIBIT F attached hereto,
(ii) any items agreed by Landlord in writing to be included on EXHIBIT F in the
future, and (iii) any trade fixtures, machinery, equipment and other personal
property not paid for out of the TI Fund (as defined in the Work Letter) which
may be removed without material damage to the Premises, which damage shall be
repaired (including capping or terminating utility hook-ups behind walls) by
Tenant during the Term
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 11
(collectively, "TENANT'S PROPERTY"), all property of any kind paid for with the
TI Fund, all Alterations, real property fixtures, built-in machinery and
equipment, built-in casework and cabinets and other similar additions and
improvements built into the Premises so as to become an integral part of the
Premises, such as fume hoods which penetrate the roof or plenum area, built-in
cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms,
deionized water systems, glass washing equipment, autoclaves, chillers, built-in
plumbing, electrical and mechanical equipment and systems, and any power
generator and transfer switch (collectively, "INSTALLATIONS"), shall be and
shall remain the property of Landlord during the Term and following the
expiration or earlier termination of the Term, shall not be removed by Tenant at
any time during the Term and shall remain upon and be surrendered with the
Premises as a part thereof in accordance with Section 28 following the
expiration or earlier termination of this Lease; provided, however, that
Landlord shall, at the time its approval of such Installation is requested or at
the time it receives notice of a Notice-Only Alteration notify Tenant if it has
elected to cause Tenant to remove such Installation upon the expiration or
earlier termination of this Lease. If Landlord so elects, Tenant shall remove
such Installation upon the expiration or earlier termination of this Lease and
restore any damage caused by or occasioned as a result of such removal,
including, when removing any of Tenant's Property which was plumbed, wired or
otherwise connected to any of the Building Systems, capping off all such
connections behind the walls of the Premises and repairing any holes. During any
such restoration period, Tenant shall pay Rent to Landlord as provided herein as
if said space were otherwise occupied by Tenant. The provisions of this Section
12 shall not apply to the Tenant Improvements installed pursuant to the Work
Letter.
13. LANDLORD'S REPAIRS. Landlord, as an Operating Expense, shall
maintain, repair and replace the exterior membrane of the roof of the Building,
all of the structural, exterior, parking and other Common Areas of the Project,
including HVAC, plumbing, fire sprinklers, elevators and all other building
systems serving the Premises and other portions of the Project ("BUILDING
SYSTEMS"), in good repair, reasonable wear and tear and losses and damages which
are both uninsured and caused by Tenant, or by any of Tenant's agents, servants,
employees, invitees and contractors (collectively, "TENANT PARTIES") excluded.
Losses and damages caused by Tenant or any Tenant Party shall be repaired by
Landlord, to the extent not covered by insurance, at Tenant's sole cost and
expense. Landlord reserves the right to stop Building System services when
necessary (i) by reason of accident or emergency, or (ii) for planned repairs,
alterations or improvements, which are, in the judgment of Landlord, desirable
or necessary to be made, until said repairs, alterations or improvements shall
have been completed. Landlord shall have no responsibility or liability for
failure to supply Building System services during any such period of
interruption; provided, however, that Landlord shall give Tenant 24 hours
advance notice of any planned stoppage of Building System services for routine
maintenance, repairs, alterations or improvements. Tenant shall promptly give
Landlord written notice of any repair required by Landlord pursuant to this
Section, after which Landlord shall have a reasonable opportunity to effect such
repair. Landlord shall not be liable for any failure to make any repairs or to
perform any maintenance unless such failure shall persist for an unreasonable
time after Tenant's written notice of the need for such repairs or maintenance.
Tenant waives its rights under any state or local law to terminate this Lease or
to make such repairs at Landlord's expense and agrees that the parties'
respective rights with respect to such matters shall be solely as set forth
herein. Repairs required as the result of fire, earthquake, flood, vandalism,
war, or similar cause of damage or destruction shall be controlled by Section
18.
14. TENANT'S REPAIRS. Subject to Section 13 hereof, Tenant, at its
expense, shall repair, replace and maintain in good condition all portions of
the Premises, including, without limitation, entries, doors, ceilings, interior
windows, interior walls, and the interior side of demising walls. Such repair
and replacements may include capital expenditures and repairs whose benefit may
extend beyond the Term. Should Tenant fail to make any such repair or
replacement or fail to maintain the Premises, Landlord shall give Tenant notice
of such failure. If Tenant fails to commence cure of such default within 10 days
of Landlord's notice, and thereafter diligently prosecute such cure to
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 12
completion, Landlord may perform such work and shall be reimbursed by Tenant
within 10 days after demand therefor; provided, however, that if such default by
Tenant creates or could create an emergency, Landlord may immediately commence
cure of such default and shall thereafter be entitled to recover the costs of
such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full
uninsured cost of any repair or replacement to any part of the Project that
results from damage caused by Tenant or any Tenant Party and any repair that
benefits only the Premises.
15. MECHANIC'S LIENS. Tenant shall discharge, by bond or otherwise, any
mechanic's lien filed against the Premises or against the Project for work
claimed to have been done for, or materials claimed to have been furnished to,
Tenant within 15 days after Tenant receives notice thereof, at Tenant's sole
cost and shall otherwise keep the Premises and the Project free from any liens
arising out of work performed, materials furnished or obligations incurred by
Tenant. Should Tenant fail to discharge any lien described herein, Landlord
shall have the right, but not the obligation, to pay such claim or post a bond
or otherwise provide security to eliminate the lien as a claim against title to
the Project and the cost thereof shall be immediately due from Tenant as
Additional Rent. If Tenant shall lease or finance the acquisition of office
equipment, furnishings, or other personal property of a removable nature
utilized by Tenant in the operation of Tenant's business, Tenant warrants that
any Uniform Commercial Code Financing Statement executed by Tenant will upon its
face or by exhibit thereto indicate that such Financing Statement is applicable
only to removable personal property of Tenant located within the Premises. In no
event shall the address of the Project be furnished on the statement without
qualifying language as to applicability of the lien only to removable personal
property, located in an identified suite held by Tenant.
16. INDEMNIFICATION. Tenant hereby indemnifies and agrees to defend,
save and hold Landlord harmless from and against any and all Claims for injury
or death to persons or damage to property occurring within or about the
Premises, arising directly or indirectly out of use or occupancy of the Premises
or a breach or default by Tenant in the performance of any of its obligations
hereunder, unless caused by the willful misconduct or negligence of Landlord.
Landlord shall not be liable to Tenant for, and Tenant assumes all risk of
damage to, personal property (including, without limitation, loss of records
kept within the Premises). Tenant further waives any and all Claims for injury
to Tenant's business or loss of income relating to any such damage or
destruction of personal property (including, without limitation, any loss of
records). Landlord shall not be liable for any damages arising from any act,
omission or neglect of any tenant in the Project or of any other third party.
17. INSURANCE. Landlord shall maintain all risk property and, if
applicable, sprinkler damage insurance covering the full replacement cost of the
Project or such lesser coverage amount as Landlord may elect provided such
coverage amount is not less than 90% of such full replacement cost. Landlord
shall further procure and maintain commercial general liability insurance with a
single loss limit of not less than $2,000,000 for bodily injury and property
damage with respect to the Project. Landlord may, but is not obligated to,
maintain such other insurance and additional coverages as it may deem necessary,
including, but not limited to, flood, environmental hazard and earthquake, loss
or failure of building equipment, errors and omissions, rental loss during the
period of repair or rebuilding, workers' compensation insurance and fidelity
bonds for employees employed to perform services and insurance for any
improvements installed by Tenant or which are in addition to the standard
improvements customarily furnished by Landlord without regard to whether or not
such are made a part of the Project. All such insurance shall be included as
part of the Operating Expenses. The Project may be included in a blanket policy
(in which case the cost of such insurance allocable to the Project will be
determined by Landlord based upon the insurer's cost calculations). Tenant shall
also reimburse Landlord for any increased premiums or additional insurance which
Landlord reasonably deems necessary as a result of Tenant's use of the Premises.
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 13
Office/Laboratory
Tenant, at its sole cost and expense, shall maintain during the Term:
all risk property insurance with business interruption and extra expense
coverage, covering the full replacement cost of all property and improvements
installed or placed in the Premises by Tenant at Tenant's expense; workers'
compensation insurance with no less than the minimum limits required by law;
employer's liability insurance with such limits as required by law; and
commercial general liability insurance, with a minimum limit of not less than
$2,000,000 per occurrence for bodily injury and not less than $2,000,000 for
property damage with respect to the Premises. The commercial general liability
insurance policies shall name Landlord, its officers, directors, employees,
managers, agents, invitees and contractors (collectively, "LANDLORD PARTIES"),
as additional insureds; insure on an occurrence and not a claims-made basis; be
issued by insurance companies which have a rating of not less than policyholder
rating of A and financial category rating of at least Class X in "Best's
Insurance Guide"; shall not be cancelable for nonpayment of premium unless 10
days prior written notice shall have been given to Landlord from the insurer;
contain a hostile fire endorsement and a contractual liability endorsement; and
provide primary coverage to Landlord (any policy issued to Landlord providing
duplicate or similar coverage shall be deemed excess over Tenant's policies).
Such policies or certificates thereof shall be delivered to Landlord by Tenant
upon commencement of the Term and upon each renewal of said insurance. Tenant's
policy may be a "blanket policy" with an aggregate per location endorsement
which specifically provides that the amount of insurance shall not be prejudiced
by other losses covered by the policy. Tenant shall, at least 5 days prior to
the expiration of such policies, furnish Landlord with renewal certificates.
In each instance where insurance is to name Landlord as an additional
insured, Tenant shall upon written request of Landlord also designate and
furnish certificates so evidencing Landlord as additional insured to: (i) any
lender of Landlord holding a security interest in the Project or any portion
thereof, (ii) the landlord under any lease wherein Landlord is tenant of the
real property on which the Project is located, if the interest of Landlord is or
shall become that of a tenant under a ground or other underlying lease rather
than that of a fee owner, and/or (iii) any management company retained by
Landlord to manage the Project.
The property insurance obtained by Landlord and Tenant shall include a
waiver of subrogation by the insurers and all rights based upon an assignment
from its insured, against Landlord or Tenant, and their respective officers,
directors, employees, managers, agents, invitees and contractors ("RELATED
PARTIES"), in connection with any loss or damage thereby insured against.
Neither party nor its respective Related Parties shall be liable to the other
for loss or damage caused by any risk insured against under property insurance
required to be maintained hereunder, and each party waives any claims against
the other party, and its respective Related Parties, for such loss or damage.
The failure of a party to insure its property shall not void this waiver.
Landlord and its respective Related Parties shall not be liable for, and Tenant
hereby waives all claims against such parties for, business interruption and
losses occasioned thereby sustained by Tenant or any person claiming through
Tenant resulting from any accident or occurrence in or upon the Premises or the
Project from any cause whatsoever. If the foregoing waivers shall contravene any
law with respect to exculpatory agreements, the liability of Landlord or Tenant
shall be deemed not released but shall be secondary to the other's insurer.
Landlord may require insurance policy limits to be raised to conform
with requirements of Landlord's lender and/or to bring coverage limits to levels
then being generally required of new tenants within the Project.
18. RESTORATION. If at any time during the Term the Project or the
Premises are damaged or destroyed by a fire or other insured casualty, Landlord
shall notify Tenant within 60 days after discovery of such damage as to the
amount of time Landlord reasonably estimates it will take to restore the Project
or the Premises, as applicable (the "RESTORATION PERIOD"). If the Restoration
Period is estimated to exceed 12 months (the "MAXIMUM RESTORATION PERIOD"),
Landlord may, in such notice, elect to terminate this Lease as of the date that
is 75 days after the
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 14
Office/Laboratory
date of discovery of such damage or destruction; provided, however, that
notwithstanding Landlord's election to restore, Tenant may elect to terminate
this Lease by written notice to Landlord delivered within 5 business days of
receipt of a notice from Landlord estimating a Restoration Period for the
Premises longer than the Maximum Restoration Period. Unless either Landlord or
Tenant so elects to terminate this Lease, Landlord shall, subject to receipt of
sufficient insurance proceeds (with any deductible to be treated as a current
Operating Expense), promptly restore the Premises (excluding the improvements
installed by Tenant or by Landlord and paid for by Tenant), subject to delays
arising from the collection of insurance proceeds, from Force Majeure events or
as needed to obtain any license, clearance or other authorization of any kind
required to enter into and restore the Premises issued by any Governmental
Authority having jurisdiction over the use, storage, handling, treatment,
generation, release, disposal, removal or remediation of Hazardous Materials (as
defined in Section 30) in, on or about the Premises (collectively referred to
herein as "HAZARDOUS MATERIALS CLEARANCES"); provided, however, that if repair
or restoration of the Premises is not substantially complete as of the end of
the Maximum Restoration Period or, if longer, the Restoration Period, Landlord
may, in its sole and absolute discretion, elect not to proceed with such repair
and restoration or Tenant may by written notice to Landlord delivered within 5
business days of the expiration of the Maximum Restoration Period or, if longer,
the Restoration Period, elect to terminate this Lease, in which event Landlord
shall be relieved of its obligation to make such repairs or restoration and this
Lease shall terminate as of the date that is 75 days after the later of: (i)
discovery of such damage or destruction, or (ii) the date all required Hazardous
Materials Clearances are obtained, but Landlord shall retain any Rent paid and
the right to any Rent payable by Tenant prior to such election by Landlord or
Tenant.
Tenant, at its expense, shall promptly perform, subject to delays
arising from the collection of insurance proceeds, from Force Majeure (as
defined in Section 34) events or to obtain Hazardous Material Clearances, all
repairs or restoration not required to be done by Landlord and shall promptly
re-enter the Premises and commence doing business in accordance with this Lease.
Notwithstanding the foregoing, Landlord may terminate this Lease if the Premises
are damaged during the last 2 years of the Term and Landlord reasonably
estimates that it will take more than 6 months to repair such damage, or if
insurance proceeds are not available for such restoration. Rent shall be abated
from the date all required Hazardous Material Clearances are obtained until the
Premises are repaired and restored, in the proportion which the area of the
Premises, if any, which is not usable by Tenant bears to the total area of the
Premises, unless Landlord provides Tenant with other space during the period of
repair that is suitable for the temporary conduct of Tenant's business. Such
abatement shall be the sole remedy of Tenant, and except as provided herein,
Tenant waives any right to terminate the Lease by reason of damage or casualty
loss.
The provisions of this Lease, including this Section 18, constitute an
express agreement between Landlord and Tenant with respect to any and all damage
to, or destruction of, all or any part of the Premises, or any other portion of
the Project, and any statute or regulation which is now or may hereafter be in
effect shall have no application to this Lease or any damage or destruction to
all or any part of the Premises or any other portion of the Project, the parties
hereto expressly agreeing that this Section 18 sets forth their entire
understanding and agreement with respect to such matters.
19. CONDEMNATION. If the whole or substantially the whole of the
Premises or the Project is taken for any public or quasi-public use under
governmental law, ordinance, or regulation, or by right of eminent domain, or by
private purchase in lieu thereof (a "TAKING" OR "TAKEN"), and the Taking would
in Landlord's reasonable judgment either prevent or materially interfere with
Tenant's use of the Premises or materially interfere with or impair Landlord's
ownership or operation of the Project, then upon 30 days advance written notice
by Landlord this Lease shall terminate and Rent shall be apportioned as of said
date. If part of the Premises shall be Taken, and this Lease is not terminated
as provided above, Landlord shall promptly restore the Premises and the Project
as nearly as is commercially reasonable under the circumstances to their
condition prior to such
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 15
Office/Laboratory
partial Taking and the rentable square footage of the Building, the rentable
square footage of the Premises, Tenant's Share of Operating Expenses and the
Rent payable hereunder during the unexpired Term shall be reduced to such extent
as may be fair and reasonable under the circumstances. Upon any such Taking,
Landlord shall be entitled to receive the entire price or award from any such
Taking without any payment to Tenant, and Tenant hereby assigns to Landlord
Tenant's interest, if any, in such award. Tenant shall have the right, to the
extent that same shall not diminish Landlord's award, to make a separate claim
against the condemning authority (but not Landlord) for such compensation as may
be separately awarded or recoverable by Tenant for moving expenses and damage to
Tenant's trade fixtures, if a separate award for such items is made to Tenant.
Tenant hereby waives any and all rights it might otherwise have pursuant to any
provision of state law to terminate this Lease upon a partial Taking of the
Premises or the Project.
20. EVENTS OF DEFAULT. Each of the following events shall be a default
("DEFAULT") by Tenant under this Lease:
(a) PAYMENT DEFAULTS. Tenant shall fail to pay any installment of Rent
or any other payment hereunder when due; provided, however, that Landlord will
give Tenant notice and an opportunity to cure any failure to pay Rent within 3
days of any such notice not more than twice in any 12 month period and Tenant
agrees that such notice shall be in lieu of and not in addition to, or shall be
deemed to be, any notice required by law.
(b) INSURANCE. Any insurance required to be maintained by Tenant
pursuant to this Lease shall be canceled or terminated or shall expire or shall
be reduced or materially changed, or Landlord shall receive a notice of
nonrenewal of any such insurance and Tenant shall fail to obtain replacement
insurance at least 20 days before the expiration of the current coverage.
(c) ABANDONMENT. Tenant shall abandon the Premises.
(d) IMPROPER TRANSFER. Tenant shall assign, sublease or otherwise
transfer or attempt to transfer all or any portion of Tenant's interest in this
Lease or the Premises except as expressly permitted herein, or Tenant's interest
in this Lease shall be attached, executed upon, or otherwise judicially seized
and such action is not released within 90 days of the action.
(e) LIENS. Tenant shall fail to discharge or otherwise obtain the
release of any lien placed upon the Premises in violation of this Lease within
15 days after Tenant receives notice that such lien is filed against the
Premises.
(f) INSOLVENCY EVENTS. Tenant or any guarantor or surety of Tenant's
obligations hereunder shall: (A) make a general assignment for the benefit of
creditors; (B) commence any case, proceeding or other action seeking to have an
order for relief entered on its behalf as a debtor or to adjudicate it a
bankrupt or insolvent, or seeking reorganization, arrangement, adjustment,
liquidation, dissolution or composition of it or its debts or seeking
appointment of a receiver, trustee, custodian or other similar official for it
or for all or of any substantial part of its property (collectively a
"PROCEEDING FOR RELIEF"); (C) become the subject of any Proceeding for Relief
which is not dismissed within 90 days of its filing or entry; or (D) die or
suffer a legal disability (if Tenant, guarantor, or surety is an individual) or
be dissolved or otherwise fail to maintain its legal existence (if Tenant,
guarantor or surety is a corporation, partnership or other entity).
(g) ESTOPPEL CERTIFICATE OR SUBORDINATION AGREEMENT. Tenant fails to
execute any document required from Tenant under Sections 23 or 27 within 5 days
after a second notice requesting such document.
(h) OTHER DEFAULTS. Tenant shall fail to comply with any provision of
this Lease other
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 16
Office/Laboratory
than those specifically referred to in this Section 20, and, except as otherwise
expressly provided herein, such failure shall continue for a period of 30 days
after written notice thereof from Landlord to Tenant.
Any notice given under Section 20(h) hereof shall: (i) specify the
alleged default, (ii) demand that Tenant cure such default, (iii) be in lieu of,
and not in addition to, or shall be deemed to be, any notice required under any
provision of applicable law, and (iv) not be deemed a forfeiture or a
termination of this Lease unless Landlord elects otherwise in such notice;
provided that if the nature of Tenant's default pursuant to Section 20(h) is
such that it cannot be cured by the payment of money and reasonably requires
more than 30 days to cure, then Tenant shall not be deemed to be in default if
Tenant commences such cure within said 30 day period and thereafter diligently
prosecutes the same to completion; provided, however, that such cure shall be
completed no later than 180 days from the date of Landlord's notice.
21. LANDLORD'S REMEDIES.
(a) PAYMENT BY LANDLORD; INTEREST. Upon a Default by Tenant hereunder,
Landlord may, without waiving or releasing any obligation of Tenant hereunder,
make such payment or perform such act. All sums so paid or incurred by Landlord,
together with interest thereon, from the date such sums were paid or incurred,
at the annual rate equal to 12% per annum or the highest rate permitted by law
(the "DEFAULT RATE"), whichever is less, shall be payable to Landlord on demand
as Additional Rent. Nothing herein shall be construed to create or impose a duty
on Landlord to mitigate any damages resulting from Tenant's Default hereunder.
(b) LATE PAYMENT RENT. Late payment by Tenant to Landlord of Rent and
other sums due will cause Landlord to incur costs not contemplated by this
Lease, the exact amount of which will be extremely difficult and impracticable
to ascertain. Such costs include, but are not limited to, processing and
accounting charges and late charges which may be imposed on Landlord under any
Mortgage covering the Premises. Therefore, if any installment of Rent due from
Tenant is not received by Landlord within 5 days after the date such payment is
due, Tenant shall pay to Landlord an additional sum equal to 6% of the overdue
Rent as a late charge. The parties agree that this late charge represents a fair
and reasonable estimate of the costs Landlord will incur by reason of late
payment by Tenant. In addition to the late charge, Rent not paid when due shall
bear interest at the Default Rate from the 5th day after the date due until
paid.
(c) REMEDIES. Upon the occurrence of a Default, Landlord, at its option,
without further notice or demand to Tenant, shall have in addition to all other
rights and remedies provided in this Lease, at law or in equity, the option to
pursue any one or more of the following remedies, each and all of which shall be
cumulative and nonexclusive, without any notice or demand whatsoever.
