OFFICE LEASE CHINA BASIN LANDING PWREF/MCC-CHINA BASIN L.L.C., a Delaware limited liability company, as Landlord, and LOOPNET, a California corporation, as Tenant.

Exhibit 10.7

EXECUTED
ORIGINAL

OFFICE LEASE

CHINA BASIN LANDING

PWREF/MCC-CHINA BASIN L.L.C.,

a Delaware limited liability company,

as Landlord,

and

LOOPNET,

a California corporation,

as Tenant.


				CHINA BASIN LANDING
				[LoopNet]

TABLE OF CONTENTS


	Page
ARTICLE 1 PREMISES, BUILDING, PROJECT, AND COMMON AREAS; RIGHT OF FIRST OFFER		4
ARTICLE 2 INITIAL LEASE TERM; OPTION TERM		6
ARTICLE 3 BASE RENT		8
ARTICLE 4 ADDITIONAL RENT		8
ARTICLE 5 USE OF PREMISES		14
ARTICLE 6 SERVICES AND UTILITIES		14
ARTICLE 7 REPAIRS		16
ARTICLE 8 ADDITIONS AND ALTERATIONS		17
ARTICLE 9 COVENANT AGAINST LIENS		19
ARTICLE 10 INSURANCE		19
ARTICLE 11 DAMAGE AND DESTRUCTION		21
ARTICLE 12 NONWAIVER		23
ARTICLE 13 CONDEMNATION		23
ARTICLE 14 ASSIGNMENT AND SUBLETTING		24
ARTICLE 15 SURRENDER OF PREMISES; OWNERSHIP AND REMOVAL OF TRADE FIXTURES		27
ARTICLE 16 HOLDING OVER		29
ARTICLE 17 ESTOPPEL CERTIFICATES		29
ARTICLE 18 SUBORDINATION		29
ARTICLE 19 DEFAULTS; REMEDIES		30
ARTICLE 20 COVENANT OF QUIET ENJOYMENT		33
ARTICLE 21 SECURITY DEPOSIT		33
ARTICLE 22 INTENTIONALLY DELETED		33
ARTICLE 23 SIGNS		33
ARTICLE 24 COMPLIANCE WITH LAW		34
ARTICLE 25 LATE CHARGES		34
ARTICLE 26 LANDLORD’S RIGHT TO CURE DEFAULT; PAYMENTS BY TENANT		34
ARTICLE 27 ENTRY BY LANDLORD		35
ARTICLE 28 TENANT PARKING		35
ARTICLE 29 MISCELLANEOUS PROVISIONS		36


EXHIBITS

A		OUTLINE OF PREMISES

A-l		FIRST OFFER SPACE

B		TENANT WORK LETTER

C		FORM OF NOTICE OF LEASE

D		RULES AND REGULATIONS

E		FORM OF TENANT’S ESTOPPEL CERTIFICATE


				CHINA BASIN LANDING
		(i)		[LoopNet]

INDEX


	Page(s)
Abatement Event		16
Additional Rent		8
Affiliate Assignee		5
Affiliates		27
Allowances		7
Alterations		17
Applicable Laws		34
Base Building		18
Base Rent		8
Base Year		8
Brokers		39
Building		4
Building Common Areas		4
Building Hours		14
China Basin Landing		4
Common Areas		4
Coordinator		39
Cost Pools		13
Designation Notice		17
Direct Expenses		9
Eligibility Period		16
Estimate		13
Estimate Statement		13
Estimated Excess		13
Excess		13
Expense Year		9
Force Majeure		38
Hazardous Material		11
Holidays		15
HVAC		14
Landlord		1
Landlord Parties		19
Landlord Repair Notice		22
Lease		1
Lease Commencement Date		6
Lease Expiration Date		6
Lease Term		6
Lease Year		6
Lines		40
Mail		38
Notices		38
Objection Notice		7
Operating Expenses		9
Option Rent		6
Option Rent Notice		7
Option Term		6
Original Improvements		20
Original Tenant		6
Other Improvements		41
Outside Agreement Date		7
Premises		4
Project		4
Project Common Areas		4
Proposition 13		12
Renovations		40
Rent		8
Rent Review Period		6
Review Period		24
Second Request		24


				CHINA BASIN LANDING
		(i)		[LoopNet]


	Page(s)
Security Deposit		33
Statement		13
Subject Space		24
Subleasing Costs		26
Summary		1
Tax Expenses		11
Tenant		1
Tenant Personal Property		28
Tenant’s Share		12
TMP		39
Transfer		26
Transfer Notice		24
Transfer Premium		26
Transferee		24
Transfers		24


				CHINA BASIN LANDING
		(ii)		[LoopNet]

CHINA BASIN LANDING

OFFICE LEASE

This Office Lease (the “Lease”), dated as of the date set forth in Section 1 of the Summary of Basic Lease Information (the “Summary”), below, is made by and between PWREF/MCC-CHINA BASIN L.L.C., a Delaware limited liability company (“Landlord”), and LOOPNET, a California corporation (“Tenant”).

SUMMARY OF BASIC LEASE INFORMATION


TERMS OF LEASE		DESCRIPTION
1.	Date:	January 8, 2003

2	Premises (Article 1).

	2.1 Building:	Wharfside Building, China Basin Landing, 000 Xxxxx Xxxxxx, Xxx Xxxxxxxxx, Xxxxxxxxxx 00000

	2.2 Premises:	Approximately 15,759 rentable square feet of space located in Suite 4000 on the fourth (4^th) floor of the Building, as further set forth in Exhibit A to the Office Lease.

3.	Lease Term (Article 2).

	3.1 Length of Term:	Five (5) years.

	3.2 Lease Commencement Date:	The earlier to occur of (i) the date upon which Xxxxxx first commences to conduct business in the Premises and (ii) three (3) days following the date upon which the Premises are Ready for Occupancy, which is anticipated to be March 1, 2003.

	3.3 Lease Expiration Date:	The last day of the month in which the 5^thanniversary of the Lease Commencement Date occurs.


				CHINA BASIN LANDING
				[LoopNet]


4.		Base Rent (Article 3):


				Annual
	Annual	Monthly		Rental Rate
Months of Lease	Base	Installment		per Rentable
Term	Rent	of Base Rent		Square Foot
1-3	$ 0.00	$	0.00	$	0.00
4-12	$346,698.00	$	28,891.50	$	22.00
13	$ 0.00	$	0.00	$	0.00
14-24	$362,457.00	$	30,204.75	$	23.00
25-36	$378,216.00	$	31,518.00	$	24.00
37-48	$393,975.00	$	32,831.25	$	25.00
49-60	$409,734.00	$	34,144.50	$	26.00


5.	Base Year (Article 4):	Calendar year 2003.

6.	Tenant’s Share (Article 4):	Approximately 2.16%.

7.	Permitted Use (Article 5):	General office use consistent with a first-class office building

8.	Security Deposit (Article 21):	$72,000.00.

9.	Parking (Article 28):	Three (3) unreserved parking passes

10.	Address of Tenant (Section 29.18):	LoopNet 0000 00^xx Xxxxxx, Ground Floor
		San Francisco,California 94110
		Attention: Mr. Xxxxxxx Xxxxx
		(Prior to Lease Commencement Date)

		and

		000 Xxxxx Xxxxxx
		Suite 4000
		San Francisco, California 94107
		Attention: Mr. Xxxxxxx Xxxxx
		(After Lease Commencement Date)

		and

		000 X. Xxxxxxxxxx Xxxxx
		Suite 118
		Monrovia, California 91016
		Attention: Xx. Xxxxx Xxxxxx
		(After Lease Commencement Date)


				CHINA BASIN LANDING
		-2-		[LoopNet]


11.	Address of Landlord	XxXxxxxx Cook & Co., LLC
	(Section 29.18):	China Basin Landing
		000 Xxxxx Xxxxxx, Xxxxx 000
		San Francisco, California 94107
		Attention: General Manager

		with copies to:

		XxXxxxxx Cook & Co., LLC
		0000 Xxxxxxxx Xxxxxxxxx
		Los Angeles, California 90036
		Attention: Xxxxxx X. Xxxx XXX

		and

		Xxxxx Xxxxxxx Xxxx Xxxxxx & Xxxxxxx LLP
		0000 Xxxxxx of the Stars, Suite 1800
		Los Angeles, California 90067
		Attention: Xxxxx X. Xxxxxx, Esq.

12.	Broker(s) (Section 29.24):	XxXxxxxx Cook & Co., LLC
		000 Xxxxx Xxxxxx, Xxxxx 000
		San Francisco, California 94107

		and

		CB Xxxxxxx Xxxxx, Inc.
		000 Xxxxx Xxxxx, Xxxxx 0000
		Los Angeles, California 90071
		Attention: Xx. Xxxxx Xxxxx


				CHINA BASIN LANDING
		-3-		[LoopNet]

ARTICLE 1

PREMISES, BUILDING, PROJECT, AND COMMON AREAS; RIGHT OF FIRST

OFFER

1.1 Premises, Building, Project and Common Areas.

1.1.1 The Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto and each floor or floors of the Premises has the number of rentable square feet as set forth in Section 2.2 of the Summary. Landlord and Tenant hereby stipulate and agree that the rentable area of the Premises is as set forth in Section 2.2 of the Summary, and such square footage shall not be subject to remeasurement or modification. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises in the “Building,” as that term is defined in Section 1.1.2, below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the “Project,” as that term is defined in Section 1.1.2, below. Except as specifically set forth in this Lease and in the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”), Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Xxxxxx also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Xxxxxx’s business, except as specifically set forth in this Lease and the Tenant Work Letter. The taking of possession of the Premises by Tenant shall conclusively establish that the Premises and the Building were at such time in good and sanitary order, condition and repair, subject to Tenant’s punchlist items. Subject to Landlord’s reasonable access control systems and procedures, the “Rules and Regulations,” as that term is defined in Section 5.2, below, and the terms of this Lease, Landlord shall allow Tenant access to the Premises twenty-four (24) hours per day, seven (7) days per week.

1.1.2 The Building and The Project. The Premises are a part of the building set forth in Section 2.1 of the Summary (the “Building”). The Building is part of an office project known as “China Basin Landing.” The term “Project,” as used in this Lease, shall mean (i) the Building and the Common Areas, (ii) the land (which is improved with landscaping, subterranean parking facilities and other improvements) upon which the Building and the Common Areas are located, (iii) the other office building located adjacent to the Building and the land upon which such adjacent office building is located, and (iv) at Landlord’s discretion, any additional real property, areas, land, buildings or other improvements added thereto outside of the Project.

1.1.3 Common Areas. Tenant shall have the non-exclusive right to use in common with other tenants in the Project, and subject to the rules and regulations referred to in Article 5 of this Lease, those portions of the Project which are provided, from time to time, for use in common by Landlord, Tenant and any other tenants of the Project (such areas, together with such other portions of the Project designated by Landlord, in its discretion, including certain areas designated for the exclusive use of certain tenants, or to be shared by Landlord and certain tenants, are collectively referred to herein as the “Common Areas”). The Common Areas shall consist of the “Project Common Areas” and the “Building Common Areas.” The term “Project Common Areas,” as used in this Lease, shall mean the portion of the Project reasonably designated as such by Landlord. The term “Building Common Areas,” as used in this Lease, shall mean the portions of the Common Areas located within the Building reasonably designated as such by Landlord. The Common Areas shall be maintained and operated in a manner consistent with the “Comparable Buildings,” as that term is defined in Section 2.2.5 of this Lease, and the use thereof shall be subject to such rules, regulations and restrictions as Landlord may make from time to time. Landlord reserves the right to close temporarily, make alterations or additions to, or change the location of elements of the Project and the Common Areas;


				CHINA BASIN LANDING
		-4-		[LoopNet]

provided, however, Landlord shall use commercially reasonable efforts not to materially interfere with Xxxxxx’s use of or access to the Premises in connection with such closures, alterations, additions and/or changes.

1.2 Right of First Offer. Landlord hereby grants to the Tenant named in the Summary (the “Original Tenant”) or an “Affiliate” of Tenant, as that term is defined in Section 14.8, below, which is an assignee of the Original Tenant (an “Affiliate Assignee”), a right of first offer with respect to certain space located on the fourth (4^th) floor of the Building, as designated on Exhibit A-1, attached hereto (the “First Offer Space”). Notwithstanding the foregoing, such first offer right of Tenant shall commence only following the expiration or earlier termination of the existing lease (including renewals) of the First Offer Space, and such right of first offer shall be subordinate to all rights of which are set forth in leases of space in the Project as of the date hereof, including any renewal, extension or expansion rights set forth as of the date hereof in such leases, regardless of whether such renewal, extension or expansion rights are executed strictly in accordance with their terms, or are commemorated pursuant to a lease amendment or a new lease (collectively, the “Superior Right Holders”) with respect to such First Offer Space. Tenant’s right of first offer shall be on the terms and conditions set forth in this Section 1.2.