(i) Terminate this Lease, or at Landlord's option, Tenant's right
to possession only, in which event Tenant shall immediately surrender
the Premises to Landlord, and if Tenant fails to do so, Landlord may,
without prejudice to any other remedy which it may have for possession
or arrearages in rent, enter upon and take possession of the Premises
and expel or remove Tenant and any other person who may be occupying the
Premises or any part thereof, without being liable for prosecution or
any claim or damages therefor;
(ii) Upon any termination of this Lease, whether pursuant to the
foregoing Section 21(c)(i) or otherwise, Landlord may recover from
Tenant the following:
(A) The worth at the time of award of any unpaid rent
which has been earned at the time of such termination; plus
(B) The worth at the time of award of the amount by which
the unpaid
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 17
Office/Laboratory
rent which would have been earned after termination until the
time of award exceeds the amount of such rental loss that Tenant
proves could have been reasonably avoided; plus
(C) The worth at the time of award of the amount by which
the unpaid rent for the balance of the Term after the time of
award exceeds the amount of such rental loss that Tenant proves
could have been reasonably avoided; plus
(D) Any other amount necessary to compensate Landlord for
all the detriment proximately caused by Tenant's failure to
perform its obligations under this Lease or which in the ordinary
course of things would be likely to result therefrom,
specifically including, but not limited to, brokerage commissions
and advertising expenses incurred, reasonable expenses of
remodeling the Premises or any portion thereof for a new tenant,
whether for the same or a different use, and any reasonable
special concessions made to obtain a new tenant; and
(E) At Landlord's election, such other amounts in addition
to or in lieu of the foregoing as may be permitted from time to
time by applicable law.
The term "RENT" as used in this Section 21 shall be deemed to be and to mean
all sums of every nature required to be paid by Tenant pursuant to the terms of
this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii) (A)
and B, above, the "WORTH AT THE TIME OF AWARD" shall be computed by allowing
interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the "WORTH
AT THE TIME OF AWARD" shall be computed by discounting such amount at the
discount rate of the Federal Reserve Bank of San Francisco at the time of award
plus 1 %.
(iii) Landlord may continue this Lease in effect after Tenant's
Default and recover rent as it becomes due (Landlord and Tenant hereby
agreeing that Tenant has the right to sublet or assign hereunder,
subject only to reasonable limitations). Accordingly, if Landlord does
not elect to terminate this Lease following a Default by Tenant,
Landlord may, from time to time, without terminating this Lease, enforce
all of its rights and remedies hereunder, including the right to recover
all Rent as it becomes due.
(iv) Whether or not Landlord elects to terminate this Lease
following a Default by Tenant, Landlord shall have the right to
terminate any and all subleases, licenses, concessions or other
consensual arrangements for possession entered into by Tenant and
affecting the Premises or may, in Landlord's sole discretion, succeed to
Tenant's interest in such subleases, licenses, concessions or
arrangements. Upon Landlord's election to succeed to Tenant's interest
in any such subleases, licenses, concessions or arrangements, Tenant
shall, as of the date of notice by Landlord of such election, have no
further right to or interest in the rent or other consideration
receivable thereunder.
(v) Independent of the exercise of any other remedy of Landlord
hereunder or under applicable law, Landlord may conduct an environmental
test of the Premises as generally described in Section 30(d) hereof, at
Tenant's expense.
(d) EFFECT OF EXERCISE. Exercise by Landlord of any remedies hereunder
or otherwise available shall not be deemed to be an acceptance of surrender of
the Premises and/or a termination of this Lease by Landlord, it being understood
that such surrender and/or termination can be effected only by the express
written agreement of Landlord and Tenant. Any law, usage, or custom to the
contrary notwithstanding, Landlord shall have the right at all times to enforce
the provisions of this Lease in strict accordance with the terms hereof; and the
failure of Landlord at any time to enforce its rights under this Lease strictly
in accordance with same shall not be
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 18
Office/Laboratory
construed as having created a custom in any way or manner contrary to the
specific terms, provisions, and covenants of this Lease or as having modified
the same and shall not be deemed a waiver of Landlord's right to enforce one or
more of its rights in connection with any subsequent default. A receipt by
Landlord of Rent or other payment with knowledge of the breach of any covenant
hereof shall not be deemed a waiver of such breach, and no waiver by Landlord of
any provision of this Lease shall be deemed to have been made unless expressed
in writing and signed by Landlord. To the greatest extent permitted by law,
Tenant waives the service of notice of Landlord's intention to re-enter, re-take
or otherwise obtain possession of the Premises as provided in any statute, or
to institute legal proceedings to that end, and also waives all right of
redemption in case Tenant shall be dispossessed by a judgment or by warrant of
any court or judge. Any reletting of the Premises or any portion thereof shall
be on such terms and conditions as Landlord in its sole discretion may
determine. Landlord shall not be liable for, nor shall Tenant's obligations
hereunder be diminished because of, Landlord's failure to relet the Premises or
collect rent due in respect of such reletting or otherwise to mitigate any
damages arising by reason of Tenant's Default.
22. ASSIGNMENT AND SUBLETTING.
(a) GENERAL PROHIBITION. Without Landlord's prior written consent
subject to and on the conditions described in this Section 22, Tenant shall not,
directly or indirectly, voluntarily or by operation of law, assign this Lease or
sublease the Premises or any part thereof or mortgage, pledge, or hypothecate
its leasehold interest or grant any concession or license within the Premises,
and any attempt to do any of the foregoing shall be void and of no effect. If
Tenant is a corporation, partnership or limited liability company, the shares or
other ownership interests thereof which are not actively traded upon a stock
exchange or in the over-the-counter market, a transfer or series of transfers
whereby 45% or more of the issued and outstanding shares or other ownership
interests of such corporation are, or voting control is, transferred (but
excepting transfers upon deaths of individual owners) from a person or persons
or entity or entities which were owners thereof at time of execution of this
Lease to persons or entities who were not owners of shares or other ownership
interests of the corporation, partnership or limited liability company at time
of execution of this Lease, shall be deemed an assignment of this Lease
requiring the consent of Landlord as provided in this Section 22.
Notwithstanding the foregoing, any public offering of shares or other ownership
interest in Tenant shall not be deemed an assignment.
(b) PERMITTED TRANSFERS. If Tenant desires to assign, sublease,
hypothecate or otherwise transfer this Lease or sublet the Premises other than
pursuant to a Permitted Assignment (as defined below), then at least 15 business
days, but not more than 45 business days, before the date Tenant desires the
assignment or sublease to be effective (the "ASSIGNMENT DATE"), Tenant shall
give Landlord a notice (the "ASSIGNMENT NOTICE") containing such information
about the proposed assignee or sublessee, including the proposed use of the
Premises and any Hazardous Materials proposed to be used, stored handled,
treated, generated in or released or disposed of from the Premises, the
Assignment Date, any relationship between Tenant and the proposed assignee or
sublessee, and all material terms and conditions of the proposed assignment or
sublease, including a copy of any proposed assignment or sublease in its final
form, and such other information as Landlord may deem reasonably necessary or
appropriate to its consideration whether to grant its consent. Landlord shall,
by giving written notice to Tenant within 15 business days after receipt of the
Assignment Notice grant or refuse such consent, in its sole discretion with
respect to a proposed assignment, hypothecation or other transfer or subletting
of more than (together with all other then effective subleases) 50% of the
Premises (a "MAJOR SUBLETTING"), or grant or refuse such consent, in its
reasonable discretion with respect to a proposed subletting other than a Major
Subletting (provided that Landlord shall further have the right to review and
approve or disapprove the proposed form of sublease prior to the effective date
of any such subletting). Notwithstanding the foregoing, (a) following a
Reorganization Assignment (as defined below) or (b) if neither the original
Landlord nor a person affiliated with the original Landlord is the
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc.
Office Laboratory - Page 19
Landlord under the Lease, then in either case Landlord shall grant or refuse its
consent to the subletting of all or any portion of the Premises in its
reasonable discretion.
Upon receiving any Assignment Notice for any proposed assignment, Major
Subletting or other subletting which is for a period of more than 50% of the
remaining balance of the Term as of the date such proposed subletting is to
commence, Landlord may terminate this Lease with respect to the space described
in the Assignment Notice as of the Assignment Date (an "ASSIGNMENT
TERMINATION"). If Landlord elects an Assignment Termination, Tenant shall have
the right to withdraw such Assignment Notice by written notice to Landlord of
such election within 5 days after Landlord's notice electing to exercise the
Assignment Termination. If Tenant withdraws such Assignment Notice, this Lease
shall continue in full force and effect. If Tenant does not withdraw such
Assignment Notice, this Lease, and the term and estate herein granted, shall
terminate as of the Assignment Date with respect to the space described in such
Assignment Notice. No failure of Landlord to exercise any such option to
terminate this Lease shall be deemed to be Landlord's consent to the proposed
assignment, sublease or other transfer. Tenant shall reimburse Landlord for all
of Landlord's reasonable out-of-pocket expenses in connection with its
consideration of any Assignment Notice.
Notwithstanding the foregoing, Landlord's consent to an assignment of
this Lease or a subletting of any portion of the Premises to any entity
controlling, controlled by or under common control with Tenant shall not be
required, provided that Landlord shall have the right to approve the form of any
such sublease or assignment, which approval shall not be unreasonably withheld.
In addition, Tenant shall have the right to assign this Lease, upon 30 days
prior written notice to Landlord but without obtaining Landlord's prior written
consent, to a corporation or other entity which is a successor-in-interest to
Tenant, by way of merger, consolidation or corporate reorganization, or by the
purchase of all or substantially all of the assets or the ownership interests of
Tenant provided that (i) such merger or consolidation, or such acquisition or
assumption, as the case may be, is not in Landlord's reasonable opinion
principally for the purpose of transferring the Lease, and (ii) the net worth
(as determined in accordance with generally accepted accounting principles
("GAAP")) of the assignee is not less than the net worth (as determined in
accordance with GAAP) of Tenant as of the date of Tenant's most current
quarterly or annual financial statements, and (iii) such assignee shall agree in
writing to assume all of the terms, covenants and conditions of this Lease
arising after the effective date of the assignment (such assignment is herein
referred to as a "REORGANIZATION ASSIGNMENT"). Each assignment or subletting
described in the two immediately preceding sentences is referred to herein as a
"PERMITTED ASSIGNMENT."
(c) ADDITIONAL CONDITIONS. As a condition to any such assignment or
subletting, whether or not Landlord's consent is required, Landlord may require:
(i) that any assignee or subtenant agree, in writing at the time
of such assignment or subletting, that if Landlord gives such party
notice that Tenant is in Default under this Lease, such party shall
thereafter make all payments otherwise due Tenant directly to Landlord,
which payments will be received by Landlord without any liability except
to credit such payment against those due under the Lease, and any such
third party shall agree to attorn to Landlord or its successors and
assigns should this Lease be terminated for any reason; provided,
however, in no event shall Landlord or its successors or assigns be
obligated to accept such attornment; and
(ii) A list of Hazardous Materials, certified by the proposed
assignee or sublessee to be true and correct, which the proposed
assignee or sublessee intends to use, store, handle, treat, generate in
or release or dispose of from the Premises, together with copies of all
documents relating to such use, storage, handling, treatment,
generation, release or disposal of Hazardous Materials by the proposed
assignee or subtenant in the Premises or on the Project, prior to the
proposed assignment or subletting, including,
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc.
Office Laboratory - Page 20
without limitation: permits; approvals; reports and correspondence;
storage and management plans; plans relating to the installation of any
storage tanks to be installed in or under the Project (provided, said
installation of tanks shall only be permitted after Landlord has given
its written consent to do so, which consent may be withheld in
Landlord's sole and absolute discretion); and all closure plans or any
other documents required by any and all federal, state and local
Governmental Authorities for any storage tanks installed in, on or under
the Project for the closure of any such tanks. Neither Tenant nor any
such proposed assignee or subtenant is required, however, to provide
Landlord with any portions) of the such documents containing information
of a proprietary nature which, in and of themselves, do not contain a
reference to any Hazardous Materials or hazardous activities.
(d) NO RELEASE OF TENANT, SHARING OF EXCESS RENTS. Notwithstanding any
assignment or subletting, Tenant and any guarantor or surety of Tenant's
obligations under this Lease shall at all times remain fully and primarily
responsible and liable for the payment of Rent and for compliance with all of
Tenant's other obligations under this Lease. If the Rent due and payable by a
sublessee or assignee (or a combination of the rental payable under such
sublease or assignment plus any bonus or other consideration therefor, whether
or not expressly so characterized) exceeds the rental payable under this Lease,
(excluding however, any Rent payable under this Section together with actual and
reasonable brokerage fees, legal costs and any design or construction fees
directly related to and required pursuant to the terms of any such sublease),
then Tenant shall be bound and obligated to pay Landlord as Additional Rent
hereunder 50% of such excess rental and other excess consideration within 10
days following receipt thereof by Tenant. If Tenant shall sublet the Premises or
any part thereof, Tenant hereby immediately and irrevocably assigns to Landlord,
as security for Tenant's obligations under this Lease, all rent from any such
subletting, and Landlord as assignee for Tenant, or a receiver for Tenant
appointed on Landlord's application, may collect such rent and apply it toward
Tenant's obligations under this Lease; except that, until the occurrence of a
Default, Tenant shall have the right to collect such rent.
(e) NO WAIVER. The consent by Landlord to an assignment or subletting
shall not relieve Tenant or any assignees of this Lease or any sublessees of the
Premises from obtaining the consent of Landlord to any further assignment or
subletting nor shall it release Tenant or any assignee or sublessee of Tenant
from full and primary liability under the Lease. The acceptance of Rent
hereunder, or the acceptance of performance of any other term, covenant, or
condition thereof, from any other person or entity shall not be deemed to be a
waiver of any of the provisions of this Lease or a consent to any subletting,
assignment or other transfer of the Premises.
(f) PRIOR CONDUCT OF PROPOSED TRANSFEREE. Notwithstanding any other
provision of this Section 22, if (i) the proposed assignee or sublessee of
Tenant has been required by any prior landlord, lender or Governmental Authority
to take remedial action in connection with Hazardous Materials contaminating a
property, where the contamination resulted from such party's action or use of
the property in question, (ii) the proposed assignee or sublessee is subject to
an enforcement order issued by any Governmental Authority in connection with the
use, storage, handling, treatment, generation, release or disposal of Hazardous
Materials (including, without limitation, any order related to the failure to
make a required reporting to any Governmental Authority), or (iii) because of
the existence of a pre-existing environmental condition in the vicinity of or
underlying the Project, the risk that Landlord would be targeted as a
responsible party in connection with the remediation of such pre-existing
environmental condition would be materially increased or exacerbated by the
proposed use of Hazardous Materials by such proposed assignee or sublessee,
Landlord shall have the absolute right to refuse to consent to any assignment or
subletting to any such party.
23. ESTOPPEL CERTIFICATE. Tenant shall, within 10 business days of
written notice from Landlord, execute, acknowledge and deliver a statement in
writing substantially in the form attached
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc.
Office Laboratory - Page 21
to this Lease as EXHIBIT G with the blanks filled in, or on any other form
reasonably requested by a proposed lender or purchaser, (i) certifying that this
Lease is unmodified and in full force and effect (or, if modified, stating the
nature of such modification and certifying that this Lease as so modified is in
full force and effect) and the dates to which the rental and other charges are
paid in advance, if any, (ii) acknowledging that Tenant has not given Landlord
notice of any uncured defaults on the part of Landlord hereunder and that to the
best of Tenant's knowledge there are no events or circumstances which, with the
passage of time or the giving of notice, would give rise to a default on the
part of Landlord hereunder, or specifying such defaults if any are claimed, and
(iii) setting forth such further information with respect to the status of this
Lease or the Premises as may be reasonably requested thereon. Any such statement
may be relied upon by any prospective purchaser or encumbrancer of all or any
portion of the real property of which the Premises are a part. Tenant's failure
to deliver such statement shall be conclusive upon Tenant that the Lease is in
full force and effect and without modification except as may be represented by
Landlord in any certificate prepared by Landlord and delivered to Tenant for
execution.
24. QUIET ENJOYMENT. So long as Tenant shall perform all of the
covenants and agreements herein required to be performed by Tenant, Tenant
shall, subject to the terms of this Lease, at all times during the Term, have
peaceful and quiet enjoyment of the Premises against any person claiming by,
through or under Landlord.
25. PRORATIONS. All prorations required or permitted to be made
hereunder shall be made on the basis of a 360 day year and 30 day months.
26. RULES AND REGULATIONS. Tenant shall, at all times during the Term
and any extension thereof, comply with all reasonable rules and regulations at
any time or from time to time established by Landlord covering use of the
Premises and the Project of which Tenant receives notice. The current rules and
regulations are attached hereto as EXHIBIT E. If there is any conflict between
said rules and regulations and other provisions of this Lease, the terms and
provisions of this Lease shall control. Landlord shall not have any liability or
obligation for the breach of any rules or regulations by other tenants in the
Project and shall not enforce such rules and regulations in a discriminatory
manner.
27. SUBORDINATION. This Lease and Tenant's interest and rights hereunder
are and shall be subject and subordinate at all times to the lien of any
Mortgage now existing or hereafter created on or against the Project or the
Premises, and all amendments, restatements, renewals, modifications,
consolidations, refinancing, assignments and extensions thereof, without the
necessity of any further instrument or act on the part of Tenant; provided,
however that so long as there is no Default hereunder, Tenant's right to
possession of the Premises shall not be disturbed by the Holder of any such
Mortgage. Tenant agrees, at the election of the Holder of any such Mortgage, to
attorn to any such Holder. Tenant agrees upon demand to execute, acknowledge and
deliver a Subordination, Non-disturbance and Attornment Agreement in
substantially the form attached hereto as EXHIBIT H, or such other instruments,
confirming such subordination, and such instruments of attornment as shall be
requested by any such Holder, provided any such instruments contain appropriate
non-disturbance provisions assuring Tenant's quiet enjoyment of the Premises as
set forth in Section 24 hereof. Notwithstanding the foregoing, any such Holder
may at any time subordinate its Mortgage to this Lease, without Tenant's
consent, by notice in writing to Tenant, and thereupon this Lease shall be
deemed prior to such Mortgage without regard to their respective dates of
execution, delivery or recording and in that event such Holder shall have the
same rights with respect to this Lease as though this Lease had been executed
prior to the execution, delivery and recording of such Mortgage and had been
assigned to such Holder. The term "MORTGAGE" whenever used in this Lease shall
be deemed to include deeds of trust, security assignments and any other
encumbrances, and any reference to the "HOLDER" of a Mortgage shall be deemed to
include the beneficiary under a deed of trust.
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 22
Office/Laboratory
28. SURRENDER. Upon the expiration of the Term or earlier termination of
Tenant's right of possession, Tenant shall surrender the Premises to Landlord in
the same condition as received, subject to any Alterations or Installations
permitted by Landlord to remain in the Premises, free of Hazardous Materials
brought upon, kept, used, stored, handled, treated, generated in, or released or
disposed of from, the Premises by any person other than a Landlord Party
(collectively, "TENANT HAZMAT OPERATIONS") and released of all Hazardous
Materials Clearances, broom clean, ordinary wear and tear and casualty loss and
condemnation covered by Sections 18 and 19 excepted. At least 3 months prior to
the surrender of the Premises, Tenant shall deliver to Landlord a narrative
description of the actions proposed (or required by any Governmental Authority)
to be taken by Tenant in order to surrender the Premises (including any
Installations permitted by Landlord to remain in the Premises) at the expiration
or earlier termination of the Term, free from any residual impact from the
Tenant HazMat Operations and otherwise released for unrestricted use and
occupancy (the "SURRENDER PLAN"). Such Surrender Plan shall be accompanied by a
current listing of (i) all Hazardous Materials licenses and permits held by or
on behalf of any Tenant Party with respect to the Premises, and (ii) all
Hazardous Materials used, stored, handled, treated, generated, released or
disposed of from the Premises, and shall be subject to the review and approval
of Landlord's environmental consultant. In connection with the review and
approval of the Surrender Plan, upon the request of Landlord, Tenant shall
deliver to Landlord or its consultant such additional non-proprietary
information concerning Tenant HazMat Operations as Landlord shall request. On or
before such surrender, Tenant shall deliver to Landlord evidence that the
approved Surrender Plan shall have been satisfactorily completed and Landlord
shall have the right, subject to reimbursement at Tenant's expense as set forth
below, to cause Landlord's environmental consultant to inspect the Premises and
perform such additional procedures as may be deemed reasonably necessary to
confirm that the Premises are, as of the effective date of such surrender or
early termination of the Lease, free from any residual impact from Tenant HazMat
Operations. Tenant shall reimburse Landlord, as Additional Rent, for the actual
out-of pocket expense incurred by Landlord for Landlord's environmental
consultant to review and approve the Surrender Plan and to visit the Premises
and verify satisfactory completion of the same, which cost shall not exceed
$5,000. Landlord shall have the unrestricted right to deliver such Surrender
Plan and any report by Landlord's environmental consultant with respect to the
surrender of the Premises to third parties.
If Tenant shall fail to prepare or submit a Surrender Plan approved by
Landlord, or if Tenant shall fail to complete the approved Surrender Plan, or if
such Surrender Plan, whether or not approved by Landlord, shall fail to
adequately address any residual effect of Tenant HazMat Operations in, on or
about the Premises, Landlord shall have the right to take such actions as
Landlord may deem reasonable or appropriate to assure that the Premises and the
Project are surrendered free from any residual impact from Tenant HazMat
Operations, the cost of which actions shall be reimbursed by Tenant as
Additional Rent, without regard to the limitation set forth in the first
paragraph of this Section 28.
Tenant shall immediately return to Landlord all keys and/or access cards
to parking, the Project, restrooms or all or any portion of the Premises
furnished to or otherwise procured by Tenant. If any such access card or key is
lost, Tenant shall pay to Landlord, at Landlord's election, either the cost of
replacing such lost access card or key or the cost of reprogramming the access
security system in which such access card was used or changing the lock or locks
opened by such lost key. Any Tenant's Property, Alterations and property not so
removed by Tenant as permitted or required herein shall be deemed abandoned and
may be stored, removed, and disposed of by Landlord at Tenant's expense, and
Tenant waives all claims against Landlord for any damages resulting from
Landlord's retention and/or disposition of such property. All obligations of
Tenant hereunder not fully performed as of the termination of the Term,
including the obligations of Tenant under Section 30 hereof, shall survive the
expiration or earlier termination of the Term, including, without limitation,
indemnity obligations, payment obligations with respect to Rent and obligations
concerning the condition and repair of the Premises.
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 23
Office/Laboratory
29. WAIVER OF JURY TRIAL. TENANT AND LANDLORD WAIVE ANY RIGHT TO TRIAL
BY JURY OR TO HAVE A JURY PARTICIPATE IN RESOLVING ANY DISPUTE, WHETHER SOUNDING
IN CONTRACT, TORT, OR OTHERWISE, BETWEEN LANDLORD AND TENANT ARISING OUT OF THIS
LEASE OR ANY OTHER INSTRUMENT, DOCUMENT, OR AGREEMENT EXECUTED OR DELIVERED IN
CONNECTION HEREWITH OR THE TRANSACTIONS RELATED HERETO.
30. ENVIRONMENTAL REQUIREMENTS.
(a) PROHIBITION/COMPLIANCE/INDEMNITY. Tenant shall not cause or permit
any Hazardous Materials (as hereinafter defined) to be brought upon, kept, used,
stored, handled, treated, generated in or about, or released or disposed of
from, the Premises or the Project in violation of applicable Environmental
Requirements (as hereinafter defined) by Tenant or any Tenant Party. If Tenant
breaches the obligation stated in the preceding sentence, or if the presence of
Hazardous Materials in the Premises during the Term or any holding over results
in contamination of the Premises, the Project or any adjacent property or if
contamination of the Premises, the Project or any adjacent property by Hazardous
Materials brought into, kept, used, stored, handled, treated, generated in, or
released or disposed of from, the Premises by anyone other than Landlord and
Landlord's employees, agents and contractors otherwise occurs during the Term or
any holding over, Tenant hereby indemnifies and shall defend and hold Landlord,
its officers, directors, employees, agents and contractors harmless from any and
all actions (including, without limitation, remedial or enforcement actions of
any kind, administrative or judicial proceedings, and orders or judgments
arising out of or resulting therefrom), costs, claims, damages (including,
without limitation, punitive damages and damages based upon diminution in value
of the Premises or the Project, or the loss of, or restriction on, use of the
Premises or any portion of the Project), expenses (including, without
limitation, attorneys', consultants' and experts' fees, court costs and amounts
paid in settlement of any claims or actions), fines, forfeitures or other civil,
administrative or criminal penalties, injunctive or other relief (whether or not
based upon personal injury, property damage, or contamination of, or adverse
effects upon, the environment, water tables or natural resources), liabilities
or losses (collectively, "ENVIRONMENTAL CLAIMS") which arise during or after the
Term as a result of such contamination. This indemnification of Landlord by
Tenant includes, without limitation, costs incurred in connection with any
investigation of site conditions or any cleanup, treatment, remedial, removal,
or restoration work required by any federal, state or local Governmental
Authority because of Hazardous Materials for which Tenant is liable or otherwise
responsible under the first or second sentences of this Section 30(a) present in
the air, soil or ground water above, on, or under the Premises. Without limiting
the foregoing, if the presence of any Hazardous Materials on the Premises, the
Project or any adjacent property caused or permitted by Tenant or any Tenant
Party results in any contamination of the Premises, the Project or any adjacent
property, Tenant shall promptly take all actions at its sole expense and in
accordance with applicable Environmental Requirements as are necessary to return
the Premises, the Project or any adjacent property to the condition existing
prior to the time of such contamination, provided that Landlord's approval of
such action shall first be obtained, which approval shall not unreasonably be
withheld so long as such actions would not potentially have any material adverse
long-term or short-term effect on the Premises or the Project.
(b) BUSINESS. Landlord acknowledges that it is not the intent of this
Section 30 to prohibit Tenant from using the Premises for the Permitted Use.
Tenant may operate its business according to prudent industry practices so long
as the use or presence of Hazardous Materials is strictly and properly managed
according to all then applicable Environmental Requirements. As a material
inducement to Landlord to allow Tenant to use Hazardous Materials in connection
with its business, Tenant agrees to deliver to Landlord prior to the
Commencement Date a list identifying each type of Hazardous Materials to be
brought upon, kept, used, stored, handled, treated, generated on, or released or
disposed of from, the Premises and setting forth any and all governmental
approvals or permits required in connection with the presence, use, storage,
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 24
Office/Laboratory
handling, treatment, generation, release or disposal of such Hazardous Materials
on or from the Premises ("HAZARDOUS MATERIALS LIST"). Tenant shall deliver to
Landlord an updated Hazardous Materials List at least once a year and shall also
deliver an updated list before any new Hazardous Material is brought onto, kept,
used, stored, handled, treated, generated on, or released or disposed of from,
the Premises. Tenant shall deliver to Landlord true and correct copies of the
following documents (the "HAZ MAT DOCUMENTS") relating to the use, storage,
handling, treatment, generation, release or disposal of Hazardous Materials
prior to the Commencement Date, or if unavailable at that time, concurrent with
the receipt from or submission to a Governmental Authority: permits; approvals;
reports and correspondence; storage and management plans, notice of violations
of any Legal Requirements; plans relating to the installation of any storage
tanks to be installed in or under the Project (provided, said installation of
tanks shall only be permitted after Landlord has given Tenant its written
consent to do so, which consent may be withheld in Landlord's sole and absolute
discretion); all closure plans or any other documents required by any and all
federal, state and local Governmental Authorities for any storage tanks
installed in, on or under the Project for the closure of any such tanks; and a
Surrender Plan (to the extent surrender in accordance with Section 28 cannot be
accomplished in 3 months). Tenant is not required, however, to provide Landlord
with any portion(s) of the Haz Mat Documents containing information of a
proprietary nature which, in and of themselves, do not contain a reference to
any Hazardous Materials or hazardous activities. It is not the intent of this
Section to provide Landlord with information which could be detrimental to
Tenant's business should such information become possessed by Tenant's
competitors.
(c) TENANT REPRESENTATION AND WARRANTY. Tenant hereby represents and
warrants to Landlord that (i) neither Tenant nor any of its legal predecessors
has been required by any prior landlord, lender or Governmental Authority at any
time to take remedial action in connection with Hazardous Materials
contaminating a property which contamination was permitted by Tenant of such
predecessor or resulted from Tenant's or such predecessor's action or use of the
property in question, and (ii) Tenant is not subject to any enforcement order
issued by any Governmental Authority in connection with the use, storage,
handling, treatment, generation, release or disposal of Hazardous Materials
(including, without limitation, any order related to the failure to make a
required reporting to any Governmental Authority). If Landlord determines that
this representation and warranty was not true as of the date of this lease,
Landlord shall have the right to terminate this Lease in Landlord's sole and
absolute discretion.
(d) TESTING. Landlord shall have the right to conduct annual tests of
the Premises to determine whether any contamination of the Premises or the
Project has occurred as a result of Tenant's use. Tenant shall be required to
pay the cost of such annual test of the Premises; provided, however, that if
Tenant conducts its own tests of the Premises using third party contractors and
test procedures acceptable to Landlord which tests are addressed directly to
Tenant and Landlord from the third party contractors, Landlord shall accept such
tests in lieu of the annual tests to be paid for by Tenant. In addition, at any
time, and from time to time, prior to the expiration or earlier termination of
the Term, Landlord shall have the right to conduct appropriate tests of the
Premises and the Project to determine if contamination has occurred as a result
of Tenant's use of the Premises. In connection with such testing, upon the
request of Landlord, Tenant shall deliver to Landlord or its consultant such
non-proprietary information concerning the use of Hazardous Materials in or
about the Premises by Tenant or any Tenant Party. If contamination has occurred
for which Tenant is liable under this Section 30, Tenant shall pay all costs to
conduct such tests. If no such contamination is found, Landlord shall pay the
costs of such tests (which shall not constitute an Operating Expense). Landlord
shall provide Tenant with a copy of all third party, non-confidential reports
and tests of the Premises made by or on behalf of Landlord during the Term
without representation or warranty and subject to a confidentiality agreement
(which excepts matters required to be reported or disclosed to Governmental
Authority). Tenant shall, at its sole cost and expense, promptly and
satisfactorily remediate any environmental conditions identified by such testing
in accordance with all Environmental Requirements. Landlord's
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 25
Office/Laboratory
receipt of or satisfaction with any environmental assessment in no way waives
any rights which Landlord may have against Tenant.
(e) UNDERGROUND TANKS. If underground or other storage tanks storing
Hazardous Materials located on the Premises or the Project are used by Tenant or
are hereafter placed on the Premises or the Project by Tenant, Tenant shall
install, use, monitor, operate, maintain, upgrade and manage such storage tanks,
maintain appropriate records, obtain and maintain appropriate insurance,
implement reporting procedures, properly close any underground storage tanks,
and take or cause to be taken all other actions necessary or required under
applicable state and federal Legal Requirements, as such now exists or may
hereafter be adopted or amended in connection with the installation, use,
maintenance, management, operation, upgrading and closure of such storage tanks.
(f) TENANT'S OBLIGATIONS. Tenant's obligations under this Section 30
shall survive the expiration or earlier termination of the Lease. During any
period of time after the expiration or earlier termination of this Lease
required by Tenant or Landlord to complete the removal from the Premises of any
Hazardous Materials required to be removed pursuant to Section 30(c) (including,
without limitation, the release and termination of any licenses or permits
restricting the use of the Premises and the completion of the approved Surrender
Plan), Tenant shall continue to pay the full Rent in accordance with this Lease
for any portion of the Premises not relet by Landlord in Landlord's sole
discretion, which Rent shall be prorated daily.
(g) DEFINITIONS. As used herein, the term "ENVIRONMENTAL REQUIREMENTS"
means all applicable present and future statutes, regulations, ordinances,
rules, codes, judgments, orders or other similar enactments of any Governmental
Authority regulating or relating to health, safety, or environmental conditions
on, under, or about the Premises or the Project, or the environment, including
without limitation, the following: the Comprehensive Environmental Response,
Compensation and Liability Act; the Resource Conservation and Recovery Act; and
all state and local counterparts thereto, and any regulations or policies
promulgated or issued thereunder. As used herein, the term "HAZARDOUS MATERIALS"
means and includes any substance, material, waste, pollutant, or contaminant
listed or defined as hazardous or toxic, or regulated by reason of its impact or
potential impact on humans, animals and/or the environment under any
Environmental Requirements, asbestos and petroleum, including crude oil or any
fraction thereof, natural gas liquids, liquefied natural gas, or synthetic gas
usable for fuel (or mixtures of natural gas and such synthetic gas). As defined
in Environmental Requirements, Tenant is and shall be deemed to be the
"OPERATOR" of Tenant's "FACILITY" and the "OWNER" of all Hazardous Materials
brought on the Premises by Tenant or any Tenant Party, and the wastes,
by-products, or residues generated, resulting, or produced therefrom.
31. TENANT'S REMEDIES/LIMITATION OF LIABILITY. Landlord shall not be in
default hereunder unless Landlord fails to perform any of its obligations
hereunder within 30 days after written notice from Tenant specifying such
failure (unless such performance will, due to the nature of the obligation,
require a period of time in excess of 30 days, then after such period of time as
is reasonably necessary). Upon any default by Landlord, Tenant shall give notice
by registered or certified mail to any Holder of a Mortgage covering the
Premises and to any landlord of any lease of property in or on which the
Premises are located and Tenant shall offer such Holder and/or landlord a
reasonable opportunity to cure the default, including time to obtain possession
of the Project by power of sale or a judicial action if such should prove
necessary to effect a cure; provided Landlord shall have furnished to Tenant in
writing the names and addresses of all such persons who are to receive such
notices. All obligations of Landlord hereunder shall be construed as covenants,
not conditions; and, except as may be otherwise expressly provided in this
Lease, Tenant may not terminate this Lease for breach of Landlord's obligations
hereunder. Notwithstanding the foregoing, if any claimed Landlord default
hereunder will immediately, materially and adversely affect Tenant's ability to
conduct its business in the Premises (a "MATERIAL
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 23
Office/Laboratory
LANDLORD DEFAULT"), Tenant shall, as soon as reasonably possible, but in any
event within 2 business days of obtaining knowledge of such claimed Material
Landlord Default, give Landlord written notice of such claim and telephonic
notice to Tenant's principal contact with Landlord. Landlord shall then have 2
business days to commence cure of such claimed Material Landlord Default and
shall diligently prosecute such cure to completion. If such claimed Material
Landlord Default is not a default by Landlord hereunder, or if Tenant failed to
give Landlord the notice required hereunder within 2 business days of learning
of the conditions giving rise to the claimed Material Landlord Default, Landlord
shall be entitled to recover from Tenant, as Additional Rent, any costs incurred
by Landlord in connection with such cure in excess of the costs, if any, that
Landlord would otherwise have been liable to pay hereunder. If Landlord fails to
commence cure of any claimed Material Landlord Default as provided above, Tenant
may commence and prosecute such cure to completion, and shall be entitled to
recover the costs of such cure (but not any consequential or other damages) from
Landlord, to the extent of Landlord's obligation to cure such claimed Material
Landlord Default hereunder, subject to the limitations set forth in the
immediately preceding sentence of this paragraph and the other provisions of
this Lease.
All obligations of Landlord under this Lease will be binding upon
Landlord only during the period of its ownership of the Premises and not
thereafter. The term "LANDLORD" in this Lease shall mean only the owner for the
time being of the Premises. Upon the transfer by such owner of its interest in
the Premises, such owner shall thereupon be released and discharged from all
obligations of Landlord thereafter accruing, but such obligations shall be
binding during the Term upon each new owner for the duration of such owner's
ownership.
32. INSPECTION AND ACCESS. Landlord and its agents, representatives, and
contractors may enter the Premises at any reasonable time to inspect the
Premises and to make such repairs as may be required or permitted pursuant to
this Lease and for any other business purpose; provided, however, that with
respect to Landlord's entry for any other business purpose, Landlord shall use
reasonable efforts consistent with such purpose to minimize interference with
Tenant's operations. Landlord and Landlord's representatives may enter the
Premises during business hours on not less than 48 hours advance written notice
(except in the case of emergencies in which case no such notice shall be
required and such entry may be at any time) for the purpose of effecting any
such repairs, inspecting the Premises, showing the Premises to prospective
purchasers and, during the last year of the Term, to prospective tenants or for
any other business purpose. Landlord may erect a suitable sign on the Premises
stating the Premises are available to let or that the Project is available for
sale; provided, however, any such sign does not interfere with Tenant's use and
enjoyment of the Premises. Landlord may grant easements, make public
dedications, designate Common Areas and create restrictions on or about the
Premises, provided that no such easement, dedication, designation or restriction
materially, adversely affects Tenant's use or occupancy of the Premises for the
Permitted Use. At Landlord's request, Tenant shall execute such instruments as
may be necessary for such easements, dedications or restrictions. Tenant shall
at all times, except in the case of emergencies, have the right to escort
Landlord or its agents, representatives, contractors or guests while the same
are in the Premises, provided such escort does not materially and adversely
affect Landlord's access rights hereunder.
33. SECURITY. Tenant acknowledges and agrees that security devices and
services, if any, while intended to deter crime may not in given instances
prevent theft or other criminal acts and that Landlord is not providing any
security services with respect to the Premises. Tenant agrees that Landlord
shall not be liable to Tenant for, and Tenant waives any claim against Landlord
with respect to, any loss by theft or any other damage suffered or incurred by
Tenant in connection with any unauthorized entry into the Premises or any other
breach of security with respect to the Premises. Tenant shall be solely
responsible for the personal safety of Tenant's officers, employees, agents,
contractors, guests and invitees while any such person is in, on or about the
Premises and/or the Project. Tenant shall at Tenant's cost obtain insurance
coverage to the extent Tenant desires protection against such criminal acts.
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc. - Page 27
Office/Laboratory
34. FORCE MAJEURE. Landlord shall not be held responsible for delays in
the performance of its obligations hereunder when caused by strikes, lockouts,
labor disputes, weather, natural disasters, inability to obtain labor or
materials or reasonable substitutes therefor, governmental restrictions,
governmental regulations, governmental controls, delay in issuance of permits,
enemy or hostile governmental action, civil commotion, fire or other casualty,
and other causes beyond the reasonable control of Landlord ("FORCE MAJEURE").
35. BROKERS, ENTIRE AGREEMENT, AMENDMENT. Landlord and Tenant each
represents and warrants that it has not dealt with any broker, agent or other
person (collectively, "BROKER") in connection with this transaction and that no
Broker brought about this transaction, other than CB Xxxxxxx Xxxxx/Whittier
Partners and Xxxxxxxxx & Xxxx Colliers. Landlord and Tenant each hereby agree to
indemnify and hold the other harmless from and against any claims by any Broker,
other than the brokers, if any named in this Section 35, claiming a commission
or other form of compensation by virtue of having dealt with Tenant or Landlord,
as applicable, with regard to this leasing transaction. This Lease constitutes
the entire agreement of the parties with respect to the subject matter hereof.
This Lease may not be amended except by an instrument in writing signed by both
parties hereto.
36. LIMITATION ON LANDLORD'S LIABILITY. NOTWITHSTANDING ANYTHING SET
FORTH HEREIN OR IN ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT TO THE
CONTRARY: (A) LANDLORD SHALL NOT BE LIABLE TO TENANT OR ANY OTHER PERSON FOR
(AND TENANT AND EACH SUCH OTHER PERSON ASSUME ALL RISK OF) LOSS, DAMAGE OR
INJURY, WHETHER ACTUAL OR CONSEQUENTIAL TO: TENANT'S PERSONAL PROPERTY OF EVERY
KIND AND DESCRIPTION, INCLUDING, WITHOUT LIMITATION TRADE FIXTURES, EQUIPMENT,
INVENTORY, SCIENTIFIC RESEARCH, SCIENTIFIC EXPERIMENTS, LABORATORY ANIMALS,
PRODUCT, SPECIMENS, SAMPLES, AND/OR SCIENTIFIC, BUSINESS, ACCOUNTING AND OTHER
RECORDS OF EVERY KIND AND DESCRIPTION KEPT AT THE PREMISES AND ANY AND ALL
INCOME DERIVED OR DERIVABLE THEREFROM; (B) THERE SHALL BE NO PERSONAL RECOURSE
TO LANDLORD FOR ANY ACT OR OCCURRENCE IN, ON OR ABOUT THE PREMISES OR ARISING IN
ANY WAY UNDER THIS LEASE OR ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT WITH
RESPECT TO THE SUBJECT MATTER HEREOF AND ANY LIABILITY OF LANDLORD HEREUNDER
SHALL BE STRICTLY LIMITED SOLELY TO LANDLORD'S INTEREST IN THE PROJECT OR ANY
PROCEEDS FROM SALE OR CONDEMNATION THEREOF AND ANY INSURANCE PROCEEDS PAYABLE IN
RESPECT OF LANDLORD'S INTEREST IN THE PROJECT OR IN CONNECTION WITH ANY SUCH
LOSS; AND (C) IN NO EVENT SHALL ANY PERSONAL LIABILITY BE ASSERTED AGAINST
LANDLORD IN CONNECTION WITH THIS LEASE NOR SHALL ANY RECOURSE BE HAD TO ANY
OTHER PROPERTY OR ASSETS OF LANDLORD OR ANY OF LANDLORD'S OFFICERS, DIRECTORS,
EMPLOYEES, AGENTS OR CONTRACTORS. UNDER NO CIRCUMSTANCES SHALL LANDLORD OR ANY
OF LANDLORD'S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS BE LIABLE
FOR INJURY TO TENANT'S BUSINESS OR FOR ANY LOSS OF INCOME OR PROFIT THEREFROM.
37. SEVERABILITY. If any clause or provision of this Lease is illegal,
invalid or unenforceable under present or future laws, then and in that event,
it is the intention of the parties hereto that the remainder of this Lease shall
not be affected thereby. It is also the intention of the parties to this Lease
that in lieu of each clause or provision of this Lease that is illegal, invalid
or unenforceable, there be added, as a part of this Lease, a clause or provision
as similar in effect to such illegal, invalid or unenforceable clause or
provision as shall be legal, valid and enforceable.
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory Page 28
500 Arsenal Street/Acusphere, Inc.
38. SIGNS; EXTERIOR APPEARANCE. Tenant shall not, without the prior
written consent of Landlord, which may be granted or withheld in Landlord's sole
discretion: (i) attach any awnings, exterior lights, decorations, balloons,
flags, pennants, banners, painting or other projection to any outside wall of
the Project, (ii) use any curtains, blinds, shades or screens other than
Landlord's standard window coverings, (iii) coat or otherwise sunscreen the
interior or exterior of any windows, (iv) place any bottles, parcels, or other
articles on the window xxxxx, (v) place any equipment, furniture or other items
of personal property on any exterior balcony, or (vi) paint, affix or exhibit on
any part of the Premises or the Project any signs, notices, window or door
lettering, placards, decorations, or advertising media of any type which can be
viewed from the exterior of the Premises. Interior signs on doors and the
directory tablet shall be inscribed, painted or affixed for Tenant by Landlord
at the sole cost and expense of Tenant, and shall be of a size, color and type
acceptable to Landlord. Nothing may be placed on the exterior of corridor walls
or corridor doors other than Landlord's standard lettering. The directory tablet
shall be provided exclusively for the display of the name and location of
tenants.
39. RIGHT TO EXPAND
(a) EXPANSION IN THE PROJECT. Tenant shall have the right, but not the
obligation, to expand the Premises (the "EXPANSION RIGHT") to include any
Available Space in the Project upon the terms and conditions in this Section.
For purposes of this Section 39(a), "AVAILABLE SPACE" shall mean any space in
the Project consisting of at least 5,000 rentable square feet which is not
occupied by a tenant or which is occupied by an existing tenant whose lease is
expiring within 6 months or less and such tenant does not wish to renew (whether
or not such tenant has a right to renew) its occupancy of such space. If a
vacancy of Available Space occurs, Landlord shall deliver to Tenant written
notice (the "EXPANSION NOTICE") of the availability of such portion of the
Available Space, together with the terms and conditions on which Landlord is
prepared to lease to Tenant such Available Space. Tenant shall have 10 business
days following delivery of the Expansion Notice to deliver to Landlord written
notification of Tenant's exercise of the Expansion Right with respect to all of
such Available Space. Provided that no right to expand is exercised by any
tenant with currently existing superior rights, Tenant shall be entitled to
lease all of such Available Space upon the terms and conditions set forth in the
Expansion Notice.