1.2.1 Procedure for Offer. Landlord shall notify Tenant (the “First Offer Notice”) from time to time when the First Offer Space becomes available for lease to third parties, provided that no Superior Right Holder wishes to lease such space. Pursuant to such First Offer Notice, Landlord shall offer to lease to Tenant the First Offer Space. The First Offer Notice shall set forth the “First Offer Rent,” as that term is defined in Section 1.2.3 below, and the other economic terms upon which Landlord is willing to lease such space to Tenant.

1.2.2 Procedure for Acceptance. If Tenant wishes to exercise Xxxxxx’s right of first offer with respect to the space, then within five (5) business days of delivery of the First Offer Notice to Tenant, Tenant shall deliver notice to Landlord of Tenant’s election to exercise its right of first offer with respect to the entire space described in the First Offer Notice on the terms contained in such notice. If Tenant does not so notify Landlord within the five (5) business day period, then Landlord shall be free to lease the space described in the First Offer Notice to anyone to whom Landlord desires on any terms Landlord desires. Notwithstanding anything to the contrary contained herein, Tenant must elect to exercise its right of first offer, if at all, with respect to all of the First Offer Space, and Tenant may not elect to lease only a portion thereof.

1.2.3 First Offer Space Rent. The “Rent,” as that term is defined in Section 4.1, below, payable by Tenant for the First Offer Space (the “First Offer Rent”) shall be equal to the “Fair Rental Value,” as that term is defined in Section 2.2.2 of this Lease, as of the “First Offer Commencement Date,” as that term is defined in Section 1.2.5, below.

1.2.4 Construction In First Offer Space. Tenant shall take the First Offer Space in its “as is” condition, subject to the payment of a tenant improvement allowance, if any, as a part of the Fair Rental Value determination, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.

1.2.5 Amendment to Lease. If Tenant timely exercises Tenant’s right to lease the First Offer Space as set forth herein, Landlord and Tenant shall within fifteen (15) days thereafter execute an amendment to this Lease for such First Offer Space upon the terms and conditions as set forth in the First Offer Notice and this Section 1.2. Tenant shall commence payment of Rent for the First Offer Space, and the term of the First Offer Space shall commence upon the date of delivery of the First Offer Space to Tenant (the “First Offer Commencement Date”) and terminate on the date set forth in the First Offer Notice.

1.2.6 Termination of Right of First Offer. The rights contained in this Section 1.2 shall be personal to the Original Tenant or its Affiliate Assignee, and may only be exercised by the Original Tenant or its Affiliate Assignee (and not any other assignee, sublessee or other transferee of the Original Tenant’s interest in this Lease) if the Original Tenant or its Affiliate Assignee occupies the entire Premises. The right of first offer granted herein shall terminate as to particular First Offer Space upon the failure by Tenant to exercise its right of first offer with respect to such First Offer Space as offered by Xxxxxxxx; provided, however, that if Landlord fails to lease such First Offer Space to a third party during the one hundred eighty


				CHINA BASIN LANDING
		-5-		[LoopNet]

(180) day period immediately following Tenant’s failure to exercise its right of first offer, then Tenant shall again have a right of first offer to lease such space in accordance with the terms of this Section 1.2. Further, in the event Tenant fails to lease such First Offer Space, and Landlord consummates a lease with a third party for such First Offer Space (an “Interim Lease”), following the expiration (including renewals) or earlier termination of the Interim Lease (provided the Lease Term has not expired), Tenant shall again have a right of first offer to lease such space in accordance with the terms of this Section 1.2. Tenant shall not have the right to lease First Offer Space, as provided in this Section 1.2. if, as of the date of the attempted exercise of any right of first offer by Xxxxxx, or as of the scheduled date of delivery of such First Offer Space to Tenant, Tenant is in default under this Lease or Tenant has previously been in default under this Lease more than once.

ARTICLE 2

INITIAL LEASE TERM; OPTION TERM

2.1 Initial Lease Term. The terms and provisions of this Lease shall be effective as of the date of this Lease. The term of this Lease (the “Lease Term”) shall be as set forth in Section 3.1 of the Summary, shall commence on the date set forth in Section 3.2 of the Summary (the “Lease Commencement Date”), and shall terminate on the date set forth in Section 3.3 of the Summary (the “Lease Expiration Date”) unless this Lease is sooner terminated as hereinafter provided. For purposes of this Lease, the term “Lease Year” shall mean each consecutive twelve (12) month period during the Lease Term; provided, however, that the first Lease Year shall commence on the Lease Commencement Date and end on the last day of the eleventh month thereafter and the second and each succeeding Lease Year shall commence on the first day of the next calendar month; and further provided that the last Lease Year shall end on the Lease Expiration Date. At any time during the Lease Term, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit C, attached hereto, as a confirmation only of the information set forth therein, which Tenant shall execute and return to Landlord within five (5) days of receipt thereof.

2.2 Option Term.

2.2.1 Landlord hereby grants the original Tenant named in the Summary (the “Original Tenant”) or an Affiliate Assignee”), one (1) option to extend the Lease Term for a period of five (5) years (the “Option Term”), which option shall be exercisable only by written notice delivered by Tenant to Landlord as provided below, provided that, as of the date of delivery of such notice, Tenant is not in default under this Lease beyond any applicable cure period set forth in this Lease, and has not previously been in default under this Lease beyond any applicable cure period set forth in this Lease more than once. Upon the proper exercise of such option to extend, and provided that, as of the end of the initial Lease Term, Tenant is not in default under this Lease, beyond any applicable cure period set forth in this Lease, and has not previously been in default under this Lease beyond any applicable cure period set forth in this Lease more than once, the Lease Term, as it applies to the Premises, shall be extended for a period of five (5) years. The rights contained in this Section 2.2 shall be personal to the Original Tenant and any Affiliate Assignee and may only be exercised by the Original Tenant or an Affiliate Assignee (and not any other assignee, sublessee or transferee of the Original Tenant’s interest in this Lease) if the Original Tenant or an Affiliate Assignee occupies the entire Premises. In the event Tenant fails to timely exercise the right set forth in this Section 2.2, this Section 2.2 shall be null and void and of no further force or effect.

2.2.2 Option Rent. The annual rent payable by Tenant during the Option Term (the “Option Rent”) shall be equal to the “Fair Rental Value” for the Premises as of the commencement date of the Option Term. The “Fair Rental Value” shall be equal to the annual rent (including additional rent and considering any “base year” or “expense stop” applicable thereto), including all escalations, at which tenants are leasing non-sublease, non-encumbered, non-equity, non-renewal commercial office space comparable in size, location and quality to the Premises, for a comparable lease term, in an arm’s length transactions consummated during the ten (10) month period (the “Rent Review Period”) prior to the date Landlord delivers the “Option Rent Notice,” as that term is defined in Section 2.2.3, below, or the First Offer Commencement Date, as the case may be, which comparable commercial office space is located in the Project, or if there are not a sufficient number of comparable transactions in the Project than in “Comparable Buildings,” as that term is defined in Section 2.2.5, below, taking into


				CHINA BASIN LANDING
		-6-		[LoopNet]

consideration only the following concession: any tenant improvements or allowances (the “Allowances”) provided or to be provided for such comparable space, taking into account, and deducting, the value of the existing improvements in the Premises or the First Offer Space, as the case may be, such value to be based upon the age, quality and layout of the improvements and the extent to which the same can be utilized by a general office user. If in determining the Option Rent a tenant improvement allowance is granted as set forth hereinabove, Landlord may, at Landlord’s sole option, elect any or a portion of the following: (A) to grant some or all of the Allowances to Tenant in the form as described above (i.e., as an improvement allowance), and (B) to adjust the rental rate component of the Option Rent to be an effective rental rate which takes into consideration the total dollar value of the Allowances (in which case the Allowances evidenced in the effective rental rate shall not be granted to Tenant).

2.2.3 Exercise of Options. The option contained in this Section 2.2 shall be exercised by Tenant, if at all, and only by Xxxxxx delivering irrevocable written notice of its exercise thereof to Landlord not less than seven (7) months prior to the expiration of the initial Lease Term. In the event that Tenant timely exercises the renewal option, then Landlord shall deliver notice (the “Option Rent Notice”) to Tenant not less than five (5) months prior to the expiration of the initial Lease Term, setting forth the Option Rent. Tenant may, at Tenant’s option, object to the Option Rent contained in the Option Rent Notice, by written notice to Landlord (the “Objection Notice”) within thirty (30) days following Tenant’s receipt of the Option Rent Notice, in which case the parties shall follow the procedure, and the Option Rent shall be determined, as set forth in Section 2.2.4, below. In the event that Tenant shall fail to timely deliver an Objection Notice, the Option Rent set forth in the Option Rent Notice shall be the Option Rent due during the Option Term and Tenant shall have no right to contest the same. Landlord and Tenant shall execute an amendment setting forth the terms and conditions of the Option Term.

2.2.4 Determination of Option Rent. In the event Tenant timely and appropriately objects to the Option Rent or the First Offer Rent, as the case may be, Landlord and Tenant shall attempt to agree upon the Option Rent or the First Offer Rent, as the case may be, using their best good-faith efforts. If Landlord and Tenant fail to reach agreement within ten (10) business days following Tenant’s objection to the Option Rent or the First Offer Rent, as the case may be (the “Outside Agreement Date”), then each party shall make a separate determination of the Option Rent or the First Offer Rent, as the case may be, within five (5) business days after the applicable Outside Agreement Date, and such determinations shall be submitted to arbitration in accordance with Sections 2.2.4.1 through 2.2.4.7 below.

2.2.4.1 Landlord and Tenant shall each appoint one arbitrator who shall be a real estate broker who shall have been active over the five (5) year period ending on the date of such appointment in the leasing of first class commercial office projects in the South of Market Street area of San Francisco, California. The determination of the arbitrators shall be limited solely to the issue of whether Xxxxxxxx’s or Tenant’s submitted Option Rent or the First Offer Rent, as the case may be, is the closest to the actual Option Rent or the First Offer Rent, as the case may be, as determined by the arbitrators, taking into account the requirements of Section 2.2.2 (and 1.2.3, as applicable) of this Lease. Each such arbitrator shall be appointed within fifteen (15) days after the applicable Outside Agreement Date.

2.2.4.2 The two (2) arbitrators so appointed shall within ten (10) days of the date of the appointment of the last appointed arbitrator agree upon and appoint an independent third arbitrator who shall be qualified under the same criteria set forth hereinabove for qualification of the initial two (2) arbitrators.

2.2.4.3 The three (3) arbitrators shall within thirty (30) days of the appointment of the third arbitrator reach a decision as to whether the parties shall use Landlord’s or Tenant’s submitted Option Rent or the First Offer Rent, as the case may be, and shall notify Landlord and Tenant thereof.

2.2.4.4 The decision of the majority of the three (3) arbitrators shall be binding upon Landlord and Tenant.

2.2.4.5 If either Landlord or Tenant fails to appoint an arbitrator within fifteen (15) days after the applicable Outside Agreement Date, then the arbitrator appointed by


				CHINA BASIN LANDING
		-7-		[LoopNet]

one of them shall reach a decision, notify Landlord and Tenant thereof, and such arbitrator’s decision shall be binding upon Landlord and Tenant.

2.2.4.6 If the two (2) arbitrators fail to agree upon and appoint a third arbitrator, or if both parties fail to appoint an arbitrator, then the appointment of the third arbitrator or any arbitrator shall be dismissed and the matter to be decided shall be forthwith submitted to arbitration under the provisions of the American Arbitration Association, but subject to the instruction set forth in this Section 2.2.4.

2.2.4.7 The cost of the arbitration shall be paid by Landlord and Tenant equally.

2.2.5 For purposes of this Lease, “Comparable Buildings” shall mean first-class commercial office projects located in San Francisco, California with similar locations and with views and amenities similar to the Building.

ARTICLE 3

BASE RENT

Tenant shall pay, without prior notice or demand, to Landlord or Landlord’s agent at the management office of the Project, or, at Landlord’s option, at such other place as Landlord may from time to time designate in writing, by a check for currency which, at the time of payment, is legal tender for private or public debts in the United States of America, base rent (“Base Rent”) as set forth in Section 4 of the Summary, payable in equal monthly installments as set forth in Section 4 of the Summary in advance on or before the first day of each and every calendar month during the Lease Term, without any setoff or deduction whatsoever, except as specifically set forth in this Lease. The Base Rent for the first full month of the Lease Term shall be paid at the time of Xxxxxx’s execution of this Lease. If any Rent payment date (including the Lease Commencement Date) falls on a day of the month other than the first day of such month or if any payment of Rent is for a period which is shorter than one month, the Rent for any fractional month shall accrue on a daily basis for the period from the date such payment is due to the end of such calendar month or to the end of the Lease Term at a rate per day which is equal to 1/365 of the applicable annual Rent. All other payments or adjustments required to be made under the terms of this Lease that require proration on a time basis shall be prorated on the same basis.