(b) AMENDED LEASE. If: (i) Tenant fails to timely deliver notice
accepting the terms of an Expansion Notice, or (ii) after the expiration of a
period of 30 days from the date Tenant gives notice accepting Landlord's offer
to lease such Available Space, no lease amendment or lease agreement for such
Available Space has been executed, and Landlord has tendered to Tenant an
amendment to this Lease setting forth the terms for the rental of such Available
Space consistent with those set forth in the Expansion Notice and otherwise
consistent with the terms of this Lease and Tenant fails to execute such Lease
amendment within 10 business days following such tender, Tenant shall be deemed
to have waived its right to lease such Available Space; provided, however, that
such right shall continue and shall not be waived with respect to such Available
Space if Landlord is unable to lease such Available Space to a third party on
economic terms that are no less than 90% of the present value of the economic
terms offered by Landlord to Tenant for such Available Space.
(c) EXCEPTIONS. Notwithstanding the above, the Expansion Right shall not
be in effect and may not be exercised by Tenant:
(i) during any period of time that Tenant is in Default under any
provision of the Lease;
(ii) if Tenant has been in Default under any provision of the
Lease 3 or more times, whether or not the Defaults are cured, during the
12 month period prior to the date on which Tenant seeks to exercise the
Expansion Right;
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory Page 29
500 Arsenal Street/Acusphere, Inc.
(iii) after such time as Landlord has offered to Tenant at least
20,000 rentable square feet pursuant to this Section 39 and Tenant has
either accepted such Available Space or has waived its right to lease
such Available Space in accordance with this Section 39; or
(iv) with respect to any Available Space as to which Tenant has
waived it rights pursuant to this Section 39 unless Landlord is unable
to lease such Available Space to a third party on economic terms that
are no less than 90% of the present value of the economic terms offered
by Landlord to Tenant for such Available Space.
(d) TERMINATION. The Expansion Right shall terminate and be of no
further force or effect with respect to any other Available Space at such time
as Landlord shall have provided Expansion Notices to Tenant aggregating at least
20,000 rentable square feet of Available Space. In addition, the Expansion Right
shall terminate and be of no further force or effect even after Tenant's due and
timely exercise of the Expansion Right, if, after such exercise, but prior to
the commencement date of the term for the Available Space, (i) Tenant fails to
timely cure any default by Tenant under the Lease; or (ii) Tenant has Defaulted
3 or more times during the period from the date of the exercise of the Expansion
Right to the date of the commencement of the lease of such Available Space,
whether or not such Defaults are cured.
(e) SUBORDINATE. Tenant's rights in connection with the Expansion Right
are and shall be subject to and subordinate to any expansion or extension rights
currently existing in the Project.
(f) RIGHTS PERSONAL. Expansion Rights are personal to Tenant and are not
assignable without Landlord's consent, which may be granted or withheld in
Landlord's sole discretion separate and apart from any consent by Landlord to an
assignment of Tenant's interest in the Lease.
(g) NO EXTENSIONS. The period of time within which any Expansion Rights
may be exercised shall not be extended or enlarged by reason of Tenant's
inability to exercise the Expansion Rights.
40. RIGHT TO EXTEND TERM. Tenant shall have the right to extend the Term
of the Lease upon the following terms and conditions:
(a) EXTENSION RIGHT. Tenant shall have a one time right (the "EXTENSION
RIGHT") to extend the term of this Lease for five years (the "EXTENSION TERM")
on the same terms and conditions as this Lease (other than Base Rent) by giving
Landlord written notice of its election to exercise each Extension Right at
least nine months prior, and no earlier than twelve months prior, to the
expiration of the Base Term of the Lease.
Upon the commencement of the Extension Term, Base Rent shall be payable
at the Market Rate (as defined below). Base Rent shall thereafter be adjusted on
each annual anniversary of the commencement of the Extension Term by a
percentage as determined by Landlord and agreed to by Tenant at the time the
Market Rate is determined. As used herein, "MARKET RATE" shall mean the then
market rental rate as determined by Landlord and agreed to by Tenant, which
shall in no event be less than the Base Rent payable as of the date immediately
preceding the commencement of the Extension Term increased by the Rent
Adjustment Percentage multiplied by such Base Rent. In addition, Landlord may
impose a market rent for the parking rights provided hereunder.
If, on or before the date which is 120 days prior to the expiration of the Base
Term of this Lease, Tenant has not agreed with Landlord's determination of the
Market Rate and the rent escalations during the Extension Term after negotiating
in good faith, Tenant may by written notice to Landlord not later than 120 days
prior to the expiration of the Base Term of this Lease, elect arbitration as
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory Page 30
500 Arsenal Street/Acusphere, Inc.
described in Section 40(b) below. If Tenant does not elect such arbitration,
Tenant shall be deemed to have waived any right to extend the Term of the Lease.
(b) ARBITRATION.
(i) Within 10 days of Tenant's notice to Landlord of its election
to arbitrate Market Rate and escalations, each party shall deliver to
the other a proposal containing the Market Rate and escalations that the
submitting party believes to be correct ("EXTENSION PROPOSAL"). If
either party fails to timely submit an Extension Proposal, the other
party's submitted proposal shall determine the Base Rent and escalations
for the Extension Term. If both parties submit Extension Proposals, then
Landlord and Tenant shall meet within 7 days after delivery of the last
Extension Proposal and make a good faith attempt to mutually appoint a
single Arbitrator (and defined below) to determine the Market Rate and
escalations. If Landlord and Tenant are unable to agree upon a single
Arbitrator, then each shall, by written notice delivered to the other
within 10 days after the meeting, select an Arbitrator. If either party
fails to timely give notice of its selection for an Arbitrator, the
other party's submitted proposal shall determine the Base Rent for the
Extension Term. The 2 Arbitrators so appointed shall, within 5 business
days after their appointment, appoint a third Arbitrator. If the 2
Arbitrators so selected cannot agree on the selection of the third
Arbitrator within the time above specified, then either party, on behalf
of both parties, may request such appointment of such third Arbitrator
by application to any state court of general jurisdiction in the
jurisdiction in which the Premises are located, upon 10 days prior
written notice to the other party of such intent.
(ii) The decision of the Arbitrator(s) shall be made within 30
days after the appointment of a single Arbitrator or the third
Arbitrator, as applicable. The decision of the single Arbitrator shall
be final and binding upon the parties. The average of the two closest
Arbitrators in a three Arbitrator panel shall be final and binding upon
the parties. Each party shall pay the fees and expenses of the
Arbitrator appointed by or on behalf of such party and the fees and
expenses of the third Arbitrator shall be borne equally by both parties.
If the Market Rate and escalations are not determined by the first day
of the Extension Term, then Tenant shall pay Landlord Base Rent in an
amount equal to the Base Rent in effect immediately prior to the
Extension Term and increased by the Rent Adjustment Percentage until
such determination is made. After the determination of the Market Rate
and escalations, the parties shall make any necessary adjustments to
such payments made by Tenant. Landlord and Tenant shall then execute an
amendment recognizing the Market Rate and escalations for the Extension
Term.
(iii) An "ARBITRATOR" shall be any person appointed by or on
behalf of either party or appointed pursuant to the provisions hereof
and: (i) shall be (A) a member of the American Institute of Real Estate
Appraisers with not less than 10 years of experience in the appraisal of
improved office and high tech industrial real estate in the greater
Boston metropolitan area, or (B) a licensed commercial real estate
broker with not less than 15 years experience representing landlords
and/or tenants in the leasing of high tech or life sciences space in the
greater Boston metropolitan area, (ii) devoting substantially all of
their time to professional appraisal or brokerage work, as applicable,
at the time of appointment and (iii) be in all respects impartial and
disinterested.
(c) RIGHTS PERSONAL. The Extension Right is personal to Tenant and is
not assignable without Landlord's consent, which may be granted or withheld in
Landlord's sole discretion separate and apart from any consent by Landlord to an
assignment of Tenant's interest in the Lease.
(d) EXCEPTIONS. Notwithstanding anything set forth above to the
contrary, the Extension Rights shall not be in effect and Tenant may not
exercise the Extension Rights:
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 31
(i) during any period of time that Tenant is in Default under any
provision of this Lease; or
(ii) if Tenant has been in Default under any provision of this
Lease 3 or more times, whether or not the Defaults are cured, during the
12 month period immediately prior to the date that Tenant intends to
exercise the Extension Right, whether or not the Defaults are cured.
(e) NO EXTENSIONS. The period of time within which the Extension Right
may be exercised shall not be extended or enlarged by reason of Tenant's
inability to exercise the Extension Right.
(f) TERMINATION. The Extension Right shall terminate and be of no
further force or effect even after Tenant's due and timely exercise of the
Extension Right, if, after such exercise, but prior to the commencement date of
the Extension Term, (i) Tenant fails to timely cure any default by Tenant under
this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from
the date of the exercise of the Extension Right to the date of the commencement
of the Extension Term, whether or not such Defaults are cured.
41. MISCELLANEOUS.
(a) NOTICES. All notices or other communications between the parties
shall be in writing and shall be deemed duly given upon delivery or refusal to
accept delivery by the addressee thereof if delivered in person, or upon actual
receipt if delivered by reputable overnight guaranty courier, addressed and sent
to the parties at their addresses set forth above. Landlord and Tenant may from
time to time by written notice to the other designate another address for
receipt of future notices. Landlord shall not be required to provide Tenant's
attorney with routine notices given under or in connection with the Work Letter.
(b) JOINT AND SEVERAL LIABILITY. If and when included within the term
"TENANT," as used in this instrument, there is more than one person or entity,
each shall be jointly and severally liable for the obligations of Tenant.
(c) FINANCIAL INFORMATION. Tenant shall furnish Landlord with true and
complete copies of (i) Tenant's most recent audited annual financial statements
within 45 days of the end of each of Tenant's fiscal years during the Term, (ii)
Tenant's most recent unaudited quarterly financial statements within 45 days of
the end of each of Tenant's first three fiscal quarters of each of Tenant's
fiscal years during the Term, (iii) at Landlord's request from time to time,
updated business plans, including cash flow projections and/or pro forma balance
sheets and income statements, all of which shall be treated by Landlord as
confidential information belonging to Tenant, (iv) corporate brochures and/or
profiles prepared by Tenant for prospective investors, and (v) any other
financial information or summaries that Tenant typically provides to its lenders
or shareholders. Notwithstanding the foregoing, if at the time of such
disclosure Tenant's stock is traded on a national stock exchange, Tenant need
not make such disclosure to the extent that such disclosure would violate the
securities laws of the United States of America.
(d) RECORDATION. This Lease shall not be filed by or on behalf of Tenant
in any public record. Concurrently, herewith, Landlord will execute and
acknowledge and Tenant will execute, acknowledge and deliver to Landlord (i) a
memorandum of lease in the form of EXHIBIT I attached hereto (the "MEMORANDUM")
and (ii) a notice of lease termination in the form of EXHIBIT J (the "NOTICE OF
LEASE TERMINATION"). Landlord shall file the Memorandum with the County recorder
in the County in which the Project is located (the "OFFICIAL RECORDS"), and
Landlord shall retain the Notice of Lease Termination. Upon termination or
earlier expiration of this Lease, Landlord is authorized by Tenant, without any
further action by Tenant, to record the Notice of Lease
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 32
Termination in the Official Records.
(e) INTERPRETATION. The normal rule of construction to the effect that
any ambiguities are to be resolved against the drafting party shall not be
employed in the interpretation of this Lease or any exhibits or amendments
hereto. Words of any gender used in this Lease shall be held and construed to
include any other gender, and words in the singular number shall be held to
include the plural, unless the context otherwise requires. The captions inserted
in this Lease are for convenience only and in no way define, limit or otherwise
describe the scope or intent of this Lease, or any provision hereof, or in any
way affect the interpretation of this Lease.
(f) NOT BINDING UNTIL EXECUTED. The submission by Landlord to Tenant of
this Lease shall have no binding force or effect, shall not constitute an option
for the leasing of the Premises, nor confer any right or impose any obligations
upon either party until execution and delivery of this Lease by both parties.
(g) LIMITATIONS ON INTEREST. It is expressly the intent of Landlord and
Tenant at all times to comply with applicable law governing the maximum rate or
amount of any interest payable on or in connection with this Lease. If
applicable law is ever judicially interpreted so as to render usurious any
interest called for under this Lease, or contracted for, charged, taken,
reserved, or received with respect to this Lease, then it is Landlord's and
Tenant's express intent that all excess amounts theretofore collected by
Landlord be credited on the applicable obligation (or, if the obligation has
been or would thereby be paid in full, refunded to Tenant), and the provisions
of this Lease immediately shall be deemed reformed and the amounts thereafter
collectible hereunder reduced, without the necessity of the execution of any new
document, so as to comply with the applicable law, but so as to permit the
recovery of the fullest amount otherwise called for hereunder.
(h) CHOICE OF LAW. Construction and interpretation of this Lease shall
be governed by the internal laws of the state in which the Premises are located,
excluding any principles of conflicts of laws.
(i) TIME. Time is of the essence as to the performance of Tenant's
obligations under this Lease.
(j) INCORPORATION BY REFERENCE. All exhibits and addenda attached hereto
are hereby incorporated into this Lease and made a part hereof. If there is any
conflict between such exhibits or addenda and the terms of this Lease, such
exhibits or addenda shall control.
(k) ATTORNEYS FEES. If either party shall be in default in the
observance or performance of any provision of this Lease, and an action shall be
brought for the enforcement thereof in which it shall be determined that such
party was in default, the party in default shall pay to the other all fees,
costs and other expenses which may become payable as a result thereof or in
connection therewith, including attorneys' fees and expenses.
(l) LIQUID NITROGEN TANK. Tenant may install an above ground liquid
nitrogen tank in connection with Tenant's use of the Premises (the "LIQUID
NITROGEN TANK") at the location set forth on Schedule I attached hereto (the
"TANK AREA"), subject to the terms and conditions set forth herein. The Liquid
Nitrogen Tank and its installation shall be considered an Alteration (and not a
Notice-Only Alteration) for all purposes under this Lease, and shall be
installed in accordance with all of the terms and conditions of this Lease
concerning or affecting Alterations. The Tank Area shall be completely enclosed
by a fence and gate, approved by Landlord, which gate shall remain locked at all
times. The Tank Area shall constitute a portion of the Premises for all purposes
under the Lease other than the determination of Rent. Tenant shall be solely
responsible, at its cost and expense, for any loss or damage to the Liquid
Nitrogen Tank and for any loss or damage resulting from the presence of the
Liquid Nitrogen Tank at the Project from any cause whatsoever. Tenant
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant Office/Laboratory
500 Arsenal Street/Acusphere, Inc. - Page 33
shall operate and maintain the Liquid Nitrogen Tank in a good, safe operating
condition and in accordance with all Legal Requirements. If, at any time,
Landlord determines, in its sole judgment, that the Liquid Nitrogen Tank has
become an imminent hazard or if an Event of Default has occurred, upon
Landlord's request, Tenant shall remove the Liquid Nitrogen Tank and the gate
and fencing and shall return the Building shell and the Tank Area to their
condition immediately prior to the installation of the Liquid Nitrogen Tank.
Upon the expiration of the Term or the earlier expiration of this Lease, if
requested to do so by Landlord, Tenant shall remove the Liquid Nitrogen Tank and
the gate and fencing and return the Building shell and the Tank Area to their
condition immediately prior to the installation of the Liquid Nitrogen Tank.
(m) RIGHT TO RELOCATE. At any time 5 years or more after the
Commencement Date, Tenant may elect to give Landlord notice that Tenant desires
to lease not less than 70,000 rentable square feet of laboratory and office
space in the Greater Boston area (the "RELOCATION SPACE"). Upon receipt of such
notice, Landlord shall have the option either to give Tenant written notice that
Landlord elects not to respond, or to give Tenant notice within 120 days of
receipt of Tenant's notice describing: (i) the available space(s), if any,
Landlord or any affiliate of Landlord (in either such event, the "RELOCATION
LANDLORD") may have or could construct which could be used for such Relocation
Space, (ii) the time period within which such space(s) could be available for
lease by Tenant, and (iii) the economic and other material business terms of any
proposed lease thereof to Tenant (the "RELOCATION NOTICE"). The decision whether
to give a Relocation Notice and the terms thereof shall be determined by
Landlord in Landlord's sole and absolute discretion. Tenant shall have 60 days
following receipt of any Relocation Notice given by Landlord to deliver to
Landlord written notification of Tenant's acceptance of such Relocation Space
and agreement to lease such Relocation Space upon the business terms set forth
in the Relocation Notice. Upon Tenant's occupancy of such Relocation Space, the
Lease described herein shall terminate.
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc.
Office/Laboratory - Page 34
IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of
the day and year first above written.
TENANT:
ACUSPHERE INC.
By: /s/ Xxxxxx X. Xxxxx
------------------------------------------
Name: Xxxxxx X. Xxxxx
------------------------------------------
Its: President and CEO
------------------------------------------
LANDLORD:
ARE-500 ARSENAL STREET, LLC
By: ALEXANDRIA REAL ESTATE EQUITIES, L.P.
managing member
By: ARE-QRS CORP.
general partner
By: /s/ Xxxxxxx X. Xxxxx
---------------------------------
Name: Xxxxxxx X. Xxxxx
---------------------------------
Its: Senior Vice President
---------------------------------
Real Estate Legal Affairs
CONFIDENTIAL - DO NOT COPY
Net/Gross Multi-Tenant 500 Arsenal Street/Acusphere, Inc.
Office/Laboratory - Page 1
EXHIBIT A TO LEASE
DESCRIPTION OF PREMISES
See Attached
CONFIDENTIAL - DO NOT COPY
EXHIBIT A TO LEASE
000 Xxxxxxx Xxxxxx, Xxxxxxxxx, XX
Premises of Acusphere, Inc.
(Hatched Area)
[Ground Level Floor Plan - Expansion]
Net/Gross Multi- 500 Arsenal Street/Acusphere, Inc. - Page 1
Tenant Office/Laboratory
EXHIBIT B TO LEASE
DESCRIPTION OF PROJECT
The land in Watertown, Middlesex County, Massachusetts, being Parcel A and
Parcel C on a plan entitled Plan of Land in Watertown, Mass., dated April 1,
1977, Bradford, Xxxxxxx & Assoc. Inc., Engineers-Architects, recorded with
Middlesex South District Deeds, Book 13181, Page 435.
Parcel C contains .32 acres and Parcel A contains 4.95 acres, according to said
Plan. Together with the right to pass and xxxxxx over Parcel B on the aforesaid
Plan and together with and subject to rights in the forty (40) foot private way
shown on the aforesaid Plan as Birch Street, all as set forth in deed of Parcel
B, dated April 14, 1977, recorded Middlesex South District Deeds, Book 13181,
Page 435.
CONFIDENTIAL - DO NOT COPY
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 1
Landlord Build
EXHIBIT C TO LEASE
WORK LETTER
THIS WORK LETTER dated March __, 2001 (this "WORK LETTER") is made and
entered into by and between ARE-500 Arsenal Street, LLC, a Delaware limited
liability company ("LANDLORD"), and Acusphere, Inc., a Delaware corporation
("TENANT"), and is attached to and made a part of the Lease dated March __, 2001
(the "LEASE"), by and between Landlord and Tenant. Any initially capitalized
terms used but not defined herein shall have the meanings given them in the
Lease.
1. GENERAL REQUIREMENTS
(a) TENANT'S AUTHORIZED REPRESENTATIVE. Tenant designates Xxxxxx Xxxxxxx
of Tenant and Xxxxx XxXxxxxxx of Laboratory and Clean Room Consulting, Inc.
(either such individual acting alone, "TENANT'S REPRESENTATIVE"), as the only
persons authorized to act for Tenant pursuant to this Work Letter. Landlord
shall not be obligated to respond to or act upon any request, approval, inquiry
or other communication ("COMMUNICATION") from or on behalf of Tenant in
connection with this Work Letter unless such Communication is in writing from
Tenant's Representative. Tenant may change either Tenant's Representative at any
time upon not less than 5 business days advance written notice to Landlord. No
period set forth herein for any approval of any matter by Tenant's
Representative shall be extended by reason of any change in Tenant's
Representative. Neither Tenant nor Tenant's Representative shall be authorized
to direct Landlord's contractors in the performance of Landlord's Work (as
hereinafter defined).
(b) LANDLORD'S AUTHORIZED REPRESENTATIVE. Landlord designates Xxxxxx
Xxxxxxx and Xxxxxx Cleef (either such individual acting alone, "LANDLORD'S
REPRESENTATIVE") as the only persons authorized to act for Landlord pursuant to
this Work Letter. Tenant shall not be obligated to respond to or act upon any
request, approval, inquiry or other Communication from or on behalf of Landlord
in connection with this Work Letter unless such Communication is in writing from
Landlord's Representative. Landlord may change either Landlord's Representative
at any time upon not less than 5 business days advance written notice to Tenant.
No period set forth herein for any approval of any matter by Landlord's
Representative shall be extended by reason of any change in Landlord's
Representative. Landlord's Representative shall be the sole persons authorized
to direct Landlord's contractors in the performance of Landlord's Work.
(c) DEVELOPMENT SCHEDULE. The schedule for design and development of
Landlord's Improvements (as defined below) and the Tenant Improvements (as
defined below), including without limitation the time periods for delivery of
construction documents and performance, shall be as provided in this Work
Letter, subject to adjustment as mutually agreed by the parties.
(d) ARCHITECTS, CONSULTANTS AND CONTRACTORS. Landlord and Tenant hereby
acknowledge and agree that: (i) Xxxxx Xxxxx and Dioli Architects, Inc. shall be
the architect (the "TI ARCHITECT") for the Tenant Improvements, and (ii) The
Richmond Group, Inc. shall be the general contractor.
2. TENANT IMPROVEMENTS.
(a) TENANT IMPROVEMENTS DEFINED. As used herein, "TENANT IMPROVEMENTS"
shall mean all improvements to the Project desired by Tenant of a fixed and
permanent nature, exclusive of the improvements indicated as Landlord's
improvements on Schedule B attached hereto ("LANDLORD'S IMPROVEMENTS"). Other
than the Tenant Improvements and Landlord's Improvements, Landlord shall not
have any obligation whatsoever with respect to the finishing of the Premises for
Tenant's use and occupancy.