ARTICLE 4

ADDITIONAL RENT

4.1 General Terms. In addition to paying the Base Rent specified in Article 3 of this Lease, Tenant shall pay, commencing after the expiration of the “Base Year”, “Tenant’s Share” of the annual “Direct Expenses,” as those terms are defined in Sections 4.2.1, 4.2.6 and 4.2.2 of this Lease, respectively, which are in excess of the amount of Direct Expenses applicable to the Base Year; provided, however, that in no event shall any decrease in Direct Expenses for any “Expense Year,” as that term is defined in Section 4.2.6 below, below Direct Expenses for the Base Year entitle Tenant to any decrease in Base Rent or any credit against sums due under this Lease. Such payments by Xxxxxx, together with any and all other amounts payable by Tenant to Landlord pursuant to the terms of this Lease, are hereinafter collectively referred to as the “Additional Rent”, and the Base Rent and the Additional Rent are herein collectively referred to as “Rent.” All amounts due under this Article 4 as Additional Rent shall be payable for the same periods and in the same manner as the Base Rent. Without limitation on other obligations of Tenant which survive the expiration of the Lease Term, the obligations of Tenant to pay the Additional Rent provided for in this Article 4 shall survive the expiration of the Lease Term; provided, however, that other than “Tax Expenses,” as that term is defined in Section 4.2.5.1, below, levied by a governmental authority, or utility charges, Tenant shall not be responsible for Tenant’s Share of any Direct Expenses attributable to any “Expense Year” which are first billed to Tenant more than two (2) years after the Lease Expiration Date.

4.2 Definitions of Key Terms Relating to Additional Rent. As used in this Article 4, the following terms shall have the meanings hereinafter set forth:

4.2.1 “Base Year” shall mean the period set forth in Section 5 of the Summary.


				CHINA BASIN LANDING
		-8-		[LoopNet]

4.2.2 “Direct Expenses” shall mean “Operating Expenses” and “Tax Expenses.”

4.2.3 “Expense Year” shall mean each calendar year in which any portion of the Lease Term falls, through and including the calendar year in which the Lease Term expires, provided that Landlord, upon notice to Tenant, may change the Expense Year from time to time to any other twelve (12) consecutive month period, and, in the event of any such change, Xxxxxx’s Share of Direct Expenses shall be equitably adjusted for any Expense Year involved in any such change.

4.2.4 “Operating Expenses” shall mean all expenses, costs and amounts of every kind and nature which Landlord pays or accrues during any Expense Year because of or in connection with the ownership, management, maintenance, security, repair, replacement, restoration or operation of the Project, or any portion thereof. Without limiting the generality of the foregoing, Operating Expenses shall specifically include any and all of the following: (i) the cost of supplying all utilities, the cost of operating, repairing, maintaining, and renovating the utility, telephone, mechanical, sanitary, storm drainage, and elevator systems, and the cost of maintenance and service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections and the cost of contesting any governmental enactments which may affect Operating Expenses, and the costs incurred in connection with a transportation system management program or similar program; (iii) the cost of all insurance carried by Landlord in connection with the Project; (iv) the cost of landscaping, relamping, and all supplies, tools, equipment and materials used in the operation, repair and maintenance of the Project, or any portion thereof; (v) costs incurred in connection with the repair, maintenance or operation of parking areas servicing the Building; (vi) fees and other costs, including management fees (provided, however, such management fee shall not materially exceed the management fees charged by landlords of other comparable office buildings in San Francisco, California, and which are managed by a first class management company with a general reputation for excellence and integrity), consulting fees, reasonable legal fees and accounting fees, of all contractors and consultants in connection with the management, operation, maintenance and repair of the Project; (vii) payments under any equipment rental agreements and the fair rental value of any management office space; (viii) wages, salaries and other compensation and benefits, including taxes levied thereon, of all persons engaged in the operation, maintenance and security of the Project; (ix) costs under any instrument pertaining to the sharing of costs by the Project; (x) operation, repair, maintenance and replacement of all systems and equipment and components thereof of the Building; (xi) the cost of janitorial, alarm, security and other services, replacement of wall and floor coverings, ceiling tiles and fixtures in common areas, maintenance and replacement of curbs and walkways, exterior windows and walls, repair to roofs and re-roofing, waterproofing and sealing of garage, foundation and basement areas; (xii) amortization (including interest, at a commercially reasonable rate, on the unamortized cost) of the cost of acquiring or the rental expense of personal property used in the maintenance, operation and repair of the Project, or any portion thereof; (xiii) the cost of capital improvements or other costs incurred in connection with the Project (A) which are intended as a labor savings device or to effect other economies in the operation or maintenance of the Project, or any portion thereof, (B) that are required to comply with present or anticipated conservation programs, (C) which are replacements or modifications of nonstructural items located in the Common Areas required to keep the Common Areas in good order or condition, or (D) that are required under any governmental law or regulation, except for capital improvements or costs to remedy a condition existing as of the Lease Commencement Date which a federal, state or municipal governmental authority, if it had knowledge of such condition existing as of the Lease Commencement Date, would have then required to be xxxxxx xx pursuant to governmental laws or regulations in their form existing as of the Lease Commencement Date; provided, however, that any capital expenditure shall be amortized with interest (at a commercially reasonable rate incurred by Landlord) over its useful life as Landlord shall reasonably determine; (xiv) costs, fees, charges or assessments imposed by, or resulting from any mandate imposed on Landlord by, any federal, state or local government for fire and police protection, trash removal, community services, or other services which do not constitute “Tax Expenses” as that term is defined in Section 4.2.5, below; and (xv) payments under any easement, license, operating agreement, declaration, restrictive covenant, or instrument pertaining to the sharing of costs by the Building. If Landlord is not furnishing any particular work or service (the cost of which, if performed by Xxxxxxxx, would be included in Operating Expenses) to a tenant who has undertaken to perform such work or service in lieu of the performance thereof by Landlord, Operating Expenses shall be deemed to be increased by an amount equal to the additional Operating Expenses which would


				CHINA BASIN LANDING
		-9-		[LoopNet]

reasonably have been incurred during such period by Landlord if it had at its own expense furnished such work or service to such tenant. If the Project is not at least ninety-five percent (95%) occupied during all or a portion of the Base Year or any Expense Year, Landlord shall elect to make an appropriate adjustment to the components of Operating Expenses for such year to determine the amount of Operating Expenses that would have been incurred had the Project been ninety-five percent (95%) occupied; and the amount so determined shall be deemed to have been the amount of Operating Expenses for such year. Operating Expenses for the Base Year shall not include market-wide labor-rate increases due to extraordinary circumstances, including, but not limited to, boycotts and strikes, and utility rate increases due to extraordinary circumstances including, but not limited to, conservation surcharges, boycotts, embargoes or other shortages, or amortized costs relating to capital improvements. In no event shall the components of Direct Expenses for any Expense Year related to electrical costs be less than the components of Direct Expenses related to electrical costs in the Base Year. Landlord shall not collect Operating Expenses from Tenant and all other tenants in the Building in an amount in excess of what Landlord incurs for the items included in Operating Expenses. If Landlord does not carry earthquake insurance for the Building during the Base Year but subsequently obtains earthquake insurance for the Building during the Lease Term, then from and after the date upon which Landlord obtains such earthquake insurance and continuing throughout the period during which Landlord maintains such insurance, Operating Expenses for the Base Year shall be deemed to be increased by the amount of the premium Landlord would have incurred had Landlord maintained such insurance for the same period of time during the Base Year as such insurance is maintained by Landlord during such subsequent Expense Year. Notwithstanding the foregoing, Operating Expenses for purposes of this Lease shall not include the following:

(i) costs of leasing commissions, attorneys’ fees and other costs and expenses incurred in connection with negotiations or disputes with present or prospective tenants or other occupants of the Building;

(ii) costs (including permit, license and inspection costs) incurred in renovating or otherwise improving, decorating or redecorating rentable space for other tenants or vacant rentable space;

(iii) except as otherwise specifically provided in this Section 4.2.4, costs incurred by Landlord for capital repairs, improvements, equipment and alterations to the Building or Project (including, but not limited to “Renovations” as that term is defined in Section 29.30 of this Lease, to the extent such Renovations are considered to be capital improvements);

(iv) costs of services or other benefits which are either not offered to Tenant or for which Tenant is charged directly, but which are provided to other tenants of the Building without a separate charge;

(v) except for a property management fee, costs of overhead or profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for services in connection with the Building to the extent the same unreasonably exceeds the cost of such services rendered by qualified, first class unaffiliated third parties on a competitive basis;

(vi) except as otherwise specifically provided in this Section 4.2.4, costs of interest on debt or amortization on any mortgages, and principal payments and other charges, costs and expenses payable under any mortgage, if any;

(vii) costs of any compensation and employee benefits paid to clerks, attendants or other persons in a commercial concession operated by Landlord, except the Building parking facility;

(viii) marketing costs, legal fees, space planner’s fees, and advertising and promotional expenses and brokerage fees incurred in connection with the original development, subsequent improvement, or original or future leasing of the Building;

(ix) any bad debt loss, rent loss, or reserves for bad debts or rent loss;

(x) tax penalties incurred as a result of Landlord’s negligence, inability or unwillingness to make payments or file returns when due;


				CHINA BASIN LANDING
		-10-		[LoopNet]

(xi) all items and services for which Tenant or any other tenant in the Building reimburses Landlord or which Landlord provides selectively to one or more tenants (other than Tenant) without reimbursement;

(xii) fees and reimbursements payable to Landlord (including its parent organization, subsidiaries and/or affiliates) or by Landlord for management of the Building which unreasonably exceeds the amount which would normally be paid to a company, in connection with the management of comparable buildings, with a general reputation for excellence and integrity, at “arms length” and which is not, directly or indirectly, affiliated with Landlord;

(xiii) costs arising from the gross negligence or willful misconduct of Landlord;

(xiv) costs incurred to comply with laws relating to the removal of hazardous material (as defined under applicable law) and asbestos containing material (collectively, “Hazardous Material”) which was in existence in the Building or on the Project prior to the Lease Commencement Date, and was of such a nature that a federal, State or municipal governmental authority, if it had then had knowledge of the presence of such Hazardous Material, in the state, and under the conditions that it then existed in the Building or on the Project, would have then required the removal of such Hazardous Material or other remedial or containment action with respect thereto; costs incurred with respect to any Hazardous Material which was in existence in the Building or on the Project prior to the Lease Commencement Date, and which Landlord is obligated to xxxxx or remediate after the Lease Commencement Date in accordance with an abatement or remediation plan which was in effect prior to the Lease Commencement Date; and costs incurred to remove, remedy, contain, or treat Hazardous Material, which Hazardous Material is brought into the Building or onto the Project after the date hereof by Landlord or any other tenant of the Project and is of such a nature, at that time, that a federal, State or municipal governmental authority, if it had then had knowledge of the presence of such Hazardous Material, in the state and under the conditions, that it then exists in the Building or on the Project, would have then required the removal of such Hazardous Material or other remedial or containment action with respect thereto;

(xv) any liability, damage, award or judgment for injury or death to persons, or for property damage;

(xvi) costs, other than those incurred in ordinary maintenance and repair, for sculpture, paintings, fountains or other objects of art; and

(xvii) costs associated with the operation of the business of Landlord, as the same are distinguished from the costs of operation of the Premises or Project, including company accounting and legal matters, costs of defending any lawsuits with any mortgagee, costs of selling, syndicating, financing, mortgaging or hypothecating any of Landlord’s interest in the Premises or Project, costs (including attorney fees and costs of settlement judgments and payments in lieu thereof) arising from claims, disputes or potential disputes in connection with potential or actual claims, litigation or arbitrations respecting Landlord and/or the Project.

4.2.5 Taxes.

4.2.5.1 “Tax Expenses” shall mean all federal, state, county, or local governmental or municipal taxes, fees, charges or other impositions of every kind and nature, whether general, special, ordinary or extraordinary, (including, without limitation, real estate taxes, general and special assessments, transit taxes, leasehold taxes or taxes based upon the receipt of rent, including gross receipts or sales taxes applicable to the receipt of rent, unless required to be paid by Tenant, personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems and equipment, appurtenances, furniture and other personal property used in connection with the Project, or any portion thereof), which shall be paid or accrued during any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority) because of or in connection with the ownership, leasing and operation of the Project, or any portion thereof.

4.2.5.2 Tax Expenses shall include, without limitation: (i) Any tax on the rent, right to rent or other income from the Project, or any portion thereof, or as against the


				CHINA BASIN LANDING
		-11-		[LoopNet]

business of leasing the Project, or any portion thereof; (ii) Any assessment, tax, fee, levy or charge in addition to, or in substitution, partially or totally, of any assessment, tax, fee, levy or charge previously included within the definition of real property tax, it being acknowledged by Xxxxxx and Landlord that Proposition 13 was adopted by the voters of the State of California in the June 1978 election (“Proposition 13”) and that assessments, taxes, fees, levies and charges may be imposed by governmental agencies for such services as fire protection, street, sidewalk and road maintenance, refuse removal and for other governmental services formerly provided without charge to property owners or occupants, and, in further recognition of the decrease in the level and quality of governmental services and amenities as a result of Proposition 13, Tax Expenses shall also include any governmental or private assessments or the Project’s contribution towards a governmental or private cost-sharing agreement for the purpose of augmenting or improving the quality of services and amenities normally provided by governmental agencies; (iii) Any assessment, tax, fee, levy, or charge allocable to or measured by the area of the Premises or the Rent payable hereunder, including, without limitation, any business or gross income tax or excise tax with respect to the receipt of such rent, or upon or with respect to the possession, leasing, operating, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises, or any portion thereof; and (iv) Any assessment, tax, fee, levy or charge, upon this transaction or any document to which Tenant is a party, creating or transferring an interest or an estate in the Premises.

4.2.5.3 Any costs and expenses (including, without limitation, reasonable attorneys’ fees) incurred in attempting to protest, reduce or minimize Tax Expenses shall be included in Tax Expenses in the Expense Year such expenses are paid. Tax refunds shall be credited against Tax Expenses and refunded to Tenant regardless of when received, based on the Expense Year to which the refund is applicable, provided that in no event shall the amount to be refunded to Tenant for any such Expense Year exceed the total amount paid by Xxxxxx as Additional Rent under this Article 4 for such Expense Year. If Tax Expenses for any period during the Lease Term or any extension thereof are increased after payment thereof for any reason, including, without limitation, error or reassessment by applicable governmental or municipal authorities, Tenant shall pay Landlord within thirty (30) days following Landlord’s written demand therefore (which written demand shall include reasonable, back-up documentation of such increase) Tenant’s Share of any such increased Tax Expenses included by Landlord as Building Tax Expenses pursuant to the terms of this Lease. Notwithstanding anything to the contrary contained in this Section 4.2.5 (except as set forth in Section 4.2.5.1, above), there shall be excluded from Tax Expenses (i) all excess profits taxes, franchise taxes, gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state income taxes, and other taxes to the extent applicable to Landlord’s general or net income (as opposed to rents, receipts or income attributable to operations at the Project), (ii) any items included as Operating Expenses, (iii) any items paid by Tenant under Section 4.5 of this Lease, (iv) tax penalties incurred as a result of Landlord’s negligence, inability or unwillingness to make payments or file returns when due, and (v) taxes on tenant improvements in the Building based upon an assessed level in excess of the Building standard set forth in Section 4.5.2, below.

4.2.5.4 The amount of Tax Expenses for the Base Year attributable to the valuation of the Project, inclusive of tenant improvements, shall be known as “Base Taxes”. If in any comparison year subsequent to the Base Year, the amount of Tax Expenses decreases below the amount of Base Taxes, then for purposes of all subsequent comparison years, including the comparison year in which such decrease in Tax Expenses occurred, the Base Taxes, and therefore the Base Year, shall be decreased by an amount equal to the decrease in Tax Expenses.

4.2.6 “Tenant’s Share” shall mean the percentage set forth in Section 6 of the Summary, and is based on the ratio of the square footage of the Premises to the total square footage of the Project.

4.3 Allocation of Direct Expenses.

4.3.1 Method of Allocation. The parties acknowledge that the Building is a part of a multi-building project and that the costs and expenses incurred in connection with the Project (i.e. the Direct Expenses) are an aggregate of the Building and the other buildings in the Project.

4.3.2 Cost Pools. Landlord shall have the right, from time to time, to equitably allocate some or all of the Direct Expenses for the Project among different portions or occupants


				CHINA BASIN LANDING
		-12-		[LoopNet]

of the Project (the “Cost Pools”), in Landlord’s discretion, which allocation shall be consistently applied. Such Cost Pools may include, but shall not be limited to, the office space tenants of a building of the Project or of the Project, and the retail space tenants of a building of the Project or of the Project. The Direct Expenses within each such Cost Pool shall be allocated and charged to the tenants as determined by Landlord in accordance with sound real estate management principles, consistently applied. Landlord shall not allocate Direct Expenses into Cost Pools as provided in this Section 4.3.2 as a subterfuge to increase the amount of Direct Expenses payable by Tenant hereunder.

4.4 Calculation and Payment of Additional Rent. If for any Expense Year ending or commencing within the Lease Term, Tenant’s Share of Direct Expenses for such Expense Year exceeds Tenant’s Share of Direct Expenses applicable to the Base Year, then Tenant shall pay to Landlord, in the manner set forth in Section 4.4.1, below, and as Additional Rent, an amount equal to the excess (the “Excess”).

4.4.1 Statement of Actual Direct Expenses and Payment by Tenant. Landlord shall endeavor to give to Tenant following the end of each Expense Year, a statement (the “Statement”) which shall state in general major categories the Direct Expenses incurred or accrued for such preceding Expense Year, and which shall indicate the amount of the Excess. Upon receipt of the Statement for each Expense Year commencing or ending during the Lease Term, if an Excess is present, Tenant shall pay, within thirty (30) days following Tenant’s receipt of the Statement, the full amount of the Excess for such Expense Year, less the amounts, if any, paid during such Expense Year as “Estimated Excess,” as that term is defined in Section 4.4.2, below. The failure of Landlord to timely furnish the Statement for any Expense Year shall not prejudice Landlord or Tenant from enforcing its rights under this Article 4. Even though the Lease Term has expired and Tenant has vacated the Premises, when the final determination is made of Tenant’s Share of Direct Expenses for the Expense Year in which this Lease terminates, if an Excess if present, Tenant shall, within thirty (30) days following Tenant’s receipt of the Statement, pay to Landlord such amount, and if Tenant paid more as Estimated Excess than actual Excess, Landlord shall, within thirty (30) days following Landlord’s determination, deliver a check to Tenant in the amount of such overpayment. The provisions of this Section 4.4.1 shall survive the expiration or earlier termination of the Lease Term.

4.4.2 Statement of Estimated Direct Expenses. In addition, Landlord shall endeavor to give Tenant a yearly expense estimate statement (the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the “Estimate”) of what the total amount of Direct Expenses for the then-current Expense Year shall be and the estimated excess (the “Estimated Excess”) as calculated by comparing the Direct Expenses for such Expense Year, which shall be based upon the Estimate, to the amount of Direct Expenses for the Base Year. The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect any Estimated Excess under this Article 4, nor shall Landlord be prohibited from revising any Estimate Statement or Estimated Excess theretofore delivered to the extent necessary; provided that Landlord shall not revise any Estimate Statement or Estimated Excess more than once per year. Thereafter, Tenant shall pay, within thirty (30) days following Xxxxxx’s receipt of the Estimate Statement, a fraction of the Estimated Excess for the then-current Expense Year (reduced by any amounts paid pursuant to the next to last sentence of this Section 4.4.2). Such fraction shall have as its numerator the number of months which have elapsed in such current Expense Year, including the month of such payment, and twelve (12) as its denominator. Until a new Estimate Statement is furnished (which Landlord shall have the right to deliver to Tenant at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Excess set forth in the previous Estimate Statement delivered by Landlord to Tenant.

4.5 Taxes and Other Charges for Which Tenant Is Directly Responsible.

4.5.1 Tenant shall be liable for and shall pay ten (10) business days before delinquency, taxes levied against Tenant’s equipment, furniture, fixtures and any other personal property located in or about the Premises. If any such taxes on Tenant’s equipment, furniture, fixtures and any other personal property are levied against Landlord or Landlord’s property or if the assessed value of Landlord’s property is increased by the inclusion therein of a value placed upon such equipment, furniture, fixtures or any other personal property and if Landlord pays the taxes based upon such increased assessment, which Landlord shall have the right to do regardless of the validity thereof but only under proper protest if requested by Tenant, Tenant shall upon


				CHINA BASIN LANDING
		-13-		[LoopNet]

demand repay to Landlord the taxes so levied against Landlord or the proportion of such taxes resulting from such increase in the assessment, as the case may be.

4.5.2 If the tenant improvements in the Premises, whether installed and/or paid for by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, are assessed for real property tax purposes at a valuation higher than the valuation at which tenant improvements conforming to Landlord’s “building standard” in other space in the Building are assessed, then the Tax Expenses levied against Landlord or the property by reason of such excess assessed valuation shall be deemed to be taxes levied against personal property of Tenant and shall be governed by the provisions of Section 4.5.1, above.

4.5.3 Notwithstanding any contrary provision herein, Tenant shall pay prior to delinquency any (i) rent tax or sales tax, service tax, transfer tax or value added tax, or any other applicable tax on the rent or services herein or otherwise respecting this Lease, (ii) taxes assessed upon or with respect to the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises or any portion of the Project, including the Project parking facility; or (iii) taxes assessed upon this transaction or any document to which Tenant is a party creating or transferring an interest or an estate in the Premises.

ARTICLE 5

USE OF PREMISES

5.1 Permitted Use. Tenant shall use the Premises solely for the Permitted Use set forth in Section 7 of the Summary and Tenant shall not use or permit the Premises or the Project to be used for any other purpose or purposes whatsoever without the prior written consent of Landlord, which may be withheld in Landlord’s sole discretion.

5.2 Prohibited Uses. The uses prohibited under this Lease shall include, without limitation, use of the Premises or a portion thereof for (i) offices of any agency or bureau of the United States or any state or political subdivision thereof; (ii) offices or agencies of any foreign governmental or political subdivision thereof; (iii) offices of any health care professionals or service organization; (iv) schools or other training facilities which are not ancillary to corporate, executive or professional office use; (v) retail or restaurant uses; or (vi) communications firms such as radio and/or television stations. Tenant shall not allow occupancy density of use of the Premises which is greater than one person for each 150 rentable square feet of the Premises. Tenant further covenants and agrees that Tenant shall not use, or suffer or permit any person or persons to use, the Premises or any part thereof for any use or purpose contrary to the provisions of the Rules and Regulations set forth in Exhibit D, attached hereto, or in violation of the laws of the United States of America, the State of California, or the ordinances, regulations or requirements of the local municipal or county governing body or other lawful authorities having jurisdiction over the Project) including, without limitation, any such laws, ordinances, regulations or requirements relating to hazardous materials or substances, as those terms are defined by applicable laws now or hereafter in effect. Tenant shall not do or permit anything to be done in or about the Premises which will in any way damage the reputation of the Project or obstruct or interfere with the rights of other tenants or occupants of the Building, or injure or annoy them or use or allow the Premises to be used for any improper, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall comply with all recorded covenants, conditions, and restrictions now or hereafter affecting the Project.

ARTICLE 6

SERVICES AND UTILITIES

6.1 Standard Tenant Services. Landlord shall provide the following services on all days (unless otherwise stated below) during the Lease Term.

6.1.1 Subject to limitations imposed by all governmental rules, regulations and guidelines applicable thereto, Landlord shall provide heating and air conditioning (“HVAC”) when necessary for normal comfort for normal office use in the Premises from 8:00 A.M. to 6:00 P.M. Monday through Friday (collectively, the “Building Hours”), except for the date of observation of New Year’s Day, Memorial Day, Independence Day, Labor Day, Thanksgiving


				CHINA BASIN LANDING
		-14-		[LoopNet]

Day, Christmas Day and, at Landlord’s reasonable discretion, other regionally or nationally recognized holidays (collectively, the “Holidays”).

6.1.2 Landlord shall provide adequate electrical wiring and facilities for connection to Building standard ceiling mounted lighting fixtures and normal office and incidental use equipment, provided that Tenant’s consumption of electricity does not exceed 1 kilowatt/hour per usable square foot of the Premises per month, which electrical usage shall be subject to applicable laws and regulations, including Title 24. Tenant will design Tenant’s electrical system serving any equipment producing nonlinear electrical loads to accommodate such nonlinear electrical loads, including, but not limited to, oversizing neutral conductors, derating transformers and/or providing power-line filters. Engineering plans shall include a calculation of Tenant’s fully connected electrical design load with and without demand factors and shall indicate the number of xxxxx of unmetered and submetered loads. Tenant shall bear the cost of replacement of lamps, starters and ballasts for non-Building standard lighting fixtures within the Premises.

6.1.3 Landlord shall provide city water from the regular Building outlets for drinking, lavatory and toilet purposes in the Building Common Areas.

6.1.4 Landlord shall provide janitorial services to the Premises, except the date of observation of the Holidays, in and about the Premises and window washing services in a manner consistent with other comparable buildings in the vicinity of the Building.