CONFIDENTIAL - DO NOT COPY
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 2
Landlord Build
(b) TENANT'S SPACE PLANS. Tenant has delivered to Landlord and the TI
Architect schematic drawings and outline specifications (the "TI DESIGN
DRAWINGS") detailing Tenant's requirements for the Tenant Improvements. Landlord
has approved the TI Design Drawings.
(c) PRELIMINARY TI PLANS. Landlord has caused the TI Architect to
prepare and submit for Tenant's review and approval preliminary plans and
specifications for development of the Tenant Improvements (the "PRELIMINARY TI
PLANS"). Tenant has approved the Preliminary TI Plans.
(d) BUDGET. Not later than 10 business days following the date of full
execution hereof, Landlord shall obtain and deliver to Tenant a budget in
accordance with Section 5(a) hereof. At Tenant's election, and not later than 5
business days after Tenant's receipt of the budget, Tenant and Landlord shall
jointly develop a list of mutually acceptable value engineering items ("VE
ITEMS") for purpose of reducing the budget. Not later than 5 business days
thereafter Landlord shall obtain and deliver a revised budget incorporating the
VE Items.
(e) CONSTRUCTION DRAWINGS. Not later than 30 business days following the
delivery of the Budget to Tenant, Landlord shall cause the TI Architect to
prepare and deliver to Tenant for review and comment construction plans,
specifications and drawings for the Tenant Improvements ("TI CONSTRUCTION
DRAWINGS"), which TI Construction Drawings shall be prepared substantially in
accordance with the Preliminary TI Plans approved by Tenant as modified by the
VE Items. Tenant shall be solely responsible for ensuring that the TI
Construction Drawings reflect Tenant's requirements for the Tenant Improvements.
Tenant shall deliver its written comments on the TI Construction Drawings to
Landlord not later than 10 business days after Tenant's receipt of the same;
provided, however, that Tenant may not disapprove any matter that is consistent
with the Preliminary TI Plans approved by Tenant as modified by the VE Items
without submitting a Change Request. Landlord and the TI Architect shall
consider all such comments in good faith and shall, within 5 business days after
receipt, notify Tenant how Landlord proposes to respond to such comments and/or
commence the revisions of the TI Construction Drawings in accordance with the
comments which are acceptable to Landlord. Any disputes in connection with such
comments shall be resolved in accordance with Section 2(f) hereof. Once approved
by Tenant, subject to the provisions of Section 2(f) below, Landlord shall not
materially modify the TI Construction Drawings except as may be reasonably
required in connection with the issuance of the TI Permit (as defined in Section
3(b) below) pursuant to Section 3(b) below.
(f) DESIGN DISPUTES. Upon any dispute regarding the design of Landlord's
Improvements or the Tenant Improvements, which is not settled within 5 business
days after notice of such dispute is delivered by one party to the other,
Landlord shall make the final decision regarding the design of Landlord's
Improvements, provided Landlord acts reasonably and such final decision is
either consistent with or a compromise between Landlord's and Tenant's positions
with respect to such dispute, and Tenant shall make the final decision regarding
the design of the Tenant Improvements, provided Tenant acts reasonably and such
final decision is either consistent with or a compromise between Landlord's and
Tenant's positions with respect to such dispute, provided further that all costs
and expenses resulting from any such decision by Tenant shall be payable out of
the TI Fund (as defined in Section 5(d) below). Any changes to the TI
Construction Drawings following Landlord's and Tenant's approval of same
requested by Tenant shall be processed as provided in Section 4 hereof.
3. PERFORMANCE OF LANDLORD'S WORK.
(a) DEFINITION OF LANDLORD'S WORK. As used herein, "LANDLORD'S WORK"
shall mean the work of constructing Landlord's Improvements and the Tenant
Improvements.
(b) COMMENCEMENT AND PERMITTING OF LANDLORD'S WORK. Landlord at its
expense has obtained a building permit authorizing the construction of
Landlord's Improvements (the "BUILDING
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 3
Landlord Build
PERMIT"). Landlord shall commence construction of the Tenant Improvements upon
the later of (i) obtaining a building permit (the "TI PERMIT") authorizing the
construction of the Tenant Improvements consistent with the TI Construction
Drawings approved by Tenant, or (ii) having sufficiently completed Landlord's
Improvements such that the work of constructing the Tenant Improvements can be
efficiently prosecuted. The cost of obtaining the TI Permit shall be payable
from the TI Fund. Tenant shall assist Landlord in obtaining the TI Permit. If
any Governmental Authority having jurisdiction over the construction of
Landlord's Work or any portion thereof shall impose terms or conditions upon the
construction thereof which: (i) are inconsistent with Landlord's obligations
hereunder, (ii) increase the cost of constructing Landlord's Work, or (iii) will
materially delay the construction of Landlord's Work, Landlord and Tenant shall
reasonably and in good faith seek means by which to mitigate or eliminate any
such adverse terms and conditions.
(c) COMPLETION OF LANDLORD'S WORK. On or before the Target Commencement
Date (subject to Tenant Delays and Force-Majeure Delays), Landlord shall
substantially complete or cause to be substantially completed Landlord's Work in
a good and workmanlike manner and in accordance with the Building Permit and the
TI Permit subject, in each case, to Minor Variations and normal "punch list"
items of a non-material nature which do not interfere with the use of the
Premises ("SUBSTANTIAL COMPLETION"). Upon the Substantial Completion of
Landlord's Work; Landlord shall require the TI Architect and the general
contractor to execute and deliver, for the benefit of Tenant and Landlord, a
Certificate of Substantial Completion in the form of the American Institute of
Architects document G704. For purposes of this Work Letter, "MINOR VARIATIONS"
shall mean any completed modifications reasonably required: (i) to comply with
all applicable Legal Requirements and/or to obtain or to comply with any
required permit (including the Building Permit and the TI Permit); (ii) to
comply with any request by Tenant for modifications to Landlord's Work; (iii) to
comport with good design, engineering, and construction practices which are not
material; or (iv) to make reasonable adjustments for field deviations or
conditions encountered during the construction of Landlord's Work.
(d) SELECTION OF MATERIALS, ETC. Where more than one type of material or
structure is indicated on the TI Construction Drawings approved by Landlord and
Tenant, the option will be within Landlord's sole discretion. As to all building
materials and equipment which Landlord is obligated to supply under this Work
Letter, Landlord shall select the manufacturer thereof in its sole discretion.
(e) DELIVERY OF THE PREMISES. When Landlord's Work is Substantially
Complete, subject to the remaining terms and provisions of this Section 3(e),
Tenant shall accept the Premises. Tenant's taking possession and acceptance of
the Premises shall not constitute a waiver of: (i) any warranty with respect to
workmanship (including installation of equipment) or material (exclusive of
equipment provided directly by manufacturers), (ii) any non-compliance of
Landlord's Work with Legal Requirements, or (iii) any claim that Landlord's Work
was not completed substantially in accordance with the TI Construction Drawings
(subject to Minor Variations and such other changes as are permitted hereunder)
(collectively, a "CONSTRUCTION DEFECT"). Tenant shall have 1 year after
Substantial Completion within which to notify Landlord of any such Construction
Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy
or cause the responsible contractor to remedy any such Construction Defect
within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be
in default under the Lease if:
(i) with respect to the Tenant Improvements, the applicable
contractor, despite Landlord's reasonable efforts, fails to remedy such
Construction Defect within such 30-day period, in which case Landlord
shall have no further obligation with respect to such Construction
Defect other than to cooperate, at no cost to Landlord, with Tenant
should Tenant elect to pursue a claim against such contractor or the TI
Architect, provided that Tenant indemnifies and holds Landlord harmless
from and against any liability, loss, cost damage or expense in
connection with any such claim, and Landlord shall assign to Tenant
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 4
Landlord Build
as reasonably necessary all rights Landlord may have against such
architect or contractor relating to a Construction Defect, or, if any
such rights are not assignable, permit Tenant to bring suit in
Landlord's name to enforce any claim or to seek any damages relating to
a Construction Defect, provided that Tenant indemnifies and holds
Landlord harmless from and against any liability, loss, cost, damage or
expense in connection with any such claim, or
(ii) with respect to Landlord's Improvements, the applicable
contractor, despite Landlord's reasonable efforts, fails to remedy such
Construction Defect within such 30-day period, but Landlord, within 30
days thereafter, commences and diligently and continuously prosecutes
such remedial action to completion.
Tenant shall be entitled to receive the benefit of all construction warranties
and manufacturer's equipment warranties relating to equipment installed in the
Premises. If requested by Tenant, Landlord shall attempt to obtain extended
warranties from manufacturers and suppliers of such equipment, but the cost of
any such extended warranties shall be borne solely out of the TI Fund. Landlord
shall diligently pursue any claims arising out of latent defects in the Project.
Landlord shall promptly undertake and complete, or cause to be completed, all
punch list items.
(f) COMMENCEMENT DATE DELAY. The Commencement Date shall occur on
Delivery (the "COMPLETION DATE"), except to the extent that Delivery shall have
been actually delayed by any one or more of the following causes (a "TENANT
DELAY"):
(i) Tenant's Representative was not available to give or receive
any Communication or to take any other action required to be taken by
Tenant hereunder,
(ii) Tenant's request for Change Requests (as defined in Section
4(a) below) whether or not any such Change Requests are actually
performed;
(iii) Construction of any Change Requests;
(iv) Tenant's request for materials, finishes or installations
requiring unusually long lead times;
(v) Tenant's delay in reviewing, revising or approving plans and
specifications beyond the periods set forth herein;
(vi) Tenant's delay in providing information critical to the
normal progression of the Project. Tenant shall provide such information
as soon as reasonably possible, but in no event longer than one week
after receipt of any request for such information from Landlord;
(vii) Tenant's delay in making payments to Landlord for Excess TI
Costs (as defined in Section 5(d) below); or
(viii) Any other act or, where Tenant has an obligation to act,
omission by Tenant or any Tenant Party, or persons employed by any of
such persons.
If the Commencement Date is delayed for any of the foregoing reasons, then
Landlord shall cause the TI Architect to certify the date on which the Tenant
Improvements would have been completed but for such Tenant Delay and such
certified date shall be the Commencement Date under the Lease.
4. CHANGES. Any changes requested by Tenant to Landlord's Improvements
at any time, or
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 5
Landlord Build
to the Tenant Improvements after the acceptance by Landlord and Tenant of the
Preliminary TI Plans, as modified by the VE Items, shall be requested and
instituted in accordance with the provisions of this Section 4 and shall be
subject to the written approval of Landlord and the TI Architect, such approval
not to be unreasonably withheld, conditioned or delayed.
(a) TENANT'S RIGHT TO REQUEST CHANGES. If Tenant shall request
changes to the Landlord's Improvements or if Tenant shall request changes to the
Tenant's Improvements after acceptance by Landlord and Tenant of the Preliminary
TI Plans, as modified by the VE Items (collectively, "Changes"), Tenant shall
request such Changes by notifying Landlord in writing in substantially the same
form as the AIA standard change order form (a "CHANGE REQUEST"), which Change
Request shall detail the nature and extent of any such Change. Such Change
Request must be signed by Tenant's Representative. Landlord shall, before
proceeding with any Change, use its best efforts to respond to Tenant as soon as
is reasonably possible with an estimate of: (i) the time it will take, and (ii)
the architectural and engineering fees and costs which will be incurred, to
analyze such Change Request (which costs shall be paid from the TI Fund to the
extent actually incurred, whether or not such change is implemented). Landlord
shall thereafter submit to Tenant in writing, within 5 business days of receipt
of the Change Request (or such longer period of time as is reasonably required
depending on the extent of the Change Request), an analysis of the additional
cost or savings involved, including, without limitation, architectural and
engineering costs and the period of time, if any, that the Change will extend
the date on which Landlord's Work will be Substantially Complete. Any such delay
in the completion of Landlord's Work caused by a Change, including any
suspension of Landlord's Work while any such Change is being evaluated and/or
designed, shall be a Tenant Delay.
(b) IMPLEMENTATION OF CHANGES. If Tenant: (i) approves in writing the
cost or savings and the estimated extension in the time for completion of
Landlord's Work, if any, and (ii) deposits with Landlord any Excess TI Costs
required in connection with such Change, Landlord shall cause the approved
Change to be instituted. Notwithstanding any approval or disapproval by Tenant
of any estimate of the delay caused by such proposed Change, the TI Architect's
determination of the amount of Tenant Delay in connection with such Change shall
be final and binding on Landlord and Tenant.
5. COSTS.
(a) BUDGET FOR TENANT IMPROVEMENTS. Before the commencement of
construction of the Tenant Improvements, Landlord shall obtain a detailed
breakdown, by trade, of the costs incurred or which will be incurred in
connection with the design and construction of Tenant Improvements (the
"BUDGET"). The Budget shall be based upon the Preliminary TI Plans as modified
by the VE Items, approved by Tenant and shall include a payment to Landlord of
administrative rent equal ("ADMINISTRATIVE RENT") equal to 3% of the TI
Allowance (as hereinafter defined) for monitoring and inspecting the
construction of Tenant's Work, which sum shall be payable from the TI Fund. Such
Administrative Rent shall include, without limitation, all out-of-pocket costs,
expenses and fees incurred by or on behalf of Landlord arising from, out of, or
in connection with, such monitoring of the construction of the Tenant
Improvements, and shall be payable out of the TI Fund. If the Budget is greater
than the TI Allowance, Tenant shall deposit with Landlord the difference, in
cash, prior to the commencement of construction of the Tenant Improvements, for
disbursement by Landlord as described in Section 5(d).
(b) TI ALLOWANCE. Landlord shall provide to Tenant a tenant
improvement allowance ("TI ALLOWANCE") of $95 per rentable square foot of the
Premises or $4,512,500 based upon the Premises containing 47,500 rentable square
feet. Within 5 business days of receipt of the Budget from Landlord, Tenant
shall notify Landlord how much TI Allowance Tenant has elected to receive from
Landlord. Such election shall be final and binding on Tenant, and may not
thereafter be modified without Landlord's consent, which may be granted or
withheld in Landlord's sole and
Major Construction - Landlord Build 500 Arsenal Street/Acusphere, Inc. - Page 6
absolute discretion. The TI Allowance shall be disbursed in accordance with this
Work Letter.
(c) COSTS INCLUDABLE IN TI FUND. The TI Fund shall be used solely for
the payment of design and construction costs in connection with the construction
of the Tenant Improvements, including, without limitation, the cost of preparing
the TI Design Drawings, the Preliminary TI Plans, and the TI Construction
Drawings, all costs set forth in the Budget, including Landlord's Administrative
Rent, Landlord's out-of-pocket expenses, costs resulting from Tenant Delays and
the cost of Changes (collectively, "TI COSTS"). Notwithstanding anything to the
contrary contained herein, the TI Fund shall not be used to purchase any
furniture, personal property or other non-Building System materials or
equipment, including, but not limited to, biological safety cabinets and other
scientific equipment not incorporated into the Tenant Improvements.
(d) EXCESS TI COSTS. It is understood and agreed that Landlord is under
no obligation to bear any portion of the cost of any of the Tenant Improvements
except to the extent of the TI Allowance. If at any time and from time-to-time,
the remaining TI Costs under the Budget exceed the remaining unexpended TI
Allowance within 5 business days of notice from Landlord, Tenant shall deposit
with Landlord, as a condition precedent to Landlord's obligation to complete the
Tenant Improvements, 100% of the then current TI Cost in excess of the remaining
TI Allowance ("EXCESS TI COSTS"). If Tenant fails to deposit, or is late in
depositing, any Excess TI Costs amount with Landlord, Landlord shall have all of
the rights and remedies set forth in the Lease for nonpayment of Rent
(including, but not limited to, the right to interest at the Default Rate and
the right to assess a late charge), and for purposes of any litigation
instituted with regard to such amounts the same will be considered Rent. Such
deposit of Excess TI Costs, together with the remaining TI Allowance, is herein
referred to as the "TI FUND." Funds so deposited by Tenant shall be the first
thereafter disbursed to pay TI Costs. Notwithstanding anything to the contrary
set forth in this Section 5(d), Tenant shall be fully and solely liable for TI
Costs and the cost of Minor Variations in excess of the TI Allowance. If upon
Substantial Completion of the Tenant Improvements and the payment of all sums
due in connection therewith there remains any undisbursed TI Fund, within 30
days thereafter, Tenant shall be entitled to such undisbursed TI Fund solely to
the extent of any Excess TI Costs deposit Tenant has actually made with
Landlord.
(e) PAYMENT FOR LANDLORD'S IMPROVEMENTS. Landlord shall bear all costs,
expenses and fees incurred by or on behalf of Landlord in connection with the
construction of Landlord's Improvements, other than as a result of Tenant
requested Changes, subject to the terms hereof and the terms of the Lease.
6. TENANT ACCESS.
(a) TENANT'S ACCESS RIGHTS. Landlord hereby agrees to permit Tenant
access, at Tenant's sole risk and expense, to the Building (i) 30 days prior to
the Term Commencement Date to perform any work ("TENANT'S WORK") required by
Tenant other than Landlord's Work and provided that such Tenant's Work is
coordinated with the TI Architect and the general contractor, and complies with
the Lease and all other reasonable restrictions and conditions Landlord may
impose, and (ii) prior to the completion of Landlord's Work, to inspect and
observe work in process; all such access shall be during normal business hours
or at such other times as are reasonably designated by Landlord. Notwithstanding
the foregoing, Tenant shall have no right to enter onto the Premises or the
Project unless and until Tenant shall deliver to Landlord evidence reasonably
satisfactory to Landlord demonstrating that any insurance reasonably required by
Landlord in connection with such pre-commencement access (including, but not
limited to, any insurance which Landlord may require pursuant to the Lease) is
in full force and effect. Any entry by Tenant shall comply with all established
safety practices of Landlord's contractor and Landlord until completion of
Landlord's Work and acceptance thereof by Tenant.
(b) NO INTERFERENCE. Neither Tenant nor any Tenant Party shall
materially interfere with
Major Construction - Landlord Build 500 Arsenal Street/Acusphere, Inc. - Page 7
the performance of Landlord's Work, nor with any inspections or issuance of
final approvals by Middlesex County or the Town of Watertown, and upon any such
interference, Landlord shall have the right to exclude Tenant and any Tenant
Party from the Premises and the Project until Substantial Completion of
Landlord's Work.
(c) NO ACCEPTANCE OF PREMISES. The fact that Tenant may, with Landlord's
consent, enter into the Project prior to the date Landlord's Work is
Substantially Complete for the purpose of performing any Tenant's Work shall not
be deemed an acceptance by Tenant of possession of the Premises, but in such
event Tenant shall indemnify and hold Landlord harmless from any loss of or
damage to Tenant's property, completed work, fixtures, equipment, materials or
merchandise, and from liability for death of, or injury to, any person, caused
by the willful misconduct or negligence of Tenant or any Tenant Party.
7. NOTIFICATION OF DELAYS. Not less than once each calendar month from the date
of this Work Letter through the Term Commencement Date, Landlord shall deliver
to Tenant written notification of the number of days during the immediately
preceding calendar month Landlord's performance under this Work Letter or the
Lease was delayed as a result of Tenant Delays or delays arising by reason of
any Force Majeure as defined in Section 34 of the Lease (a "FORCE MAJEURE
DELAY"), which written notification shall also include a description of the
nature of such Tenant Delay or Force Majeure Delay.
8. MISCELLANEOUS
(a) CONSENTS. Whenever consent or approval of either party is required
under this Work Letter, that party shall not unreasonably withhold, condition or
delay such consent or approval, except as may be expressly set forth herein to
the contrary.
(b) MODIFICATION. No modification, waiver or amendment of this Work
Letter or of any of its conditions or provisions shall be binding upon Landlord
or Tenant unless in writing signed by Landlord and Tenant.
(c) COUNTERPARTS. This Work Letter may be executed in any number of
counterparts but all counterparts taken together shall constitute a single
document.
(d) GOVERNING LAW. This Work Letter shall be governed by, construed and
enforced in accordance with the internal laws of the state in which the Premises
are located, without regard to choice of law principles of such State.
(e) TIME OF THE ESSENCE. Time is of the essence of this Work Letter and
of each and all provisions thereof.
(f) DEFAULT. Notwithstanding anything set forth herein or in the Lease
to the contrary, Landlord shall not have any obligation to perform any work
hereunder or to fund any portion of the TI Fund during any period Tenant is in
Default under the Lease.
(g) SEVERABILITY. If any term or provision of this Work Letter is
declared invalid or unenforceable, the remainder of this Work Letter shall not
be affected by such determination and shall continue to be valid and
enforceable.
(h) MERGER. All understandings and agreements, oral or written,
heretofore made between the parties hereto and relating to Landlord's Work and
Tenant's Work are merged in this Work Letter, which alone (but inclusive of
provisions of the Lease incorporated herein and the final approved constructions
drawings and specifications prepared pursuant hereto) fully and completely
expresses the agreement between Landlord and Tenant with regard to the matters
set forth in this
Major Construction - Landlord Build 500 Arsenal Street/Acusphere, Inc. - Page 8
Work Letter.
(i) ENTIRE AGREEMENT. This Work Letter is made as a part of and pursuant
to the Lease and, together with the Lease, constitutes the entire agreement of
the parties with respect to the subject matter hereof. This Work Letter is
subject to all of the terms and limitation set forth in the Lease, and neither
party shall have any rights or remedies under this Work Letter separate and
apart from their respective remedies pursuant to the Lease.
Major Construction - Landlord Build 500 Arsenal Street/Acusphere, Inc. - Page 9
IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter
to be effective on the date first above written.
TENANT:
ACUSPHERE INC.