6.1.5 Landlord shall provide nonexclusive, non-attended automatic passenger elevator service during the Building Hours, shall have one elevator available at all other times, except in the event of an emergency.

6.1.6 Landlord shall provide nonexclusive freight elevator service subject to scheduling by Landlord.

Tenant shall cooperate fully with Landlord at all times and abide by all regulations and requirements that Landlord may reasonably prescribe for the proper functioning and protection of the HVAC, electrical, mechanical and plumbing systems.

6.2 Overstandard Tenant Use. Tenant shall not, without Xxxxxxxx’s prior written consent, use heat-generating machines, machines other than normal fractional horsepower office machines, or equipment or lighting other than Building standard lights in the Premises, which may affect the temperature otherwise maintained by the air conditioning system or materially increase the water normally furnished for the Premises by Landlord pursuant to the terms of Section 6.1 of this Lease. If such consent is given, Landlord shall have the right to install supplementary air conditioning units or other facilities in the Premises, including supplementary or additional metering devices, and the cost thereof, including the cost of installation, operation and maintenance, increased wear and tear on existing equipment and other similar charges, shall be paid by Tenant to Landlord upon billing by Landlord. In the event, in Landlord’s reasonable discretion, Tenant uses water, electricity, heat or air conditioning in excess of that supplied by Landlord pursuant to Section 6.1 of this Lease, Tenant shall pay to Landlord, upon billing, the cost of such excess consumption, the cost of the installation, operation, and maintenance of equipment which is installed in order to supply such excess consumption, and the cost, if any, of the increased wear and tear on existing equipment caused by such excess consumption; and Landlord may, upon reasonable prior notice to Tenant, install devices to separately meter any increased use and in such event Tenant shall pay the increased cost directly to Landlord, within ten (10) days following demand by Landlord (which demand shall include reasonable back-up documentation), at the rates charged by the public utility company furnishing the same, including the cost of such additional metering devices, In the event Tenant delivers to Landlord detailed specifications for any equipment Tenant intends to install in the Premises, Landlord shall use commercially reasonable efforts to notify Tenant within ten (10) business days following such receipt whether Landlord believes such equipment shall cause excess consumption as set forth in this Section 6.2. To the extent Landlord delivers a bill for excess water and/or electricity, following a request by Xxxxxx, Landlord shall meet with Tenant to discuss Landlord’s determination of such excess usage. Tenant’s use of electricity shall never exceed the capacity of the feeders to the Project or the risers or wiring installation. If Tenant desires to use heat, ventilation or air conditioning during hours other than those for which Landlord is obligated to supply such utilities pursuant to the terms of Section 6.1 of this Lease, Tenant shall give


				CHINA BASIN LANDING
		-15-		[LoopNet]

Landlord such prior notice, if any, as Landlord shall from time to time reasonably establish as appropriate, to the extent such additional utilities can be made available, and Landlord shall supply such utilities to Tenant at such hourly cost to Tenant (which shall be treated as Additional Rent and which may include an administrative fee) as Landlord shall from time to time reasonably establish.

6.3 Interruption of Use. Tenant agrees that Landlord shall not be liable for damages, by abatement of Rent (except as set forth in Section 6.4, below) or otherwise, for failure to furnish or delay in furnishing any service (including telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by breakage, repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after reasonable effort to do so, by any riot or other dangerous condition, emergency, accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause; and such failures or delays or diminution shall never be deemed to constitute an eviction or disturbance of Tenant’s use and possession of the Premises or relieve Tenant from paying Rent (except as set forth in Section 6.4, below) or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for a loss of, or injury to, property or for injury to, or interference with, Xxxxxx’s business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the services or utilities as set forth in this Article 6. Landlord may comply with voluntary controls or guidelines promulgated by any governmental entity relating to the use or conservation of energy, water, gas, light or electricity or the reduction of automobile or other emissions without creating any liability of Landlord to Tenant under this Lease, provided that the Premises are not thereby rendered untenantable.

6.4 Rent Abatement. Notwithstanding anything in this Lease to the contrary, in the event that Tenant is prevented from using, and does not use, the Premises or any portion thereof, as a result of any failure of Landlord to provide any services, utilities or access to the Premises as required by this Lease (other than for a reason beyond Landlord’s reasonable control, including, but not limited to, loss of electricity due to black-outs) (an “Abatement Event”), then Tenant shall give Landlord notice of such Abatement Event, and if such Abatement Event continues for three (3) consecutive business days after Landlord’s receipt of any such notice (the “Eligibility Period”), then the Base Rent and Tenant’s Share of Direct Expenses shall be abated or reduced, as the case may be, after expiration of the Eligibility Period for such time that Tenant continues to be so prevented from using, and does not use, the Premises or a portion thereof, in the proportion that the rentable area of the portion of the Premises that Tenant is prevented from using, and does not use, bears to the total rentable area of the Premises. Such right to xxxxx Base Rent and Xxxxxx’s Share of Direct Expenses shall be Tenant’s sole and exclusive remedy at law or in equity for an Abatement Event. Except as provided in this Section 6.4, nothing contained herein shall be interpreted to mean that Tenant is excused from paying Rent due hereunder.

ARTICLE 7

REPAIRS

Tenant shall, at Xxxxxx’s own expense, pursuant to the terms of this Lease, including without limitation Article 8 hereof, keep the Premises, including all improvements, fixtures and furnishings therein, in good order, repair and condition at all times during the Lease Term. In addition, Tenant shall, at Xxxxxx’s own expense, but under the supervision and subject to the prior approval of Landlord, and within any reasonable period of time specified by Landlord, pursuant to the terms of this Lease, including without limitation Article 8 hereof, promptly and adequately repair all damage to the Premises and replace or repair all damaged, broken, or worn fixtures and appurtenances, except for damage caused by ordinary wear and tear or beyond the reasonable control of Tenant; provided however, that, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, after written notice to Tenant and Tenant’s failure to commence repair within five (5) days thereafter and to diligently pursue the same to completion (except in the event of an emergency, when no notice shall be required) but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a percentage of the cost thereof (to be uniformly established for the Building and/or the Project) sufficient to reimburse Landlord for all overhead, general conditions, fees and other costs or expenses arising from Landlord’s involvement with such repairs and replacements forthwith within thirty (30) days after being billed for same. Landlord shall be responsible for repairs to the exterior walls,


				CHINA BASIN LANDING
		-16-		[LoopNet]

foundation and roof of the Building, the structural portions of the floors of the Building, the systems and equipment of the Building, and the Common Areas, except to the extent that such repairs are required due to the negligence or willful misconduct of Tenant; provided, however, that if such repairs are due to the negligence or willful misconduct of Tenant, Landlord shall nevertheless make such repairs, but at Tenant’s expense, or, if covered by Landlord’s insurance, Tenant shall only be obligated to pay any deductible in connection therewith. Subject to Article 27, below, Landlord may, but shall not be required to, enter the Premises at all reasonable times to make such repairs to the Premises or repairs, alterations, improvements or additions to the Project or to any equipment located in the Project as Landlord shall deem reasonably necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree. Tenant hereby waives any and all rights under and benefits of subsection 1 of Section 1932 and Sections 1941 and 1942 of the California Civil Code or under any similar law, statute, or ordinance now or hereafter in effect.

ARTICLE 8

ADDITIONS AND ALTERATIONS

8.1 Landlord’s Consent to Alterations. Tenant may not make any improvements, alterations, additions or changes to the Premises or any mechanical, plumbing or HVAC facilities or systems pertaining to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than thirty (30) days prior to the commencement thereof, and which consent may be withheld in Landlord’s reasonable discretion. Notwithstanding the foregoing, Tenant shall be permitted to make Alterations following ten (10) business days-notice to Landlord, but without Landlord’s prior approval, to the extent such Alterations are merely cosmetic in nature (i.e. re-painting and re-carpeting), and provided that such Alterations do not (a) affect the exterior of the Building, (b) affect the structure of the Building or the systems and equipment of the Building, and/or (c) interfere with Building services or the use of the Project or the Building by other tenants or occupants. The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.

8.2 Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen selected by Tenant from a list provided and approved by Landlord. Notwithstanding the foregoing, in the event such Alterations or repairs (i) affect the exterior of the Building, (ii) affect the structure of the Building, or the systems and equipment of the Building, or (iii) may interfere with Building services or the use of the Building or Project by other tenants or occupants, then Landlord may condition its approval in Landlord’s sole discretion. Prior to the expiration or earlier termination of this Lease, Tenant shall, at Tenant’s expense, remove any Alteration designated by Landlord for removal by notice to Tenant prior to the expiration or earlier termination of this Lease, and shall repair any damage to the Premises or the Building caused by such removal; provided, however, in the event that in Tenant’s request for approval of such Alterations or the “Final Working Drawings” for the “Tenant Improvements,” as those terms are defined in the Tenant Work Letter, attached hereto as Exhibit B, constructed pursuant to the terms of the Tenant Work Letter, as the case may be, Tenant requests a determination by Landlord (the “Designation Notice”) as to whether or not Tenant shall be required to remove such Alteration or Tenant Improvements upon the expiration or earlier termination of the Lease, in accordance with the terms hereof, then Landlord shall include in its consent (if granted) notice as to whether such Alteration or Tenant Improvements shall be required to be removed prior to the expiration or earlier termination of this Lease, and corresponding repairs made. If such Alterations will involve the use of or disturb hazardous materials or substances existing in the Premises, Tenant shall comply with Landlord’s rules and regulations concerning such hazardous materials or substances. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the City of San Francisco, all in conformance with Xxxxxxxx’s construction rules and regulations. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the “Base Building,” as that term is defined below, then Landlord shall, at Tenant’s expense, make such


				CHINA BASIN LANDING
		-17-		[LoopNet]

changes to the Base Building. The “Base Building” shall include the structural portions of the Building, and the public restrooms and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Francisco in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project management office a reproducible copy of the “as built” drawings of the Alterations (to the extent such Alterations are of the type and scope for which such plans are typically prepared) as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

8.3 Payment for Improvements. If payment is made directly to contractors, Tenant shall comply with Landlord’s requirements for final lien releases and waivers in connection with Tenant’s payment for work to contractors. If Tenant orders any work directly from Landlord, Tenant shall pay to Landlord a percentage of the cost of such work sufficient to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord’s involvement with such work. If Xxxxxx does not order the work directly from Landlord, Tenant shall reimburse Landlord for Landlord’s actual out-of-pocket costs and expenses actually incurred in connection with Xxxxxxxx’s review of such work.

8.4 Construction Insurance. In addition to the requirements of Article 10 of this Lease, in the event that Tenant makes any Alterations, prior to the commencement of such Alterations, Tenant shall provide Landlord with evidence that Tenant carries “Builder’s All Risk” insurance in an amount approved by Landlord, in Landlord’s reasonable discretion, covering the construction of such Alterations, and such other insurance as Landlord may require, it being understood and agreed that all of such Alterations shall be insured by Tenant pursuant to Article 10 of this Lease immediately upon completion thereof. In addition, to the extent any Alteration is reasonably anticipated to cost in excess of $100,000.00, Landlord may, in its discretion, require Tenant to obtain a lien and completion bond or some alternate form of security satisfactory to Landlord in an amount sufficient to ensure the lien-free completion of such Alterations and naming Landlord as a co-obligee.

8.5 Landlord’s Property. All Alterations, improvements, fixtures, equipment and/or appurtenances which may be installed or placed in or about the Premises, from time to time, shall be at the sole cost of Tenant and shall be and become the property of Landlord, except that Tenant may remove any Alterations, improvements, fixtures and/or equipment which Tenant can substantiate to Landlord have not been paid for with any Tenant improvement allowance funds provided to Tenant by Landlord, provided Tenant repairs any damage to the Premises and Building caused by such removal and returns the affected portion of the Premises to a building standard tenant improved condition as determined by Landlord. Furthermore, prior to the expiration or earlier termination of this Lease, Tenant shall, at Tenant’s expense, remove any Alterations or improvements in the Premises designated by Landlord and restore the same to the condition existing prior to the installation of such Alteration (provided such previous condition did not require any repair, in which event Tenant shall restore the same to the condition existing as of the completion of the initial Tenant Improvements), subject to the terms of Section 8.2, above. If Tenant fails to complete such removal and/or to repair any damage caused by the removal of any Alterations or improvements in the Premises, and return the affected portion of the Premises to the condition required hereunder, as reasonably determined by Landlord, Landlord may do so and may charge the reasonable cost thereof to Tenant. Tenant hereby protects, defends, indemnifies and holds Landlord harmless from any liability, cost, obligation, expense or claim of lien in any manner relating to the installation, placement, removal or financing of any such Alterations, improvements, fixtures and/or equipment in, on or about the Premises placed there by or on behalf of Tenant, which obligations of Tenant shall survive the expiration or earlier termination of this Lease.


				CHINA BASIN LANDING
		-18-		[LoopNet]

ARTICLE 9

COVENANT AGAINST LIENS

Tenant shall keep the Project and Premises free from any liens or encumbrances arising out of the work performed, materials furnished or obligations incurred by or on behalf of Tenant, and shall protect, defend, indemnify and hold Landlord harmless from and against any claims, liabilities, judgments or costs (including, without limitation, reasonable attorneys’ fees and costs) arising out of same or in connection therewith. Tenant shall give Landlord notice at least ten (10) days prior to the commencement of any such work on the Premises (or such additional time as may be necessary under applicable laws) to afford Landlord the opportunity of posting and recording appropriate notices of non-responsibility. Tenant shall remove any such lien or encumbrance by bond or otherwise within ten (10) days after notice by Landlord, and if Tenant shall fail to do so, Landlord may pay the amount necessary to remove such lien or encumbrance, without being responsible for investigating the validity thereof. The amount so paid shall be deemed Additional Rent under this Lease payable upon demand, without limitation as to other remedies available to Landlord under this Lease. Nothing contained in this Lease shall authorize Tenant to do any act which shall subject Landlord’s title to the Building or Premises to any liens or encumbrances whether claimed by operation of law or express or implied contract. Any claim to a lien or encumbrance upon the Building or Premises arising in connection with any such work or respecting the Premises not performed by or at the request of Landlord shall be null and void, or at Landlord’s option shall attach only against Xxxxxx’s interest in the Premises and shall in all respects be subordinate to Landlord’s title to the Project, Building and Premises.

ARTICLE 10

INSURANCE

10.1 Indemnification and Waiver.

10.1.1 Tenant Indemnification and Waiver. Except to the extent caused by the negligence or willful misconduct of Landlord or “Landlord Parties,” as that term is defined hereinbelow, Tenant hereby assumes all risk of damage to property or injury to persons in, upon or about the Premises from any cause whatsoever and agrees that Landlord, its partners, subpartners and their respective officers, agents, servants, employees, and independent contractors (collectively, “Landlord Parties”) shall not be liable for, and are hereby released from any responsibility for, any damage either to person or property or resulting from the loss of use thereof, which damage is sustained by Tenant or by other persons claiming through Tenant. Tenant shall indemnify, defend, protect, and hold harmless the Landlord Parties from any and all loss, cost, damage, expense and liability (including without limitation court costs and reasonable attorneys’ fees) incurred in connection with or arising from any cause in the Premises, any acts, omissions or negligence of Tenant or of any person claiming by, through or under Tenant, or of the contractors, agents, servants, employees, invitees, guests or licensees of Tenant or any such person, in, on or about the Project or any breach of the terms of this Lease, either prior to, during, or after the expiration of the Lease Term, provided that the terms of the foregoing indemnity shall not apply to the negligence or willful misconduct of Landlord or the Landlord Parties. Should Landlord be named as a defendant in any suit brought against Tenant in connection with or arising out of Tenant’s occupancy of the Premises, Tenant shall pay to Landlord its costs and expenses incurred in such suit, including without limitation, its actual and reasonable professional fees such as appraisers’, accountants’ and attorneys’ fees. Further, Tenant’s agreement to indemnify Landlord pursuant to this Section 10.1.1 is not intended and shall not relieve any insurance carrier of its obligations under policies required to be carried by Tenant pursuant to the provisions of this Lease, to the extent such policies cover the matters subject to Tenant’s indemnification obligations; nor shall they supersede any inconsistent agreement of the parties set forth in any other provision of this Lease. The provisions of this Section 10.1.1 shall survive the expiration or sooner termination of this Lease with respect to any claims or liability arising in connection with any event occurring prior to such expiration or termination.

10.1.2 Landlord Indemnification. Xxxxxxxx agrees to indemnify Tenant and hold it harmless from any and all loss, cost, damage, expense and liability (including without limitation court costs,and reasonable attorneys’ fees) incurred in connection with or arising from any loss, including, without limitation, any loss by reason of injury to person or property, caused by Landlord’s or its agents’ gross negligence or willful misconduct. In case any action, suit or


				CHINA BASIN LANDING
		-19-		[LoopNet]

proceeding is brought against Tenant by reason of any such occurrence, Landlord, upon Xxxxxx’s request, will, at Xxxxxxxx’s expense, resist and defend such action, suit or proceeding, itself or through counsel designated by the applicable insurer, or otherwise reasonably approved by Xxxxxx. The obligations of Landlord under this Section 10.1.2 shall survive the termination of this Lease with respect to any claims or liability arising in connection with any event occurring prior to such termination.

10.2 Landlord’s Fire and Casualty Insurance. Landlord shall carry commercial general liability insurance with respect to the Building during the Lease Term, and shall further insure the Building during the Lease Term against loss or damage due to fire and other casualties covered within the classification of fire and extended coverage, vandalism coverage and malicious mischief, sprinkler leakage, water damage and special extended coverage. Such coverage shall be in such amounts, from such companies, and on such other terms and conditions, as Landlord may from time to time reasonably determine. Additionally, at the option of Landlord, such insurance coverage may include the risks of earthquakes and/or flood damage and additional hazards, a rental loss endorsement and one or more loss payee endorsements in favor of the holders of any mortgages or deeds of trust encumbering the interest of Landlord in the Building or the ground or underlying lessors of the Building, or any portion thereof. Notwithstanding the foregoing provisions of this Section 10.2, the coverage and amounts of insurance carried by Landlord in connection with the Building shall, at a minimum, be comparable to the coverage and amounts of insurance which are carried by reasonably prudent landlords of Comparable Buildings (provided that in no event shall Landlord be required to carry earthquake insurance). Tenant shall, at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies then Tenant shall reimburse Landlord within thirty (30) days following Landlord’s request therefor (which request shall include reasonable back-up documentation) for any such increase. Tenant, at Tenant’s expense, shall comply with all rules, orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and with any similar body.

10.3 Tenant’s Insurance. Tenant shall maintain the following coverages in the following amounts.

10.3.1 Commercial General Liability Insurance covering the insured against claims of bodily injury, personal injury and property damage (including loss of use thereof) arising out of Tenant’s operations, and contractual liabilities (covering the performance by Tenant of its indemnity agreements) including a Broad Form endorsement covering the insuring provisions of this Lease and the performance by Tenant of the indemnity agreements set forth in Section 10.1 of this Lease, for limits of liability not less than:


Bodily Injury and		$5,000,000 each occurrence
Property Damage Liability		$5,000,000 annual aggregate
Personal Injury Liability		$5,000,000 each occurrence
		$5,000,000 annual aggregate
		0% Insured’s participation

10.3.2 Physical Damage Insurance covering (i) all office furniture, business and trade fixtures, office equipment, free-standing cabinet work, movable partitions, merchandise and all other items of Tenant’s property on the Premises installed by, for, or at the expense of Tenant, (ii) the “Tenant Improvements,” as that term is defined in Section 2.1 of the Tenant Work Letter, and any other improvements which exist in the Premises as of the Lease Commencement Date (excluding the Base Building) (the “Original Improvements”), and (iii) all other improvements, alterations and additions to the Premises. Such insurance shall be written on an “all risks” of physical loss or damage basis, for the full replacement cost value (subject to reasonable deductible amounts) new without deduction for depreciation of the covered items and in amounts that meet any co-insurance clauses of the policies of insurance and shall include coverage for damage or other loss caused by fire or other peril including, but not limited to, vandalism and malicious mischief, theft, water damage of any type, including sprinkler leakage, bursting or stoppage of pipes, and explosion, and providing business interruption coverage for a period of one year.


				CHINA BASIN LANDING
		-20-		[LoopNet]

10.3.3 Worker’s Compensation and Employer’s Liability or other similar insurance pursuant to all applicable state and local statutes and regulations.

10.3.4 Business Interruption Insurance in the amount necessary to insure payment of Tenant’s obligations to pay Rent hereunder for a period of not less than twelve (12) months.

10.4 Form of Policies. The minimum limits of policies of insurance required of Tenant under this Lease shall in no event limit the liability of Tenant under this Lease. Such insurance shall (i) name Landlord, and any other party the Landlord reasonably specifies, in writing, as an additional insured, including Xxxxxxxx’s managing agent, if any; (ii) specifically cover the liability assumed by Tenant under this Lease, including, but not limited to, Tenant’s obligations under Section 10.1 of this Lease; (iii) be issued by an insurance company having a rating of not less than A-X in Best’s Insurance Guide or which is otherwise acceptable to Landlord and licensed to do business in the State of California; (iv) be primary insurance as to all claims thereunder and provide that any insurance carried by Landlord is excess and is non-contributing with any insurance requirement of Tenant; (v) be in form and content reasonably acceptable to Landlord; and (vi) provide that said insurance shall not be canceled or coverage changed unless thirty (30) days’ prior written notice shall have been given to Landlord and any mortgagee of Landlord. Tenant shall deliver said policy or policies or, at Tenant’s option, certificates (including endorsements) thereof to Landlord on or before the Lease Commencement Date and at least thirty (30) days before the expiration dates thereof. In the event Tenant shall fail to procure such insurance, or to deliver such policies or certificate, Landlord may, at its option, within live (5) days following written notice from Landlord to Tenant, procure such policies for the account of Tenant, and the cost thereof shall be paid to Landlord within five (5) days after delivery to Tenant of bills therefor.

10.5 Subrogation. Landlord and Tenant intend that, notwithstanding any other provision of this Lease to the contrary, their respective property loss risks shall be borne by reasonable insurance carriers to the extent above provided, and Landlord and Tenant hereby agree to look solely to, and seek recovery only from, their respective insurance carriers in the event of a property loss to the extent that such coverage is agreed to be provided hereunder. Accordingly, notwithstanding any other provision of this Lease to the contrary, the parties each hereby waive all rights and claims against each other for such losses, and waive all rights of subrogation of their respective insurers, provided such waiver of subrogation shall not affect the right of the insured to recover thereunder. The parties agree that their respective insurance policies are now, or shall be, endorsed such that the waiver of subrogation shall not affect the right of the insured to recover thereunder, so long as no material additional premium is charged therefor.

10.6 Additional Insurance Obligations. Tenant shall carry and maintain during the entire Lease Term, as the same may be extended, at Tenant’s sole cost and expense, increased amounts of the insurance required to be carried by Tenant pursuant to this Article 10 and such other reasonable types of insurance coverage and in such reasonable amounts covering the Premises and Tenant’s operations therein, as may be reasonably requested by Landlord, but in no event shall such increased amounts of insurance or such other reasonable types of insurance be in excess of that generally requested by landlords of Comparable Buildings.

ARTICLE 11

DAMAGE AND DESTRUCTION

11.1 Repair of Damage to Premises by Landlord. Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matter’s beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the


				CHINA BASIN LANDING
		-21-		[LoopNet]

occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3.2 (ii) and (iii) of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements, the Original Improvements installed in the Premises all other improvements, alterations and additions to the Premises and shall return such Tenant Improvements, Original Improvements and all other improvements, alterations and additions to the Premises to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage, or as soon as such additional costs are known. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall, upon receipt of written request from Landlord, submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, Landlord shall allow Tenant an equitable, proportionate abatement of Rent to the extent Landlord is reimbursed from the proceeds of rental interruption insurance purchased by Landlord as part of Operating Expenses, during the time and to the extent the Premises are unfit for occupancy for the purposes permitted under this Lease, and not occupied by Tenant as a result thereof; provided, further, however, that to the extent the damage or destruction is due to the negligence or wilful misconduct of Tenant or any of its agents, employees or contractors, Tenant shall be responsible for any reasonable, applicable insurance deductible (which shall be payable to Landlord upon demand). In the event that Landlord shall not deliver the Landlord Repair Notice, Xxxxxx’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.