By: __________________________________________
Name:__________________________________________
Its: __________________________________________
LANDLORD:
ARE-500 ARSENAL STREET, LLC
By: ALEXANDRIA REAL ESTATE EQUITIES, L.P.
managing member
By: ARE-QRS CORP.
general partner
By: ______________________________
Name: ______________________________
Title:______________________________
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 10
Landlord Build
SCHEDULE B TO WORK LETTER
LANDLORD'S IMPROVEMENTS
See Attached
Major Construction - 500 Arsenal Street/Acusphere, Inc. - Page 11
Landlord Build
EXHIBIT D TO LEASE
ACKNOWLEDGMENT OF COMMENCEMENT DATE
This ACKNOWLEDGMENT OF COMMENCEMENT DATE is made this __________ day of
____________________, ______________________, between ARE-500 ARSENAL STREET,
LLC, a Delaware limited liability company ("LANDLORD"), and ACUSPHERE, INC., a
Delaware corporation ("TENANT"), and is attached to and made a part of the Lease
dated March _, 2001 (the "LEASE"), by and between Landlord and Tenant. Any
initially capitalized terms used but not defined herein shall have the meanings
given them in the Lease.
Landlord and Tenant hereby acknowledge and agree, for all purposes of
the Lease, that the Commencement Date of the Base Term of the Lease is
_______________, __ and the termination date of the Base Term of the Lease shall
be midnight on _______________, __.
IN WITNESS WHEREOF, Landlord and Tenant have executed this
ACKNOWLEDGMENT OF COMMENCEMENT DATE to be effective on the date first above
written.
TENANT:
ACUSPHERE INC.
By: ________________________________________
Name: ______________________________________
Its:________________________________________
LANDLORD:
ARE-500 ARSENAL STREET, LLC
By: ALEXANDRIA REAL ESTATE EQUITIES, L.P.
managing member
By: ARE-QRS CORP.
general partner
By: __________________________
Name: ________________________
Its:__________________________
Rules and Regulations 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT E TO LEASE
RULES AND REGULATIONS
1. The sidewalk, entries, and driveways of the Project shall not be
obstructed by Tenant, or any Tenant Party, or used by them for any purpose other
than ingress and egress to and from the Premises.
2. Tenant shall not place any objects, including antennas, outdoor
furniture, etc., in the parking areas, landscaped areas or other areas outside
of its Premises, or on the roof of the Project.
3. Except for seeing-eye dogs, no animals shall be allowed in the
offices, halls, or corridors in the Project.
4. Tenant shall not disturb the occupants of the Project or adjoining
buildings by the use of any radio or musical instrument or by the making of loud
or improper noises.
5. If Tenant desires telegraphic, telephonic or other electric
connections in the Premises, Landlord or its agent will direct the electrician
as to where and how the wires may be introduced; and, without such direction, no
boring or cutting of wires will be permitted. Any such installation or
connection shall be made at Tenant's expense.
6. Tenant shall not install or operate any steam or gas engine or
boiler, or other mechanical apparatus in the Premises, except as specifically
approved in the Lease. The use of oil, gas or inflammable liquids for heating,
lighting or any other purpose is expressly prohibited. Explosives or other
articles deemed extra hazardous shall not be brought into the Project.
7. Parking any type of recreational vehicles is specifically prohibited
on or about the Project. Except for the overnight parking of operative vehicles,
no vehicle of any type shall be stored in the parking areas at any time. In the
event that a vehicle is disabled, it shall be removed within 48 hours. There
shall be no "For Sale" or other advertising signs on or about any parked
vehicle. All vehicles shall be parked in the designated parking areas in
conformity with all signs and other markings. All parking will be open parking,
and no reserved parking, numbering or lettering of individual spaces will be
permitted except as specified by Landlord.
8. Tenant shall maintain the Premises free from rodents, insects and
other pests.
9. Landlord reserves the right to exclude or expel from the Project any
person who, in the judgment of Landlord, is intoxicated or under the influence
of liquor or drugs or who shall in any manner do any act in violation of the
Rules and Regulations of the Project.
10. Tenant shall not cause any unnecessary labor by reason of Tenant's
carelessness or indifference in the preservation of good order and cleanliness.
Landlord shall not be responsible to Tenant for any loss of property on the
Premises, however occurring, or for any damage done to the effects of Tenant by
the janitors or any other employee or person.
11. Tenant shall give Landlord prompt notice of any defects in the
water, lawn sprinkler, sewage, gas pipes, electrical lights and fixtures,
heating apparatus, or any other service equipment affecting the Premises.
12. Tenant shall not permit storage outside the Premises, including
without limitation,
Rules and Regulations 500 Arsenal Street/Acusphere, Inc. - Page 2
outside storage of trucks and other vehicles, or dumping of waste or refuse or
permit any harmful materials to be placed in any drainage system or sanitary
system in or about the Premises, except in accordance with the Lease.
13. All moveable trash receptacles provided by the trash disposal firm
for the Premises must be kept in the trash enclosure areas, if any, provided for
that purpose.
14. No auction, public or private, will be permitted on the Premises or
the Project.
15. No awnings shall be placed over the windows in the Premises except
with the prior written consent of Landlord.
16. The Premises shall not be used for lodging, sleeping or cooking or
for any immoral or illegal purposes or for any purpose other than that specified
in the Lease. No gaming devices shall be operated in the Premises.
17. Tenant shall ascertain from Landlord the maximum amount of
electrical current which can safely be used in the Premises, taking into account
the capacity of the electrical wiring in the Project and the Premises and the
needs of other tenants, and shall not use more than such safe capacity.
Landlord's consent to the installation of electric equipment shall not relieve
Tenant from the obligation not to use more electricity than such safe capacity.
18. Tenant assumes full responsibility for protecting the Premises from
theft, robbery and pilferage.
19. Tenant shall not install or operate on the Premises any machinery or
mechanical devices of a nature not directly related to Tenant's ordinary use of
the Premises and shall keep all such machinery free of vibration, noise and air
waves which may be transmitted beyond the Premises.
Tenant's Personal Property 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT F TO LEASE
TENANT'S PERSONAL PROPERTY
None except as set forth below:
EStoppel Certificate 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT G TO LEASE
ESTOPPEL CERTIFICATE
THIS TENANT ESTOPPEL CERTIFICATE ("CERTIFICATE"), dated as of ________,
____________, is executed by _____________________________________ ("TENANT") in
favor of [BUYER], a _____________________________________, together with its
nominees, designees and assigns (collectively, "BUYER"), and in favor of
__________________________________, together with its nominees, designees and
assigns (collectively, "LENDER").
RECITALS
A. Buyer and ______________("LANDLORD") have entered into that certain
Purchase and Sale Agreement and Joint Escrow Instructions, dated as of
________________, 20__ (the "PURCHASE AGREEMENT"), whereby Buyer has agreed to
purchase, among other things, the improved real property located in the City of
___________, County of _____________, State of _________, more particularly
described on Exhibit A attached to the Purchase Agreement (the "PROPERTY").
B. Tenant and Landlord have entered into that certain Lease Agreement,
dated as of _____________ (together with all amendments, modifications,
supplements, guarantees and restatements thereof, the "LEASE"), for a portion of
the Property.
C. Pursuant to the Lease, Tenant has agreed that upon the request of
Landlord, Tenant would execute and deliver an estoppel certificate certifying
the status of the Lease.
D. In connection with the Purchase Agreement, Landlord has requested
that Tenant execute this Certificate with an understanding that Lender will rely
on the representations and agreements below in granting to Buyer a loan.
NOW, THEREFORE, Tenant certifies, warrants, and represents to Buyer and
Lender as follows:
1. LEASE. Attached hereto as Exhibit B is a true, correct and complete copy of
the Lease, including the following amendments, modifications, supplements,
guarantees and restatements thereof, which together represent all of the
amendments, modifications, supplements, guarantees and restatements thereof:
________________________________________________________________________________
__________________________________ . (If none, please state "None.")
2. PREMISES. Pursuant to the Lease, Tenant leases those certain premises (the
"PREMISES") consisting of approximately ________ rentable square feet within the
Property, as more particularly described in the Lease. In addition, pursuant to
the terms of the Lease, Tenant has the [non-exclusive] right to use [_____
parking spaces/the parking area] located on the Property during the term of the
Lease. [CROSS-OUT THE PRECEDING SENTENCE OR PORTIONS THEREOF IF INAPPLICABLE.]
3. FULL FORCE OF LEASE. The Lease has been duly authorized, executed and
delivered by Tenant, is in full force and effect, has not been terminated, and
constitutes a legally valid instrument, binding and enforceable against Tenant
in accordance with its terms, subject only to applicable limitations imposed by
laws relating to bankruptcy and creditor's rights.
4. COMPLETE AGREEMENT. The Lease constitutes the complete agreement between
Landlord and Tenant for the Premises and the Property, and except as modified by
the Lease amendments noted above (if any), has not been modified, altered or
amended.
EStoppel Certificate 500 Arsenal Street/Acusphere, Inc. - Page 2
5. ACCEPTANCE OF PREMISES. Tenant has accepted possession of and is currently
occupying the Premises.
6. LEASE TERM. The term of the Lease commenced on _________________ and ends on
_________________, subject to the following options to extend:
_________________________________________________________. (If none, please
state "None.")
7. PURCHASE RIGHTS. Tenant has no option, right of first refusal, right of first
offer, or other right to acquire or purchase all or any portion of the Premises
or all or any portion of, or interest in, the Property, except as follows:
__________________________________________________________________________
___________________________________________________. (If none, please state
"None.")
8. RIGHTS OF TENANT. Except as expressly stated in this Certificate, Tenant:
(a) has no right to renew or extend the term of the Lease;
(b) has no option or other right to purchase all or any part
of the Premises or all or any part of the Property; and
(c) has no right, title, or interest in the Premises, other
than as Tenant under the Lease.
9. RENT.
(a) The obligation to pay rent under the Lease commenced on
_________________. The rent under the Lease is current, and Tenant is
not in default in the performance of any of its obligations under the
Lease.
(b) Tenant is currently paying base rent under the Lease in
the amount of $ ___ per month. Tenant has not received and is not
presently entitled to any abatement, refunds, rebates, concessions or
forgiveness of rent or other charges, free rent, partial rent, or
credits, offsets or reductions in rent, except as follows:
_____________________________________________. (If none, please state
"None.")
(c) Tenant's estimated share of operating expenses, common
area charges, insurance, real estate taxes and administrative and
overhead expenses is ___% and is currently being paid at the rate of
$______ per month, payable to: _______________________________________.
(d) There are no existing defenses or offsets against rent due
or to become due under the terms of the Lease, Tenant has not given
Landlord notice of a default or other wrongful act or omission by
Landlord under the Lease or otherwise in connection with Tenant's
occupancy of the Premises and, to the best of Tenant's knowledge,
acknowledging that Tenant has not given Landlord notice of any uncured
defaults on the part of Landlord hereunder and that to the best of
Tenant's knowledge there are no events or circumstances which, with the
passage of time or the giving of notice, would give rise to a default
or other wrongful act or omission by Landlord under the Lease or
otherwise in connection with Tenant's occupancy of the Premises, nor is
there a state of facts which with the passage of time or the giving of
notice or both could ripen into a default on the part of Tenant, or, to
the best knowledge of Tenant, could ripen into a default on the part of
Landlord under the Lease, except as follows:__________________________
Estoppel Certificate 500 Arsenal Street/Acusphere, Inc. - Page 3
______________________________________________________________________
__________________________________________. (If none, please state
"None.")
10. SECURITY DEPOSIT. The amount of Tenant's security deposit held by Landlord
under the Lease is $_________________.
11. PREPAID RENT. The amount of prepaid rent, separate from the security
deposit, is $___________, covering the period from ______________________ to
___________________.
12. INSURANCE. All insurance, if any, required to be maintained by Tenant under
the Lease is presently in effect.
13. PENDING ACTIONS. There is not pending or, to the knowledge of Tenant,
threatened against or contemplated by Tenant, any petition in bankruptcy,
whether voluntary or otherwise, any assignment for the benefit of creditors, or
any petition seeking reorganization or arrangement under the federal bankruptcy
laws or those of any state.
14. TENANT IMPROVEMENTS. As of the date of this Certificate, to the best of
Tenant's knowledge, Landlord has performed all obligations required of Landlord
pursuant to the Lease with respect to the Tenant Improvements; no counterclaims,
or defenses of Tenant under the Lease exist against Landlord; and no events have
occurred that, with the passage of time or the giving of notice or both, would
constitute a basis for offsets, counterclaims, or defenses against Landlord,
except as follows:______________________________________________________
______________________________________________. (If none, please state "None.")
15. ASSIGNMENTS BY LANDLORD. Tenant has received no notice of any assignment,
hypothecation or pledge of the Lease or rentals under the Lease by Landlord.
Tenant hereby consents to an assignment of the Lease and rents to be executed by
Landlord to Buyer or Lender in connection with the Loan and acknowledges that
said assignment does not violate the provisions of the Lease. Tenant
acknowledges that the interest of Landlord under the Lease is to be assigned to
Buyer or Lender solely as security for the purposes specified in said assignment
and Buyer or Lender shall have no duty, liability or obligation whatsoever under
the Lease or any extension or renewal thereof, either by virtue of said
assignment or by any subsequent receipt or collection of rents thereunder,
unless Buyer or Lender shall specifically undertake such liability in writing.
Tenant agrees (and Landlord consents thereto) that upon receipt of a written
notice from Buyer or Lender of a default by Landlord under the Loan, Tenant will
thereafter pay rent to Buyer or Lender in accordance with the terms of the
Lease.
16. ASSIGNMENTS BY TENANT. Tenant has not sublet or assigned the Premises or the
Lease or any portion thereof to any sublessee or assignee except as follows:
______________________. (If none, please state "None.") No one except Tenant and
its employees will occupy the Premises. The address for notices to be sent to
Tenant is as set forth in the Lease.
17. ENVIRONMENTAL MATTERS. The operation and use of the Premises does not
involve the use, storage, handling, treatment, generation, disposal or release
into the environment of any hazardous materials, regulated materials and/or
solid waste, except those used in the ordinary course of operating for the
Permitted Use (as defined in the Lease), or otherwise used in accordance with
all applicable laws.
18. NOTICE OF DEFAULT. Tenant agrees to give Buyer and Lender a copy of any
notice of default under the Lease served upon Landlord at the same time as such
notice is given to Landlord. Tenant further agrees that if Landlord shall fail
to cure such default within the applicable grace period, if any, provided in the
Lease, then Buyer or Lender shall have an additional 60 days within
Estoppel Certificate 500 Arsenal Street/Acusphere, Inc. - Page 4
which to cure such default, or if such default cannot be cured within such
60-day period, such 60-day period shall be extended so long as Buyer or Lender
has commenced and is diligently pursuing the remedies necessary to cure such
default, including, but not limited to, commencement of foreclosure proceedings,
if necessary to effect such cure, in which event the Lease shall not be
terminated while such remedies are being pursued.
Tenant makes this Certificate with the knowledge that it will be relied
upon by Buyer and Lender in agreeing to purchase the Property.
Tenant has executed this Certificate as of the date first written above
by the person named below, who is duly authorized to do so.
TENANT: _____________________________________________________,
a _________________________________________________
By: _____________________________________________
Name: _______________________________________
Its: _______________________________________
Estoppel Certificate 500 Arsenal Street/Acusphere, Inc. - Page 5
EXHIBIT A TO ESTOPPEL CERTIFICATE
LEGAL DESCRIPTION
Estoppel Certificate 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT B TO ESTOPPEL CERTIFICATE
COPY OF LEASE
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT H TO LEASE
SUBORDINATION, NON-DISTURBANCE AND
ATTORNMENT AGREEMENT
THIS SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT is made
and entered into as of _______________, _______________ ("AGREEMENT"), by and
between ARE- _____________________ [CHECK ENTITY OWNERSHIP CHART], a
______________, together with its nominees, designees and assigns (collectively,
"LANDLORD"), ______________, a _________ ("TENANT"), and
___________________________, a _________________ ("MORTGAGEE").
WHEREAS, Mortgagee is making a loan to Landlord and others evidenced by
a certain promissory note ("NOTE"), and secured by, among other things, a deed
of trust/mortgage to be recorded prior hereto in the public records of the City
of __________, County of __________, State of __________ ("MORTGAGE")
constituting a lien upon the real property described in Exhibit A hereto (the
"REAL PROPERTY"); and
WHEREAS, __________________ and Tenant have entered into a Lease
Agreement dated as of ______________________, __ ("LEASE"), for certain leased
premises encompassing____________________________ located in
___________________________, containing approximately _________________________
net square feet (hereinafter collectively referred to as "PREMISES"); and
WHEREAS, the Lease is subordinate to the Mortgage and to the right,
title, and interests of Mortgagee thereto and thereunder; and
WHEREAS, Mortgagee wishes to obtain from Tenant certain assurances that
Tenant will attorn to Mortgagee in the event of a foreclosure by Mortgagee or
the exercise of other rights under the Mortgage; and
WHEREAS, Tenant wishes to obtain from Mortgagee certain assurances that
Tenant's possession of the Premises will not, subject to the terms and
conditions of this Agreement, be disturbed by reason of a foreclosure of the
lien of the Mortgage on the Real Property; and
WHEREAS, Tenant and Mortgagee are both willing to provide such
assurances to each other upon and subject to the terms and conditions of this
Agreement.
NOW, THEREFORE, in consideration of the above, the mutual promises
hereinafter set forth, and other good and valuable consideration, the receipt
and sufficiency of which are hereby acknowledged, the parties hereto mutually
agree as follows:
1. AFFIRMATION. Tenant hereby agrees that the Lease now is and shall be
subject and subordinate in all respects to the Mortgage and to all renewals,
modifications and extensions thereof until such time that the Mortgage is
released, satisfied or otherwise discharged, subject to the terms and conditions
of this Agreement. Landlord and Tenant hereby affirm that the Lease is in full
force and effect and that the Lease has not been modified or amended. Mortgagee
hereby confirms that it is the holder of the Note and the beneficiary of the
Mortgage and has full power and authority to enter into this Agreement.
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. - Page 2
2. ATTORNMENT AND NON-DISTURBANCE.
(a) So long as Tenant is not in default under the Lease (beyond
Tenant's receipt of notice from Landlord and any grace period granted Tenant
under the Lease to cure such default) as would entitle Landlord to terminate the
Lease or would cause, without any further action of Landlord, the termination of
the Lease or would entitle Landlord to dispossess Tenant thereunder then
Mortgagee agrees with Tenant that in the event the interest of Landlord shall be
acquired by Mortgagee or in the event Mortgagee comes into possession of or
acquires title to the Real Property by reason of foreclosure or foreclosure sale
or the enforcement of the Mortgage or the Note or other obligation secured
thereby or by a conveyance in lieu thereof, or as a result of any other means
then:
(i) Subject to the provisions of this Agreement, Tenant's
occupancy and possession of the Premises and Tenant's rights and
privileges under the Lease or any extensions, modifications or renewals
thereof or substitutions therefor (in accordance with the Lease and the
Mortgage) shall not be disturbed, diminished or interfered with by
Mortgagee during the term of the Lease (or any extensions or renewals
thereof provided for in the Lease);
(ii) Mortgagee will not join Tenant as a party defendant in
any action or proceeding for the purpose of terminating Tenant's
interest and estate under the Lease because of any default under the
Mortgage; and
(iii) The Lease shall continue in full force and effect and
shall not be terminated except in accordance with the terms of the
Lease.
(b) Tenant shall be bound to Mortgagee under all of the terms,
covenants and conditions of the Lease for the balance of the term thereof
remaining (and any extensions or renewals thereof which may be effected in
accordance with any option contained in the Lease) with the same force and
effect as if Mortgagee were the landlord under the Lease, and Tenant does hereby
agree to attorn to Mortgagee as its landlord, said attornment to be effective
and self-operative without the execution of any other instruments on the part of
either party hereto immediately upon Mortgagee's succeeding to the interest of
Landlord under the Lease. Upon request of Lender, Tenant shall execute and
deliver to Lender an agreement reaffirming such attornment.
(c) If the Mortgage is foreclosed and any party ("PURCHASER") other
than Mortgagee purchases the Premises and succeeds to the interest of Landlord
under the Lease, Tenant shall likewise be bound to Purchaser and Tenant hereby
covenants and agrees to attorn to Purchaser in accordance with all of the
provisions of this Agreement; provided, however, that Purchaser shall have
transmitted to Tenant a written document in recordable form, whereby Purchaser
agrees to recognize Tenant as its lessee under the Lease and agrees to be
directly bound to Tenant for the performance and observance of all the terms and
conditions of the Lease required to be performed or observed by Landlord
thereunder, subject to and in accordance with the terms of this Agreement.
(d) Mortgagee agrees that if Mortgagee shall succeed to the interest of
Landlord under the Lease as above provided, Mortgagee shall be bound to Tenant
under all of the terms, covenants, and conditions of the Lease, and Tenant
shall, from and after Mortgagee's succession to the interest of Landlord under
the Lease, have the same remedies against Mortgagee that Tenant might have had
under the Lease against Landlord if Mortgagee had not succeeded to the interest
of Landlord; provided, however, that Mortgagee (and Purchaser, as the case may
be) shall not be:
(i) liable for any act or omission of any prior lessor
(including Landlord) occurring prior to the date that Mortgagee or
Purchaser acquired title to the Premises;
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. - Page 3
(ii) subject to any offsets, counterclaims or defenses which
Tenant might have against any prior lessor (including Landlord);
(iii) bound by any previous payment of rent or additional rent
for a period greater than 1 month unless such prepayment shall have
been consented to in writing by Mortgagee;
(iv) bound by any amendment or modification of the Lease made
prior to the date Mortgagee or Purchaser succeeds to the interest of
Landlord without Mortgagee's written consent; or
(v) liable for the return of any security deposit unless such
deposit has been paid over to the Mortgagee.
The foregoing shall not be construed to modify or limit any right
Tenant may have at law or in equity against Landlord or any other prior
owner of the Real Property.
3. NOTICES. All notices required or permitted to be given pursuant to
this Agreement shall be in writing and shall be sent postage prepaid, by
certified mail, return receipt requested, or other nationally utilized overnight
delivery service. All notices shall be deemed delivered when received or
refused. Rejection or other refusal to accept or inability to deliver because of
changed address of which no notice has been given shall constitute receipt of
the notice, demand or request sent. Any such notice if given to Tenant shall be
addressed as follows:
________________________________________________
________________________________________________
________________________________________________
________________________________________________
________________________________________________
if given to Landlord shall be addressed as follows:
c/o Alexandria Real Estate Equities, Inc.
000 X. Xxx Xxxxxx Xxxxxx
Xxxxx 000
Xxxxxxxx, Xxxxxxxxxx 00000
Attention: General Counsel
if given to Mortgagee shall be addressed as follows:
________________________________________________
________________________________________________
________________________________________________
________________________________________________
4. SUCCESSORS AND ASSIGNS. This Agreement shall be binding upon and
inure to the benefit of the parties hereto and their respective successors and
assigns. The words "foreclosure" and "foreclosure sale" as used herein shall be
deemed to also include the acquisition of Landlord's estate in the Real Property
by voluntary deed, assignment or other conveyance or transfer in lieu of
foreclosure.
5. MODIFICATIONS TO LEASE. Tenant shall not modify or amend the Lease
or terminate the same, unless in accordance with the terms of the Lease, without
Mortgagee's prior written
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. -- Page 4
consent. If Mortgagee fails to provide Tenant with a written approval of the
proposed modification, amendment or termination within 10 business days after
notice to Mortgagee of such proposal, then Mortgagee shall be deemed to have
rejected such proposal.
6. ADDITIONAL AGREEMENTS. Tenant agrees that:
(a) it shall give Mortgagee copies of all notices of default that
Tenant gives to Landlord pursuant to the Lease in the same manner as they are
given to Landlord and no such notice or other communication shall be deemed to
be effective until a copy is given to Mortgagee;
(b) in all provisions of the Lease where Landlord is indemnified, the
reference to Landlord as an indemnitee shall be deemed to include Mortgagee and
any Purchaser and such agreement of indemnification shall survive the repayment
of the loan secured by the Mortgage, and, to the extent provided in the Lease,
the expiration or termination of the Lease;
(c) Tenant shall name Mortgagee and any Purchaser as additional
insureds and loss payees, as applicable and appropriate, on all insurance
policies required by the Lease;
(d) this Agreement satisfies any condition or requirement in the Lease
relating to the granting of a non-disturbance agreement by Mortgagee, and if
there are inconsistencies between the terms and provisions of this Agreement and
the terms and provisions of the Lease dealing with non-disturbance by Mortgagee,
the terms and provisions hereof shall be controlling; and
(e) Mortgagee shall have no liability under the Lease until Mortgagee
succeeds to the rights of Landlord under the Lease, and then only during such
period as Mortgagee is the landlord. At all times during which Mortgagee is
liable under the Lease, Mortgagee's liability shall be limited to Mortgagee's
interest in the Real Property.
7. MORTGAGEE CURE RIGHTS. If Landlord shall have failed to cure any
default within the time period provided for in the Lease (including any
applicable notice and grace periods) and Tenant exercises any right to terminate
the Lease, Mortgagee shall have an additional 30 days within which to cure such
default, or if such default cannot by the exercise of reasonable efforts by
Mortgagee be cured within such period, then such additional time as may be
reasonable necessary to effect such a cure (including, if necessary, sufficient
time to complete foreclosure proceedings) provided that Mortgagee shall commence
and thereafter diligently pursue remedies to cure such default. The Lease shall
not be terminated (i) while such remedies are being diligently pursued or (ii)
based upon a default which is personal to Landlord and therefore not susceptible
to cure by Mortgagee or which requires possession of the Premises to cure.
Mortgagee shall in no event be obligated to cure any such default by Landlord
unless it forecloses. Nothing in this Section 7 shall affect any of Tenant's
termination rights under the Lease due to casualty or condemnation.
8. DIRECTION TO PAY. Landlord hereby directs Tenant and Tenant agrees
to make all payments of amounts owed by Tenant under the Lease directly to
Mortgagee from and after receipt by Tenant of notice from Mortgagee directing
Tenant to make such payments to Mortgagee. (As between Landlord and Mortgagee,
the foregoing provision shall not be construed to modify any rights of Landlord
under any provisions of the Mortgage or any other instrument securing the Note).
9. CONDITIONAL ASSIGNMENT. With reference to any assignment by Landlord
of Landlord's interest in the Lease, or the rents payable thereunder,
conditional in nature or otherwise, which assignment is made to Mortgagee,
Tenant agrees that the execution thereof by Landlord, and the acceptance thereof
by Mortgagee, shall never be treated as an assumption by Mortgagee of any of the
obligations of Landlord under the Lease unless and until Mortgagee shall have
succeeded to the interest of Landlord. The foregoing sentence shall not affect
any of Tenant's rights against Landlord under the Lease.
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. -- Page 5
[SIGNATURES ON NEXT PAGE]
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. -- Page 6
IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be
properly executed by their duly authorized representatives as of the date first
above written.
TENANT: __________________________,
a _________________________
By: _________________________________________
Its: _________________________________
LANDLORD: [INSERT APPROPRIATE SIGNATURE BLOCK]
MORTGAGEE: ___________________________________________,
a
By: ___________________________________
Name: _____________________________
Its: _____________________________
Subordination Agreement 500 Arsenal Street/Acusphere, Inc. -- Page 7
EXHIBIT A TO SUBORDINATION AGREEMENT
Legal Description
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT I TO LEASE
NOTICE OF LEASE
This instrument is intended to provide record notice under
Massachusetts General Laws Chapter 183, Section 4, of the following lease (the
"Lease"):
LANDLORD: ARE-500 Arsenal Street, LLC, a Delaware limited
liability company
TENANT: Acusphere, Inc., a Delaware corporation
DATE OF EXECUTION: March __, 2001
PREMISES: Approximately 47,500 rentable square feet of space on
the first floor of the building located at 000 Xxxxxxx
Xxxxxx, Xxxxxxxxx, Xxxxxxxxxxxxx (the "Building"). The
Building is located on the parcel of land described in
Exhibit A attached to this Notice of Lease.
TERM: Beginning on the Commencement Date, as defined in
section 2 of the Lease, and expiring 120 months from
the first day of the first full month of the Term,
unless sooner terminated, as provided in the Lease.
EXTENSION RIGHTS: Tenant has the right to extend the Term of the Lease
for one extension period of five (5) years on terms and
conditions set forth in the Lease.
EXPANSION RIGHTS: Tenant has the right to lease up to an additional
20,000 rentable square feet of available space in the
Building, if any, on terms and conditions set forth in
the Lease.
This Notice of Lease does not modify the Lease and, in the event of any
inconsistency between this Notice of Lease and the Lease, the Lease shall
govern.
[THE REMAINDER OF THIS PAGE IS INTENTIONALLY LEFT BLANK.]
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 2
For Landlord's title, see the deed dated August 7, 2000 and recorded with the
Middlesex County (Southern District) Registry of Deeds in Book 31703, Page 530.
This Notice of Lease is executed under seal as of March __, 2001.
TENANT:
ACUSPHERE INC.
By: _________________________________
Name: _________________________________
Its: _________________________________
By: _________________________________
Name: _________________________________
Its: _________________________________
LANDLORD:
ARE-500 ARSENAL STREET, LLC
By: ALEXANDRIA REAL ESTATE EQUITIES, L.P.
managing member
By: ARE-QRS CORP.
general partner
By:_____________________________________
Name: __________________________________
Its: ___________________________________
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 3
STATE OF CALIFORNIA )
) SS.
COUNTY OF_________ )
On __________________, before me, _____________________, a Notary
Public, personally appeared _____________________, personally known to me (or
proved to me on the basis of satisfactory evidence) to be the person whose name
is subscribed to the within instrument and acknowledged to me that he/she
executed the same in his/her authorized capacity, and that by his/her signature
on the instrument the person, or the entity upon behalf of which the person
acted, executed the instrument.
WITNESS my hand and official seal.
__________________________________
Notary Public
__________________________________________
Notary Public
My commission expires:
Commonwealth of Massachusetts
County of ______________________
Before me today, ____________________________, President of Acusphere,
Inc. personally appeared and acknowledged the foregoing instrument to be his
free act and deed as President of Acusphere, Inc.
__________________________________________
Notary Public
My commission expires:
Commonwealth of Massachusetts
County of ______________________
Before me today, ____________________________, Treasurer of Acusphere,
Inc. personally appeared and acknowledged the foregoing instrument to be his/her
free act and deed as Treasurer of Acusphere, Inc.
__________________________________________
Notary Public
My commission expires:
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 4
EXHIBIT A TO NOTICE OF LEASE
The land in Watertown, Middlesex County, Massachusetts, being Parcel A and
Parcel C on a plan entitled Plan of Land in Watertown, Mass., dated April 1,
1977, Bradford, Xxxxxxx & Assoc. Inc., Engineers-Architects, recorded with
Middlesex South District Deeds, Book 13181, Page 435.
Parcel C contains .32 acres and Parcel A contains 4.95 acres, according to said
Plan. Together with the right to pass and xxxxxx over Parcel B on the aforesaid
Plan and together with and subject to rights in the forty (40) foot private way
shown on the aforesaid Plan as Birch Street, all as set forth in deed of Parcel
B, dated April 14, 1977, recorded Middlesex South District Deeds, Book 13181,
Page 435.
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 1
EXHIBIT J TO LEASE
NOTICE OF LEASE TERMINATION
Notice is hereby given, pursuant to the provisions of M.G.L. Chapter 183,
Section 4, of the termination on ___________________________, 20__, of a lease
dated March __, 2001, from ARE-500 Arsenal Street, LLC, a Delaware limited
liability company, as Landlord, to Acusphere, Inc., a Delaware corporation, as
Tenant, with respect to certain premises located at 000 Xxxxxxx Xxxxxx,
Xxxxxxxxx, Xxxxxxxxx Xxxxxx, Xxxxxxxxxxxxx, a Notice of Lease with respect to
which was recorded with the Middlesex South Registry of Deeds in Book ____, Page
____.
EXECUTED as a sealed instrument as of the __________ day of ________,
20__.
TENANT:
ACUSPHERE INC.
By: ______________________________
Name: ______________________________
Its: ______________________________
By: ______________________________
Name: ______________________________
Its: ______________________________
LANDLORD:
ARE-500 ARSENAL STREET, LLC
By: ALEXANDRIA REAL ESTATE EQUITIES, L.P.
managing member
By: ARE-QRS CORP.
general partner
By: _________________________
Name: _________________________
Its: _________________________
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 2
STATE OF CALIFORNIA )
) SS.
COUNTY OF_________ )
On __________________, before me, _____________________, a Notary
Public, personally appeared _____________________, personally known to me (or
proved to me on the basis of satisfactory evidence) to be the person whose name
is subscribed to the within instrument and acknowledged to me that he/she
executed the same in his/her authorized capacity, and that by his/her signature
on the instrument the person, or the entity upon behalf of which the person
acted, executed the instrument.
WITNESS my hand and official seal.
__________________________________
Notary Public
Notary Public
My commission expires:
Commonwealth of Massachusetts
County of ______________________
Before me today, ____________________________, President of Acusphere,
Inc. personally appeared and acknowledged the foregoing instrument to be his
free act and deed as President of Acusphere, Inc.
__________________________________________
Notary Public
My commission expires:
Commonwealth of Massachusetts
County of ______________________
Before me today, ____________________________, Treasurer of Acusphere,
Inc. personally appeared and acknowledged the foregoing instrument to be his/her
free act and deed as Treasurer of Acusphere, Inc.
__________________________________________
Notary Public
My commission expires:
Notice of Lease 500 Arsenal Street/Acusphere, Inc. - Page 1
SCHEDULE I TO LEASE
TANK AREA
See Attached
SCHEDULE I TO LEASE
000 Xxxxxxx Xxxxxx, Xxxxxxxxx, XX
Acusphere, Inc. - Proposed Location of Liquid Nitrogen Tank
[MAP OF TANK LOCATION]
WORK LETTER
THIS WORK LETTER dated March 30, 2001 (this "WORK LETTER") is made and
entered into by and between ARE-500 Arsenal Street, LLC, a Delaware limited
liability company ("LANDLORD"), and Acusphere, Inc., a Delaware corporation
("TENANT"), and is attached to and made a part of the Lease dated March 30, 2001
(the "LEASE"), by and between Landlord and Tenant. Any initially capitalized
terms used but not defined herein shall have the meanings given them in the
Lease.
1. GENERAL REQUIREMENTS
(a) TENANT'S AUTHORIZED REPRESENTATIVE. Tenant designates Xxxxxx
Xxxxxxx of Tenant and Xxxx XxXxxxxxx of Laboratory and Clean Room Consulting,
Inc. (either such individual acting alone, "TENANT'S REPRESENTATIVE"), as the
only persons authorized to act for Tenant pursuant to this Work Letter. Landlord
shall not be obligated to respond to or act upon any request, approval, inquiry
or other communication ("COMMUNICATION") from or on behalf of Tenant in
connection with this Work Letter unless such Communication is in writing from
Tenant's Representative. Tenant may change either Tenant's Representative at any
time upon not less than 5 business days advance written notice to Landlord. No
period set forth herein for any approval of any matter by Tenant's
Representative shall be extended by reason of any change in Tenant's
Representative. Neither Tenant nor Tenant's Representative shall be authorized
to direct Landlord's contractors in the performance of Landlord's Work (as
hereinafter defined).
(b) LANDLORD'S AUTHORIZED REPRESENTATIVE. Landlord designates
Xxxxxx Xxxxxxx and Xxxxxx Cleef (either such individual acting alone,
"LANDLORD'S REPRESENTATIVE") as the only persons authorized to act for Landlord
pursuant to this Work Letter. Tenant shall not be obligated to respond to or act
upon any request, approval, inquiry or other Communication from or on behalf of
Landlord in connection with this Work Letter unless such Communication is in
writing from Landlord's Representative. Landlord may change either Landlord's
Representative at any time upon not less than 5 business days advance written
notice to Tenant. No period set forth herein for any approval of any matter by
Landlord's Representative shall be extended by reason of any change in
Landlord's Representative. Landlord's Representative shall be the sole persons
authorized to direct Landlord's contractors in the performance of Landlord's
Work.
(c) DEVELOPMENT SCHEDULE. The schedule for design and development
of Landlord's Improvements (as defined below) and the Tenant Improvements (as
defined below), including without limitation the time periods for delivery of
construction documents and performance, shall be as provided in this Work
Letter, subject to adjustment as mutually agreed by the parties.
(d) ARCHITECTS, CONSULTANTS AND CONTRACTORS. Landlord and Tenant
hereby acknowledge and agree that: (i) Xxxxx Xxxxx and Dioli Architects, Inc.
shall be the architect (the "TI ARCHITECT") for the Tenant Improvements, and
(ii) The Richmond Group, Inc. shall be the general contractor.
2. TENANT IMPROVEMENTS.
(a) TENANT IMPROVEMENTS DEFINED. As used herein, "TENANT
IMPROVEMENTS" shall mean all improvements to the Project desired by Tenant of a
fixed and permanent nature, exclusive of the improvements indicated as
Landlord's improvements on Exhibit A attached hereto ("LANDLORD'S
IMPROVEMENTS"). Other than the Tenant Improvements and Landlord's Improvements,
Landlord shall not have any obligation whatsoever with respect to the finishing
of the Premises for Tenant's use and occupancy.
(b) TENANT'S SPACE PLANS. Tenant has delivered to Landlord and the
TI Architect schematic drawings and outline specifications (the "TI DESIGN
DRAWINGS") detailing Tenant's requirements for the Tenant Improvements. Landlord
has approved the TI Design Drawings.
(c) PRELIMINARY TI PLANS. Landlord has caused the TI Architect to
prepare and submit for Tenant's review and approval preliminary plans and
specifications for development of the Tenant Improvements (the "PRELIMINARY TI
PLANS"). Tenant has approved the Preliminary TI Plans.
(d) BUDGET. Not later than 10 business days following the date of
full execution hereof, Landlord shall obtain and deliver to Tenant a budget in
accordance with Section 5(a) hereof. At Tenant's election, and not later than 5
business days after Tenant's receipt of the budget, Tenant and Landlord shall
jointly develop a list of mutually acceptable value engineering items ("VE
ITEMS") for purpose of reducing the budget. Not later than 5 business days
thereafter Landlord shall obtain and deliver a revised budget incorporating the
VE Items.
(e) CONSTRUCTION DRAWINGS. Not later than 30 business days
following the delivery of the Budget to Tenant, Landlord shall cause the TI
Architect to prepare and deliver to Tenant for review and comment construction
plans, specifications and drawings for the Tenant Improvements ("TI CONSTRUCTION
DRAWINGS"), which TI Construction Drawings shall be prepared substantially in
accordance with the Preliminary TI Plans approved by Tenant as modified by the
VE Items. Tenant shall be solely responsible for ensuring that the TI
Construction Drawings reflect Tenant's requirements for the Tenant Improvements.
Tenant shall deliver its written comments on the TI Construction Drawings to
Landlord not later than 10 business days after Tenant's receipt of the same;
provided, however, that Tenant may not disapprove any matter that is consistent
with the Preliminary TI Plans approved by Tenant as modified by the VE Items
without submitting a Change Request. Landlord and the TI Architect shall
consider all such comments in good faith and shall, within 5 business days after
receipt, notify Tenant how Landlord proposes to respond to such comments and/or
commence the revisions of the TI Construction Drawings in accordance with the
comments which are acceptable to Landlord. Any disputes in connection with such
comments shall be resolved in accordance with Section 2(f) hereof. Once approved
by Tenant, subject to the provisions of Section 2(f) below, Landlord shall not
materially modify the TI Construction Drawings except as may be reasonably
required in connection with the issuance of the TI Permit (as defined in Section
3(b) below) pursuant to Section 3(b) below.
(f) DESIGN DISPUTES. Upon any dispute regarding the design of
Landlord's Improvements or the Tenant Improvements, which is not settled within
5 business days after notice of such dispute is delivered by one party to the
other, Landlord shall make the final decision regarding the design of Landlord's
Improvements, provided Landlord acts reasonably
and such final decision is either consistent with or a compromise between
Landlord's and Tenant's positions with respect to such dispute, and Tenant shall
make the final decision regarding the design of the Tenant Improvements,
provided Tenant acts reasonably and such final decision is either consistent
with or a compromise between Landlord's and Tenant's positions with respect to
such dispute, provided further that all costs and expenses resulting from any
such decision by Tenant shall be payable out of the TI Fund (as defined in
Section 5(d) below). Any changes to the TI Construction Drawings following
Landlord's and Tenant's approval of same requested by Tenant shall be processed
as provided in Section 4 hereof.
3. PERFORMANCE OF LANDLORD'S WORK.
(a) DEFINITION OF LANDLORD'S WORK. As used herein, "LANDLORD'S
WORK" shall mean the work of constructing Landlord's Improvements and the Tenant
Improvements.
(b) COMMENCEMENT AND PERMITTING OF LANDLORD'S WORK. Landlord at
its expense has obtained a building permit authorizing the construction of
Landlord's Improvements (the "BUILDING PERMIT"). Landlord shall commence
construction of the Tenant Improvements upon the later of (i) obtaining a
building permit (the "TI PERMIT") authorizing the construction of the Tenant
Improvements consistent with the TI Construction Drawings approved by Tenant, or
(ii) having sufficiently completed Landlord's Improvements such that the work of
constructing the Tenant Improvements can be efficiently prosecuted. The cost of
obtaining the TI Permit shall be payable from the TI Fund. Tenant shall assist
Landlord in obtaining the TI Permit. If any Governmental Authority having
jurisdiction over the construction of Landlord's Work or any portion thereof
shall impose terms or conditions upon the construction thereof which: (i) are
inconsistent with Landlord's obligations hereunder, (ii) increase the cost of
constructing Landlord's Work, or (iii) will materially delay the construction of
Landlord's Work, Landlord and Tenant shall reasonably and in good faith seek
means by which to mitigate or eliminate any such adverse terms and conditions.
(c) COMPLETION OF LANDLORD'S WORK. On or before the Target
Commencement Date (subject to Tenant Delays and Force-Majeure Delays), Landlord
shall substantially complete or cause to be substantially completed Landlord's
Work in a good and workmanlike manner and in accordance with the Building Permit
and the TI Permit subject, in each case, to Minor Variations and normal "punch
list" items of a non-material nature which do not interfere with the use of the
Premises ("SUBSTANTIAL COMPLETION"). Upon the Substantial Completion of
Landlord's Work, Landlord shall require the TI Architect and the general
contractor to execute and deliver, for the benefit of Tenant and Landlord, a
Certificate of Substantial Completion in the form of the American Institute of
Architects document G704. For purposes of this Work Letter, "MINOR VARIATIONS"
shall mean any completed modifications reasonably required: (i) to comply with
all applicable Legal Requirements and/or to obtain or to comply with any
required permit (including the Building Permit and the TI Permit); (ii) to
comply with any request by Tenant for modifications to Landlord's Work; (iii) to
comport with good design, engineering, and construction practices which are not
material; or (iv) to make reasonable adjustments for field deviations or
conditions encountered during the construction of Landlord's Work.
(d) SELECTION OF MATERIALS, ETC. Where more than one type of
material or structure is indicated on the TI Construction Drawings approved by
Landlord and Tenant, the option will
be within Landlord's sole discretion. As to all building materials and equipment
which Landlord is obligated to supply under this Work Letter, Landlord shall
select the manufacturer thereof in its sole discretion.