11.2 Landlord’s Option to Repair. Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, and instead terminate this Lease, by notifying Tenant in writing of such termination within sixty (60) days after the date of damage, such notice to include a termination date giving Tenant sixty (60) days to vacate the Premises, but Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred twenty (120) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be, and Landlord elects to terminate the leases of all other tenants of the Project similarly affected by the damage and destruction; (iii) the damage is not fully covered by Landlord’s insurance policies or the coverage which would have been afforded had Landlord maintained the insurance required under this Lease, and Landlord elects to terminate the leases of all other tenants of the Project similarly affected by the damage and destruction; or (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally or (v) the damage occurs during the last eighteen (18) months of the Lease Term. If Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and the repairs cannot, in the reasonable opinion of Landlord, be completed within one hundred eighty days (180) days after being commenced (which one hundred eighty days (180) day period shall be subject to execution as a result of any “Force Majeure” as that term is defined in Section 29.16, below), Tenant may elect, within thirty (30) days after the date of Xxxxxxxx’s notice, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Xxxxxx. Furthermore, if neither Landlord nor


				CHINA BASIN LANDING
		-22-		[LoopNet]

Tenant has terminated this Lease, and the repairs to be made by Landlord are not actually completed within two hundred forty (240) day period (which period may be extended up to ninety (90) days for an event of Force Majeure), then Tenant shall have the right to terminate this Lease during the first five (5) business days of each calendar month following the end of such period until such time as the repairs to be made by Landlord are complete, by notice to Landlord (the “Damage Termination Notice”), effective as of a date set forth in the Damage Termination Notice (the “Damage Termination Date”), which Damage Termination Date shall not be less than ten (10) business days following the end of each such month. Notwithstanding the foregoing, if Tenant delivers a Damage Termination Notice to Landlord, then Landlord shall have the right to suspend the occurrence of the Damage Termination Date for a period ending thirty (30) days after the Damage Termination Date set forth in the Damage Termination Notice by delivering to Tenant, within five (5) business days of Landlord’s receipt of the Damage Termination Notice, a certificate of Landlord’s contractor responsible for the repair of the damage certifying that it is such contractor’s good faith judgment that the repairs to be made by Landlord shall be substantially completed within thirty (30) days after the Damage Termination Date. If such repairs shall be substantially completed prior to the expiration of such thirty-day period, then the Damage Termination Notice shall be of no force or effect, but if such repairs shall not be substantially completed within such thirty-day period, then this Lease shall terminate upon the expiration of such thirty-day period.

11.3 Waiver of Statutory Provisions. The provisions of this Lease, including this Article 11, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, the Building or the Project, and any statute or regulation of the State of California, including, without limitation, Sections 1932(2) and 1933(4) of the California Civil Code, with respect to any rights or obligations concerning damage or destruction in the absence of an express agreement between the parties, and any other statute or regulation, now or hereafter in effect, shall have no application to this Lease or any damage or destruction to all or any part of the Premises, the Building or the Project.

ARTICLE 12

NONWAIVER

No provision of this Lease shall be deemed waived by either party hereto unless expressly waived in a writing signed thereby. The waiver by either party hereto of any breach of any term, covenant or condition herein contained shall not be deemed to be a waiver of any subsequent breach of same or any other term, covenant or condition herein contained. The subsequent acceptance of Rent hereunder by Landlord shall not be deemed to be a waiver of any preceding breach by Tenant of any term, covenant or condition of this Lease, other than the failure of Tenant to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of acceptance of such Rent. No acceptance of a lesser amount than the Rent herein stipulated shall be deemed a waiver of Landlord’s right to receive the full amount due, nor shall any endorsement or statement on any check or payment or any letter accompanying such check or payment be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s right to recover the full amount due. No receipt of monies by Landlord from Tenant after the termination of this Lease shall in any way alter the length of the Lease Term or of Tenant’s right of possession hereunder, or after the giving of any notice shall reinstate, continue or extend the Lease Term or affect any notice given Tenant prior to the receipt of such monies, it being agreed that after the service of notice or the commencement of a suit, or after final judgment for possession of the Premises, Landlord may receive and collect any Rent due, and the payment of said Rent shall not waive or affect said notice, suit or judgment.

ARTICLE 13

CONDEMNATION

If the whole or any part of the Premises, Building or Project shall be taken by power of eminent domain or condemned by any competent authority for any public or quasi-public use or purpose, or if any adjacent property or street shall be so taken or condemned, or reconfigured or vacated by such authority in such manner as to require the use, reconstruction or remodeling of any part of the Premises, Building or Project, or if Landlord shall grant a deed or other


				CHINA BASIN LANDING
		-23-		[LoopNet]

instrument in lieu of such taking by eminent domain or condemnation, Landlord shall have the option to terminate this Lease effective as of the date possession is required to be surrendered to the authority. If more than twenty-five percent (25%) of the rentable square feet of the Premises is taken, or if access to the Premises is substantially impaired, in each case for a period in excess of one hundred eighty (180) days, Tenant shall have the option to terminate this Lease effective as of the date possession is required to be surrendered to the authority. Tenant shall not because of such taking assert any claim against Landlord or the authority for any compensation because of such talcing and Landlord shall be entitled to the entire award or payment in connection therewith, except that Tenant shall have the right to file any separate claim available to Tenant for any taking of Tenant’s personal property and fixtures belonging to Tenant and removable by Tenant upon expiration of the Lease Term pursuant to the terms of this Lease, and for moving expenses, so long as such claims do not diminish the award available to Landlord, its ground lessor with respect to the Building or Project or its mortgagee, and such claim is payable separately to Tenant. All Rent shall be apportioned as of the date of such termination. If any part of the Premises shall be taken, and this Lease shall not be so terminated, the Rent shall be proportionately abated. Tenant hereby waives any and all rights it might otherwise have pursuant to Section 1265.130 of The California Code of Civil Procedure. Notwithstanding anything to the contrary contained in this Article 13, in the event of a temporary taking of all or any portion of the Premises for a period of one hundred and eighty (180) days or less, then this Lease shall not terminate but the Base Rent and the Additional Rent shall be abated for the period of such taking in proportion to the ratio that the amount of rentable square feet of the Premises taken bears to the total rentable square feet of the Premises. Landlord shall be entitled to receive the entire award made in connection with any such temporary taking.

ARTICLE 14

ASSIGNMENT AND SUBLETTING

14.1 Transfers. Tenant shall not, without the prior written consent of Landlord, assign, mortgage, pledge, hypothecate, encumber, or permit any lien to attach to, or otherwise transfer, this Lease or any interest hereunder, permit any assignment, or other transfer of this Lease or any interest hereunder by operation of law, sublet the Premises or any part thereof, or enter into any license or concession agreements or otherwise permit the occupancy or use of the Premises or any part thereof by any persons other than Tenant and its employees and contractors (all of the foregoing are hereinafter sometimes referred to collectively as “Transfers” and any person to whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a “Transferee”). If Tenant desires Landlord’s consent to any Transfer, Tenant shall notify Landlord in writing, which notice (the “Transfer Notice”) shall include (i) the proposed effective date of the Transfer, which shall not be less than twenty (20) days nor more than one hundred eighty (180) days after the date of delivery of the Transfer Notice, (ii) a description of the portion of the Premises to be transferred (the “Subject Space”), (iii) all of the terms of the proposed Transfer and the consideration therefor, including calculation of the “Transfer Premium”, as that term is defined in Section 14.3 below, in connection with such Transfer, the name and address of the proposed Transferee, and a copy of all existing executed and/or proposed documentation pertaining to the proposed Transfer, including all existing operative documents to be executed to evidence such Transfer or the agreements incidental or related to such Transfer, (iv) current financial statements of the proposed Transferee certified by an officer, partner or owner thereof, business credit and personal references and history of the proposed Transferee and any other information reasonably required by Landlord (provided such information is requested by Landlord within ten (10) days following Tenant’s submission to Landlord of the Transfer Notice) which will enable Landlord to determine the financial responsibility, character, and reputation of the proposed Transferee, nature of such Transferee’s business and proposed use of the Subject Space, and (v) an executed estoppel certificate from Tenant in the form attached hereto as Exhibit E (which estoppel certificate shall be modified, as appropriate, to contain accurate information). Landlord shall approve or disapprove of the proposed transfer within twenty (20) days following Landlord’s receipt of the applicable Transfer Notice and all documents requested by Landlord pursuant to this Section 14.1 (the “Review Period”). In the event Landlord fails to respond to any request for consent to a Transfer within the Review Period, then Tenant shall have the right to provide Landlord with a second (2^nd) request for consent (the “Second Request”). The Second Request shall specify the terms of the first request, and specifically state that Landlord’s failure to respond within ten (10) days following Landlord’s receipt of the Second Request shall be deemed Landlord’s approval of such


				CHINA BASIN LANDING
		-24-		[LoopNet]

proposed Transfer. In the event Landlord fails to respond to Xxxxxx’s Second Request with ten (10) days following Xxxxxxxx’s receipt of the Second Request, the Proposed Transfer shall be deemed to have been approved by Landlord. Any Transfer made without Landlord’s prior written consent shall, at Landlord’s option, be null, void and of no effect, and shall, at Landlord’s option, constitute a default by Tenant under this Lease. Whether or not Landlord consents to any proposed Transfer, Tenant shall pay Landlord’s commercially reasonable review and processing fees, as well as any reasonable professional fees (including, without limitation, attorneys’, accountants’, architects’, engineers’ and consultants’ fees) incurred by Xxxxxxxx, within thirty (30) days after written request by Landlord.

14.2 Landlord’s Consent. Landlord shall not unreasonably withhold its consent to any proposed Transfer of the Subject Space to the Transferee on the terms specified in the Transfer Notice. In the event Landlord withholds its consent to the proposed Transfer, in its notice to Tenant, Landlord shall set forth in reasonable detail the basis for its determination. Without limitation as to other reasonable grounds for withholding consent, the parties hereby agree that it shall be reasonable under this Lease and under any applicable law for Landlord to withhold consent to any proposed Transfer where one or more of the following apply:

14.2.1 The Transferee is of a character or reputation or engaged in a business which is not consistent with the quality of the Building or the Project;

14.2.2 The Transferee intends to use the Subject Space for purposes which are not permitted under this Lease;

14.2.3 The Transferee is either a governmental agency or instrumentality thereof;

14.2.4 The Transferee is not a party of reasonable financial worth and/or financial stability in light of the responsibilities to be undertaken in connection with the Transfer on the date consent is requested;

14.2.5 The proposed Transfer would cause a violation of another lease for space in the Project, or would give an occupant of the Project a right to cancel its lease;

14.2.6 The terms of the proposed Transfer will allow the Transferee to exercise a right of renewal, right of expansion, right of first offer, or other similar right held by Tenant (or will allow the Transferee to occupy space leased by Tenant pursuant to any such right); or

14.2.7 Either the proposed Transferee, or any person or entity which directly or indirectly, controls, is controlled by, or is under common control with, the proposed Transferee, is negotiating or has negotiated within the past three (3) months with Landlord to lease space in the Project, provided that Landlord has space in the Project reasonably consistent with the Transferee’s rentable area requirements.

14.2.8 The Transferee does not intend to occupy the Subject Space and conduct its business therefrom for a substantial portion of the term of the Transfer.

If Landlord consents (or is deemed to have consented) to any Transfer pursuant to the terms of this Section 14.2 (and does not exercise any recapture rights Landlord may have under Section 14.4 of this Lease), Tenant may within six (6) months after Landlord’s consent, but not later than the expiration of said six-month period, enter into such Transfer of the Premises or portion thereof, upon substantially the same terms and conditions as are set forth in the Transfer Notice furnished by Tenant to Landlord pursuant to Section 14.1 of this Lease. Notwithstanding anything to the contrary in this Lease, if Tenant or any proposed Transferee claims that Landlord has unreasonably withheld or delayed its consent under Section 14.2 or otherwise has breached or acted unreasonably under this Article 14, their sole remedies shall be a declaratory judgment and an injunction for the relief sought without any monetary damages, and Tenant hereby waives all other remedies, including, without limitation, any right at law or equity to terminate this Lease, on its own behalf and, to the extent permitted under all applicable laws, on behalf of the proposed Transferee.

14.3 Transfer Premium. If Landlord consents to a Transfer, as a condition thereto which the parties hereby agree is reasonable, Tenant shall pay to Landlord fifty percent (50%) of any “Transfer Premium,” as that term is defined in this Section 14.3, received by Tenant from such Transferee; provided, however, that Tenant shall not be required to pay to Landlord any


				CHINA BASIN LANDING
		-25-		[LoopNet]

Transfer Premium until such time as Tenant has recovered all applicable “Subleasing Costs,” as that term is defined hereinbelow. “Transfer Premium” shall mean all rent, additional rent or other consideration payable by such Transferee in connection with the Transfer in excess of the Rent and Additional Rent payable by Tenant under this Lease during the term of the Transfer on a per rentable square foot basis if less than all of the Premises is transferred, after deducting the reasonable expenses incurred by Tenant for (i) any changes, alterations and improvements to the Premises in connection with the Transfer, (ii) any commercially reasonable brokerage commissions in connection with the Transfer, (iii) reasonable legal fees in connection with the Transfer, and (iv) reasonable out-of-pocket costs of advertising the Subject Space related to the Transfer (items (i), (ii), (iii) and (iv) collectively referred to herein as the “Subleasing Costs”). “Transfer Premium” shall also include, but not be limited to, key money, bonus money or other cash consideration paid by Transferee to Tenant in connection with such Transfer, and any payment in excess of fair market value for services rendered by Tenant to Transferee or for assets, fixtures, inventory, equipment, or furniture transferred by Tenant to Transferee in connection with such Transfer. In the calculations of the Rent (as it relates to the Transfer Premium calculated under this Section 14.3), the Rent paid during each annual period for the Subject Space, shall be computed after adjusting such rent to the actual effective rent to be paid, taking into consideration any and all leasehold concessions granted in connection therewith, including, but not limited to, any rent credit and tenant improvement allowance.