(e) DELIVERY OF THE PREMISES. When Landlord's Work is
Substantially Complete, subject to the remaining terms and provisions of this
Section 3(e), Tenant shall accept the Premises. Tenant's taking possession and
acceptance of the Premises shall not constitute a waiver of: (i) any warranty
with respect to workmanship (including installation of equipment) or material
(exclusive of equipment provided directly by manufacturers), (ii) any
non-compliance of Landlord's Work with Legal Requirements, or (iii) any claim
that Landlord's Work was not completed substantially in accordance with the TI
Construction Drawings (subject to Minor Variations and such other changes as are
permitted hereunder) (collectively, a "CONSTRUCTION DEFECT"). Tenant shall have
1 year after Substantial Completion within which to notify Landlord of any such
Construction Defect discovered by Tenant, and Landlord shall use reasonable
efforts to remedy or cause the responsible contractor to remedy any such
Construction Defect within 30 days thereafter. Notwithstanding the foregoing,
Landlord shall not be in default under the Lease if:
(i) with respect to the Tenant Improvements, the applicable
contractor, despite Landlord's reasonable efforts, fails to remedy such
Construction Defect within such 30-day period, in which case Landlord
shall have no further obligation with respect to such Construction
Defect other than to cooperate, at no cost to Landlord, with Tenant
should Tenant elect to pursue a claim against such contractor or the TI
Architect, provided that Tenant indemnifies and holds Landlord harmless
from and against any liability, loss, cost damage or expense in
connection with any such claim, and Landlord shall assign to Tenant as
reasonably necessary all rights Landlord may have against such
architect or contractor relating to a Construction Defect, or, if any
such rights are not assignable, permit Tenant to bring suit in
Landlord's name to enforce any claim or to seek any damages relating to
a Construction Defect, provided that Tenant indemnifies and holds
Landlord harmless from and against any liability, loss, cost, damage or
expense in connection with any such claim, or
(ii) with respect to Landlord's Improvements, the applicable
contractor, despite Landlord's reasonable efforts, fails to remedy such
Construction Defect within such 30-day period, but Landlord, within 30
days thereafter, commences and diligently and continuously prosecutes
such remedial action to completion.
Tenant shall be entitled to receive the benefit of all construction warranties
and manufacturer's equipment warranties relating to equipment installed in the
Premises. If requested by Tenant, Landlord shall attempt to obtain extended
warranties from manufacturers and suppliers of such equipment, but the cost of
any such extended warranties shall be borne solely out of the TI Fund. Landlord
shall diligently pursue any claims arising out of latent defects in the Project.
Landlord shall promptly undertake and complete, or cause to be completed, all
punch list items.
(f) COMMENCEMENT DATE DELAY. The Commencement Date shall occur on
Delivery (the "COMPLETION DATE"), except to the extent that Delivery shall have
been actually delayed by any one or more of the following causes (a "TENANT
DELAY"):
(i) Tenant's Representative was not available to give or
receive any Communication or to take any other action required to be
taken by Tenant hereunder;
(ii) Tenant's request for Change Requests (as defined in
Section 4(a) below) whether or not any such Change Requests are
actually performed;
(iii) Construction of any Change Requests;
(iv) Tenant's request for materials, finishes or installations
requiring unusually long lead times;
(v) Tenant's delay in reviewing, revising or approving plans
and specifications beyond the periods set forth herein;
(vi) Tenant's delay in providing information critical to the
normal progression of the Project. Tenant shall provide such
information as soon as reasonably possible, but in no event longer than
one week after receipt of any request for such information from
Landlord;
(vii) Tenant's delay in making payments to Landlord for Excess
TI Costs (as defined in Section 5(d) below); or
(viii) Any other act or, where Tenant has an obligation to
act, omission by Tenant or any Tenant Party, or persons employed by any
of such persons.
If the Commencement Date is delayed for any of the foregoing reasons, then
Landlord shall cause the TI Architect to certify the date on which the Tenant
Improvements would have been completed but for such Tenant Delay and such
certified date shall be the Commencement Date under the Lease.
4. CHANGES. Any changes requested by Tenant to Landlord's Improvements at any
time, or to the Tenant Improvements after the acceptance by Landlord and Tenant
of the Preliminary TI Plans, as modified by the VE Items, shall be requested and
instituted in accordance with the provisions of this Section 4 and shall be
subject to the written approval of Landlord and the TI Architect, such approval
not to be unreasonably withheld, conditioned or delayed.
(a) TENANT'S RIGHT TO REQUEST CHANGES. If Tenant shall request
changes to the Landlord's Improvements or if Tenant shall request changes to the
Tenant's Improvements after acceptance by Landlord and Tenant of the Preliminary
TI Plans, as modified by the VE Items (collectively, "CHANGES"), Tenant shall
request such Changes by notifying Landlord in writing in substantially the same
form as the AIA standard change order form (a "CHANGE REQUEST"), which Change
Request shall detail the nature and extent of any such Change. Such Change
Request must be signed by Tenant's Representative. Landlord shall, before
proceeding with any Change, use its best efforts to respond to Tenant as soon as
is reasonably possible with an estimate of: (i) the time it will take, and (ii)
the architectural and engineering fees and costs which will be incurred, to
analyze such Change Request (which costs shall be paid from the TI Fund to the
extent actually incurred, whether or not such change is implemented). Landlord
shall thereafter submit to Tenant in writing, within 5 business days of receipt
of the Change
Request (or such longer period of time as is reasonably required depending on
the extent of the Change Request), an analysis of the additional cost or savings
involved, including, without limitation, architectural and engineering costs and
the period of time, if any, that the Change will extend the date on which
Landlord's Work will be Substantially Complete. Any such delay in the completion
of Landlord's Work caused by a Change, including any suspension of Landlord's
Work while any such Change is being evaluated and/or designed, shall be a Tenant
Delay.
(b) IMPLEMENTATION OF CHANGES. If Tenant: (i) approves in writing
the cost or savings and the estimated extension in the time for completion of
Landlord's Work, if any, and (ii) deposits with Landlord any Excess TI Costs
required in connection with such Change, Landlord shall cause the approved
Change to be instituted. Notwithstanding any approval or disapproval by Tenant
of any estimate of the delay caused by such proposed Change, the TI Architect's
determination of the amount of Tenant Delay in connection with such Change shall
be final and binding on Landlord and Tenant.
5. COSTS.
(a) BUDGET FOR TENANT IMPROVEMENTS. Before the commencement of
construction of the Tenant Improvements, Landlord shall obtain a detailed
breakdown, by trade, of the costs incurred or which will be incurred in
connection with the design and construction of Tenant Improvements (the
"BUDGET"). The Budget shall be based upon the Preliminary TI Plans as modified
by the VE Items, approved by Tenant and shall include a payment to Landlord of
administrative rent equal ("ADMINISTRATIVE RENT") equal to 3% of the TI
Allowance (as hereinafter defined) for monitoring and inspecting the
construction of Tenant's Work, which sum shall be payable from the TI Fund. Such
Administrative Rent shall include, without limitation, all out-of-pocket costs,
expenses and fees incurred by or on behalf of Landlord arising from, out of, or
in connection with, such monitoring of the construction of the Tenant
Improvements, and shall be payable out of the TI Fund. If the Budget is greater
than the TI Allowance, Tenant shall deposit with Landlord the difference, in
cash, prior to the commencement of construction of the Tenant Improvements, for
disbursement by Landlord as described in Section 5(d).
(b) TI ALLOWANCE. Landlord shall provide to Tenant a tenant
improvement allowance ("TI ALLOWANCE") of $95 per rentable square foot of the
Premises or $4,512,500 based upon the Premises containing 47,500 rentable square
feet. Within 5 business days of receipt of the Budget from Landlord, Tenant
shall notify Landlord how much TI Allowance Tenant has elected to receive from
Landlord. Such election shall be final and binding on Tenant, and may not
thereafter be modified without Landlord's consent, which may be granted or
withheld in Landlord's sole and absolute discretion. The TI Allowance shall be
disbursed in accordance with this Work Letter.
(c) COSTS INCLUDABLE IN TI FUND. The TI Fund shall be used solely
for the payment of design and construction costs in connection with the
construction of the Tenant Improvements, including, without limitation, the cost
of preparing the TI Design Drawings, the Preliminary TI Plans, and the TI
Construction Drawings, all costs set forth in the Budget, including Landlord's
Administrative Rent, Landlord's out-of-pocket expenses, costs resulting from
Tenant Delays and the cost of Changes (collectively, "TI COSTS").
Notwithstanding anything to the contrary contained herein, the TI Fund shall not
be used to purchase any furniture, personal property or other non-Building
System materials or equipment, including, but
not limited to, biological safety cabinets and other scientific equipment not
incorporated into the Tenant Improvements.
(d) EXCESS TI COSTS. It is understood and agreed that Landlord is
under no obligation to bear any portion of the cost of any of the Tenant
Improvements except to the extent of the TI Allowance. If at any time and from
time-to-time, the remaining TI Costs under the Budget exceed the remaining
unexpended TI Allowance within 5 business days of notice from Landlord, Tenant
shall deposit with Landlord, as a condition precedent to Landlord's obligation
to complete the Tenant Improvements, 100% of the then current TI Cost in excess
of the remaining TI Allowance ("EXCESS TI COSTS"). If Tenant fails to deposit,
or is late in depositing, any Excess TI Costs amount with Landlord, Landlord
shall have all of the rights and remedies set forth in the Lease for nonpayment
of Rent (including, but not limited to, the right to interest at the Default
Rate and the right to assess a late charge), and for purposes of any litigation
instituted with regard to such amounts the same will be considered Rent. Such
deposit of Excess TI Costs, together with the remaining TI Allowance, is herein
referred to as the "TI FUND." Funds so deposited by Tenant shall be the first
thereafter disbursed to pay TI Costs. Notwithstanding anything to the contrary
set forth in this Section 5(d), Tenant shall be fully and solely liable for TI
Costs and the cost of Minor Variations in excess of the TI Allowance. If upon
Substantial Completion of the Tenant Improvements and the payment of all sums
due in connection therewith there remains any undisbursed TI Fund, within 30
days thereafter, Tenant shall be entitled to such undisbursed TI Fund solely to
the extent of any Excess TI Costs deposit Tenant has actually made with
Landlord.
(e) PAYMENT FOR LANDLORD'S IMPROVEMENTS. Landlord shall bear all
costs, expenses and fees incurred by or on behalf of Landlord in connection with
the construction of Landlord's Improvements, other than as a result of Tenant
requested Changes, subject to the terms hereof and the terms of the Lease.
6. TENANT ACCESS.
(a) TENANT'S ACCESS RIGHTS. Landlord hereby agrees to permit
Tenant access, at Tenant's sole risk and expense, to the Building (i) 30 days
prior to the Term Commencement Date to perform any work ("TENANT'S WORK")
required by Tenant other than Landlord's Work and provided that such Tenant's
Work is coordinated with the TI Architect and the general contractor, and
complies with the Lease and all other reasonable restrictions and conditions
Landlord may impose, and (ii) prior to the completion of Landlord's Work, to
inspect and observe work in process; all such access shall be during normal
business hours or at such other times as are reasonably designated by Landlord.
Notwithstanding the foregoing, Tenant shall have no right to enter onto the
Premises or the Project unless and until Tenant shall deliver to Landlord
evidence reasonably satisfactory to Landlord demonstrating that any insurance
reasonably required by Landlord in connection with such pre-commencement access
(including, but not limited to, any insurance which Landlord may require
pursuant to the Lease) is in full force and effect. Any entry by Tenant shall
comply with all established safety practices of Landlord's contractor and
Landlord until completion of Landlord's Work and acceptance thereof by Tenant.
(b) NO INTERFERENCE. Neither Tenant nor any Tenant Party shall
materially interfere with the performance of Landlord's Work, nor with any
inspections or issuance of final approvals
by Middlesex County or the Town of Watertown, and upon any such interference,
Landlord shall have the right to exclude Tenant and any Tenant Party from the
Premises and the Project until Substantial Completion of Landlord's Work.
(c) NO ACCEPTANCE OF PREMISES. The fact that Tenant may, with
Landlord's consent, enter into the Project prior to the date Landlord's Work is
Substantially Complete for the purpose of performing any Tenant's Work shall not
be deemed an acceptance by Tenant of possession of the Premises, but in such
event Tenant shall indemnify and hold Landlord harmless from any loss of or
damage to Tenant's property, completed work, fixtures, equipment, materials or
merchandise, and from liability for death of, or injury to, any person, caused
by the willful misconduct or negligence of Tenant or any Tenant Party.
7. NOTIFICATION OF DELAYS. Not less than once each calendar month from the
date of this Work Letter through the Term Commencement Date, Landlord shall
deliver to Tenant written notification of the number of days during the
immediately preceding calendar month Landlord's performance under this Work
Letter or the Lease was delayed as a result of Tenant Delays or delays arising
by reason of any Force Majeure as defined in Section 34 of the Lease (a "FORCE
MAJEURE DELAY"), which written notification shall also include a description of
the nature of such Tenant Delay or Force Majeure Delay.
8. MISCELLANEOUS
(a) CONSENTS. Whenever consent or approval of either party is
required under this Work Letter, that party shall not unreasonably withhold,
condition or delay such consent or approval, except as may be expressly set
forth herein to the contrary.
(b) MODIFICATION. No modification, waiver or amendment of this
Work Letter or of any of its conditions or provisions shall be binding upon
Landlord or Tenant unless in writing signed by Landlord and Tenant.
(c) COUNTERPARTS. This Work Letter may be executed in any number
of counterparts but all counterparts taken together shall constitute a single
document.
(d) GOVERNING LAW. This Work Letter shall be governed by,
construed and enforced in accordance with the internal laws of the state in
which the Premises are located, without regard to choice of law principles of
such State.
(e) TIME OF THE ESSENCE. Time is of the essence of this Work
Letter and of each and all provisions thereof.
(f) DEFAULT. Notwithstanding anything set forth herein or in the
Lease to the contrary, Landlord shall not have any obligation to perform any
work hereunder or to fund any portion of the TI Fund during any period Tenant is
in Default under the Lease.
(g) SEVERABILITY. If any term or provision of this Work Letter is
declared invalid or unenforceable, the remainder of this Work Letter shall not
be affected by such determination and shall continue to be valid and
enforceable.
(h) MERGER. All understandings and agreements, oral or written,
heretofore made between the parties hereto and relating to Landlord's Work and
Tenant's Work are merged in this Work Letter, which alone (but inclusive of
provisions of the Lease incorporated herein and the final approved constructions
drawings and specifications prepared pursuant hereto) fully and completely
expresses the agreement between Landlord and Tenant with regard to the matters
set forth in this Work Letter.
(i) ENTIRE AGREEMENT. This Work Letter is made as a part of and
pursuant to the Lease and, together with the Lease, constitutes the entire
agreement of the parties with respect to the subject matter hereof. This Work
Letter is subject to all of the terms and limitation set forth in the Lease, and
neither party shall have any rights or remedies under this Work Letter separate
and apart from their respective remedies pursuant to the Lease.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter
to be effective on the date first above written.
TENANT:
ACUSPHERE INC.
By: /s/ Xxxxxx X. Xxxxx
Name: Xxxxxx X. Xxxxx
Its: President and CEO
LANDLORD:
ARE-500 ARSENAL STREET, LLC
By: ALEXANDRIA REAL ESTATE EQUITIES, L.P.
managing member
By: ARE-QRS CORP.
general partner
By: /s/ Xxxxxxx X. Xxxxx
Name: Xxxxxxx X. Xxxxx
Title: Senior Vice President
Real Estate Legal Affairs
EXHIBIT A TO WORK LETTER
LANDLORD'S IMPROVEMENTS
See Attached
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 1
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
SITEWORK New Sidewalks, curbs, parking lot X
paving, storm drainage system per
approved site plans.
New exterior landscaping in parking X
areas and around building per
approved landscape plans.
Existing Xxxx Atlantic X
telephone/fiber conduit from Arsenal
Street into first floor telephone
room. New fiber conduit from MMFN
main trunk into building.
Existing medium pressure Boston Gas X
service into building. New meters
provided for tenant loads.
Existing sanitary sewer connection to X
MWRA system.
Existing domestic water and fire X
service to building.
STRUCTURE Floor live load capacity to be 150 X
psf on first floor, 80 psf on second
floor.
Live load increases for special X
tenant loads.
Existing clear heights from 11'4" to X
11'9"
New framing with lateral bracing in X
conformance with seismic code.
Structural upgrade to accommodate X
future roof-mounted tenant equipment.
Miscellaneous metal items (lintels, X
canopy framing, etc.) related to
shell building construction.
Miscellaneous metal items related X
to tenant fit-out.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 2
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
EXTERIOR New exterior walls on East Section X
consisting of aluminum, glass, and
spandrel panel system with brick
veneer features on light-gage metal
back-up system, insulation and vapor
barrier.
Existing brick walls on West Section X
and rear of building to be repointed
and repaired as needed.
New exterior brick, metal, and glass X
canopies at East and West tenant
entries.
Existing covered patio at cafeteria X
to be infilled with aluminum and
glass curtainwall system.
Existing metal roll-up doors at X
loading dock to be repaired as needed.
Existing concrete loading dock to be X
modified and repaired as needed.
ROOFING Roofing system consisting of X
fully-adhered single-ply EPDM with
rigid insulation. New roofing to be
provided on two-story section.
Walkway pads to tenant mechanical X
equipment as required.
Roof screen for tenant mechanical X
equipment as required.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 3
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
COMMON AREAS Finished first floor building lobby X
including quarry tile flooring, wood
or tilewall accents, drywall and
suspended ceilings and appropriate
accent lighting.
Refinished and expanded existing X
toilet rooms with thin-set ceramic
tile floors and walls,
drywall/acoustic ceilings, Corian or
equal lavatory counters.
Finished janitor, electrical and X
telephone closets.
Finished loading area with 2 truck X
bays and 1 trash compactor bay.
Finished first floor main electrical X
room and tenant electrical rooms.
Finished first floor lab waste system X
room and pit for tenants'
neutralization systems.
Doors and frames at common areas: X
hollow metal frames; hollow metal
doors at service areas, solid core
wood doors at other areas, and
heavy-duty lever hardware.
Doors and frames at tenant areas. X
Finished storage rooms for flammable X
and radioactive waste, including
venting, spill containment,
grounding, and Class 1 Division 1
electrical.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 4
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
ELEVATORS Existing passenger elevator with new X
interior finishes.
Existing freight lift. x
WINDOW TREATMENT Building standard blinds on all X
windows.
TENANT AREAS Finished drywall inside face of X
exterior wall, with vapor barrier and
xxxxx.
Existing masonry walls cleaned and X
ready to paint.
Partitions, ceilings, flooring, X
painting, finishes, doors, millwork,
and all office and laboratory
build-out within tenant area.
Lab casework and fume hoods. X
EQUIPMENT Warm/cold rooms, including X
roof-mounted condensers.
Air compressors, vacuum pumps, steam X
generators, bottled gas manifolds.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 5
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
PLUMBING Gas piping from meter to gas fired X
equipment in tenant mechanical room.
Gas piping from mechanical room to X
laboratory outlets and remote
equipment.
Roof drainage piping in East Section X
connecting to storm drain outside
foundation wall.
New double check valve assemblies and X
containment backfloor preventers in
water service room.
Domestic cold and hot water supply X
piping, with electric water heaters,
from meter to all toilet rooms and
vending area.
Sanitary sewer waste and vent from X
toilet rooms and vending area.
Laboratory waste and vent system from X
lab sinks, equipment, and floor
drains, including pumps as needed.
Laboratory wastewater pretreatment X
systems per MWRA standards.
Non-potable cold water system from X
water service room to all lab sinks
and equipment requiring cold water.
Electric or gas fired water heaters X
for non-potable water system.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 6
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
PLUMBING (CONT.) Non-potable hot water distribution to X
all laboratory sinks and equipment
requiring hot water.
Tempered water systems to eye wash X
unit sand emergency showers in
laboratory area.
Laboratory vacuum system and X
distribution piping to outlets.
Compressed air system and X
distribution piping to outlets.
Special gas cylinders and X
distribution piping to outlets.
Purified water system and X
distribution piping to outlets.
FIRE PROTECTION Combination sprinkler/standpipe X
system with fire department valves.
Alarm check valve and siamese X
connection.
Flow control valve assemblies and X
test drains.
Sprinkler coverage to all core areas. X
Flow switches, tamper switches, X
pressure switches.
Branch distribution. X
Modification of sprinkler piping and X
head layout to suit tenant build-out
package.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 7
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
HVAC Air-cooled chillers, pad-mounted for X
2-story section, roof-mounted for
1-story section, sized to meet tenant
general air supply cooling
requirements.
Gas-fired boilers, floor-mounted in X
tenant mechanical rooms, sized to
meet tenant general air supply
heating requirements.
All supplemental heating, cooling and X
humidification requirements for
specialized areas such as clean
rooms, animal rooms, etc.
Main Air Handling Units mounted on X
roof or in tenant mechanical rooms,
sized to meet tenant ventilation
requirements.
Hot and chilled water pumps and water X
treatment system located in tenant
mechanical rooms.
Air distribution system including X
main and branch ductwork, valves, fan
boxes and terminal units, registers,
diffusers, and grilles.
HVAC automation system X
Toilet exhaust and loading dock X
ventilation.
Existing rooftop DX units to be X
incorporated as appropriate into
tenant HVAC designs.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 8
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
XXXXXXXX Xxxxx Xxxx Xxxxxxxxxxx 0000X at X
480/277 volt 3-phase, located in
house electric room. House meter for
parking lot lighting and common
electric loads, separate meters for
feeds to Tenant Main Switchboards.
Tenant Main Switchboard(s) 480/277V, X
3-phase, sized to meet tenant loads,
located in tenant switchgear rooms.
Exterior pad mounted standby power X
generator, sized to meet tenant
requirements.
Transfer switch and standby power X
panels located in tenant switchgear
rooms, including feed from generator.
Tenant electric distribution from X
tenant switchgear rooms to include
main distribution conduit, dry type
transformers, remote 480/277-volt and
120-volt panels, feeders to tenant
lighting, HVAC equipment, lab
equipment, and outlets.
Exit/emergency life safety lighting X
consisting of battery packs in the
lobbies, loading dock, and common
mechanical spaces.
Life Safety lighting in tenant spaces X
to be battery packs or integral
emergency battery normally "ON"
lighting fixtures.
New City-connected addressable fire X
alarm system including code-required
devices in at lobbies, loading dock,
and common mechanical spaces.
000 Xxxxxxx Xxxxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
Page 9
EXHIBIT A TO WORK LETTER
LANDLORD'S WORK/TENANT IMPROVEMENTS
ELEMENT DESCRIPTION LANDLORD'S TENANT
WORK IMPROVEMENTS
ELECTRIC Fire alarm devices in tenant spaces X
(CONT'D) as required by code.
Existing perimeter card access and X
intrusion control system.
Additional security system components X
including equipment monitoring,
security cameras, etc.
Telecommunications cabling, outlets, X
equipment within tenant areas.