14.4 Landlord’s Option as to Subject Space. Notwithstanding anything to the contrary contained in this Article 14, and except as set forth in Section 14.8, below, with respect to a Transfer (i) for not less than twenty-five percent (25%) of the Premises, and/or (ii) for the entire remaining Lease Term, Landlord shall have the option, by giving written notice to Tenant within twenty (20) days after receipt of any Transfer Notice, to recapture the Subject Space. Such recapture notice shall cancel and terminate this Lease with respect to the Subject Space as of the date stated in the Transfer Notice as the effective date of the proposed Transfer until the last day of the term of the Transfer as set forth in the Transfer Notice (or at Landlord’s option, shall cause the Transfer to be made to Landlord or its agent, in which case the parties shall execute the Transfer documentation promptly thereafter). In the event of a recapture by Landlord, if this Lease shall be canceled with respect to less than the entire Premises, the Rent reserved herein shall be prorated on the basis of the number of rentable square feet retained by Tenant in proportion to the number of rentable square feet contained in the Premises, and this Lease as so amended shall continue thereafter in full force and effect, and upon request of either party, the parties shall execute written confirmation of the same. If Landlord declines, or fails to elect in a timely manner to recapture the Subject Space under this Section 14.4, then, provided Landlord has consented to the proposed Transfer, Tenant shall be entitled to proceed to transfer the Subject Space to the proposed Transferee, subject to provisions of this Article 14.

14.5 Effect of Transfer. If Landlord consents to a Transfer, (i) the terms and conditions of this Lease shall in no way be deemed to have been waived or modified, (ii) such consent shall not be deemed consent to any further Transfer by either Tenant or a Transferee, (iii) Tenant shall deliver to Landlord, promptly after execution, an original executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, (iv) Tenant shall furnish upon Landlord’s request a complete statement, certified by an independent certified public accountant, or Tenant’s chief financial officer, setting forth in detail the computation of any Transfer Premium Tenant has derived and shall derive from such Transfer, and (v) no Transfer relating to this Lease or agreement entered into with respect thereto, whether with or without Landlord’s consent, shall relieve Tenant or any guarantor of the Lease from any liability under this Lease, including, without limitation, in connection with the Subject Space. Landlord or its authorized representatives shall have the right at all reasonable times to audit the books, records and papers of Tenant relating to any Transfer, and shall have the right to make copies thereof. If the Transfer Premium respecting any Transfer shall be found understated, Tenant shall, within thirty (30) days after demand, pay the deficiency, and if understated by more than two percent (2%), Tenant shall pay Landlord’s reasonable costs of such audit.

14.6 Additional Transfers. Except as set forth in Section 14.8, below, for purposes of this Lease, the term “Transfer” shall also include (i) if Tenant is a partnership, the withdrawal or change, voluntary, involuntary or by operation of law, of fifty percent (50%) or more of the partners, or transfer of fifty percent (50%) or more of partnership interests, within a twelve (12)- month period, or the dissolution of the partnership without immediate reconstitution thereof, and (ii) if Tenant is a closely held corporation (i.e., whose stock is not publicly held and not traded through an exchange or over the counter), (A) the dissolution, merger, consolidation or other


				CHINA BASIN LANDING
		-26-		[LoopNet]

reorganization of Tenant or (B) the sale or other transfer of an aggregate of fifty percent (50%) or more of the voting shares of Tenant (other than to immediate family members by reason of gift or death), within a twelve (12)-month period, or (C) the sale, mortgage, hypothecation or pledge of an aggregate of fifty percent (50%) or more of the value of the unencumbered assets of Tenant within a twelve (12)-month period.

14.7 Occurrence of Default. Any Transfer hereunder shall be subordinate and subject to the provisions of this Lease, and if this Lease shall be terminated during the term of any Transfer, Landlord shall have the right to: (i) treat such Transfer as cancelled and repossess the Subject Space by any lawful means, or (ii) require that such Transferee attorn to and recognize Landlord as its landlord under any such Transfer. If Tenant shall be in default under this Lease, Landlord is hereby irrevocably authorized, as Xxxxxx’s agent and attorney-in-fact, to direct any Transferee to make all payments under or in connection with the Transfer directly to Landlord (which Landlord shall apply towards Tenant’s obligations under this Lease) until such default is cured. Such Transferee shall rely on any representation by Landlord that Tenant is in default hereunder, without any need for confirmation thereof by Xxxxxx. Upon any assignment, the assignee shall assume in writing all obligations and covenants of Tenant thereafter to be performed or observed under this Lease. No collection or acceptance of rent by Landlord from any Transferee shall be deemed a waiver of any provision of this Article 14 or the approval of any Transferee or a release of Tenant from any obligation under this Lease, whether theretofore or thereafter accruing. In no event shall Landlord’s enforcement of any provision of this Lease against any Transferee be deemed a waiver of Landlord’s right to enforce any term of this Lease against Tenant or any other person. If Xxxxxx’s obligations hereunder have been guaranteed, Xxxxxxxx’s consent to any Transfer shall not be effective unless the guarantor also consents to such Transfer.

14.8 Non-Transfers. Notwithstanding anything to the contrary contained in this Article 14, neither (i) an assignment to an entity which acquires all or substantially all of the stock or assets of Tenant, (ii) an assignment of the Premises to a transferee which is the resulting entity of a merger or consolidation of Tenant with another entity, nor (iii) an assignment or subletting of all or a portion of the Premises to an affiliate of Tenant (an entity which is controlled by, controls, or is under common control with, Tenant) (collectively, “Affiliates”), shall be deemed a Transfer under this Article 14, provided that Tenant notifies Landlord of any such assignment or sublease and promptly supplies Landlord with any documents or information reasonably requested by Landlord regarding such assignment or sublease or such Affiliate (excluding any documentation regarding the economic terms of the merger or sale transaction, but including documentation regarding the assignment or subletting), and further provided that such assignment or sublease is not a subterfuge by Tenant to avoid its obligations under this Lease. “Control,” as used in this Section 14.8, shall mean the ownership, directly or indirectly, of at least fifty-one percent (51%) of the voting securities of, or possession of the right to vote, in the ordinary direction of its affairs, of at least fifty-one percent (51%) of the voting interest in, any person or entity.

ARTICLE 15

SURRENDER OF PREMISES; OWNERSHIP AND
REMOVAL OF TRADE FIXTURES

15.1 Surrender of Premises. No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Xxxxxx, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such sublessees or subtenancies.

15.2 Removal of Tenant Property by Xxxxxx. Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and


				CHINA BASIN LANDING
		-27-		[LoopNet]

condition as when Xxxxxx took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear, damage from a casualty which is Xxxxxxxx’s obligation to repair under Article 11 of this Lease, and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises (the “Tenant Personal Property”), and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal. Landlord shall have the right, at Xxxxxx’s sole cost and expense, to dispose of any Tenant Personal Property remaining in the Premises after the expiration or earlier termination of this Lease in any manner Landlord sees fit.


				CHINA BASIN LANDING
		-28-		[LoopNet]

ARTICLE 16

HOLDING OVER

If Tenant holds over after the expiration of the Lease Term or earlier termination thereof, with or without the express or implied consent of Landlord, such tenancy shall be from month-to-month only, and shall not constitute a renewal hereof or an extension for any further term, and in such case Rent shall be payable at a monthly rate equal to one hundred fifty percent (150%) of the Rent applicable during the last rental period of the Lease Term under this Lease for the first two (2) months following the expiration or earlier termination of this Lease, and two hundred percent (200%) thereafter. Such month-to-month tenancy shall be subject to every other applicable term, covenant and agreement contained herein. Nothing contained in this Article 16 shall be construed as consent by Landlord to any holding over by Xxxxxx, and Landlord expressly reserves the right to require Tenant to surrender possession of the Premises to Landlord as provided in this Lease upon the expiration or other termination of this Lease. The provisions of this Article 16 shall not be deemed to limit or constitute a waiver of any other rights or remedies of Landlord provided herein or at law. If Xxxxxx fails to surrender the Premises upon the termination or expiration of this Lease, in addition to any other liabilities to Landlord accruing therefrom, Tenant shall protect, defend, indemnify and hold Landlord harmless from all loss, costs (including reasonable attorneys’ fees) and liability resulting from such failure, including, without limiting the generality of the foregoing, any claims made by any succeeding tenant founded upon such failure to surrender and any lost profits to Landlord resulting therefrom.

ARTICLE 17

ESTOPPEL CERTIFICATES

Within five (5) business days following a request in writing by Landlord, Tenant shall execute, acknowledge and deliver to Landlord an estoppel certificate, which, as submitted by Landlord, shall be substantially in the form of Exhibit E, attached hereto (or such other form as may be required by any prospective mortgagee or purchaser of the Project, or any portion thereof), indicating therein any exceptions thereto that may exist at that time, and shall also contain any other information reasonably requested by Landlord or Landlord’s mortgagee or prospective mortgagee. Any such certificate may be relied upon by any prospective mortgagee or purchaser of all or any portion of the Project. Tenant shall execute and deliver whatever other instruments may be reasonably required for such purposes. At any time during the Lease Term (but no more than once per a calendar year), Landlord may require Tenant to provide Landlord with a current financial statement and financial statements of the two (2) years prior to the current financial statement year. Such statements shall be prepared in accordance with generally accepted accounting principles and, if such is the normal practice of Tenant, shall be audited by an independent certified public accountant. Failure of Tenant to timely execute, acknowledge and deliver such estoppel certificate or other instruments shall constitute an acceptance of the Premises and an acknowledgment by Tenant that statements included in the estoppel certificate are true and correct, without exception. In connection with an assignment of the Lease by Tenant pursuant to Section 14.8, above, Landlord hereby agrees to provide to Tenant an estoppel certificate signed by Landlord, containing the same types of information, and within the same time periods set forth above, with such changes to the Estoppel certificate as are reasonably necessary to reflect that the estoppel certificate is being given by Landlord to Tenant rather than from Tenant to Landlord or a lender.

ARTICLE 18

SUBORDINATION

This Lease shall be subject and subordinate to all present and future ground or underlying leases of the Building or Project and to the lien of any mortgage, trust deed or other encumbrances now or hereafter in force against the Building or Project or any part thereof, if any, and to all renewals, extensions, modifications, consolidations and replacements thereof, and to all advances made or hereafter to be made upon the security of such mortgages or trust deeds, unless the holders of such mortgages, trust deeds or other encumbrances, or the lessors under such ground lease or underlying leases, require in writing that this Lease be superior thereto. In consideration of, and as a condition precedent to, Xxxxxx’s agreement to permit its interest pursuant to this Lease to be subordinated to any particular future ground or underlying lease of


				CHINA BASIN LANDING
		-29-		[LoopNet]

the Building or the Project or to the lien of any mortgage or trust deed, first encumbering the Building or the Project following the date hereof, and to any renewals, extensions, modifications, consolidations and replacements thereof, Landlord shall deliver to Tenant a commercially reasonable non-disturbance agreement executed by the landlord under such ground lease or underlying lease or the holder of such mortgage or trust deed, as appropriate. Tenant covenants and agrees in the event any proceedings are brought for the foreclosure of any such mortgage or deed in lieu thereof (or if any ground lease is terminated), to attorn, without any deductions or set-offs whatsoever, to the lienholder or purchaser or any successors thereto upon any such foreclosure sale or deed in lieu thereof (or to the ground lessor), if so requested to do so by such purchaser or lienholder or ground lessor, and to recognize such purchaser or lienholder or ground lessor as the lessor under this Lease, provided such lienholder or purchaser or ground lessor shall agree to accept this Lease and not disturb Tenant’s occupancy, so long as Tenant timely pays the rent and observes and performs the terms, covenants and conditions of this Lease to be observed and performed by Xxxxxx. Xxxxxxxx’s interest herein may be assigned as security at any time to any lienholder. Tenant shall, within ten (10) business days of request by Landlord, execute such further instruments or assurances as Landlord may reasonably deem necessary to evidence or confirm the subordination or superiority of this Lease to any such mortgages, trust deeds, ground leases or underlying leases. Tenant waives the provisions of any current or future statute, rule or law which may give or purport to give Tenant any right or election to terminate or otherwise adversely affect this Lease and the obligations of the Tenant hereunder in the event of any foreclosure proceeding or sale. Tenant shall, within five (5) business days of request by Landlord from time to time, (i) execute a commercially reasonable Nondisturbance and Attornment Agreement in the form reasonably approved by Xxxxxxxx’s mortgagee in favor of any mortgagee of the Building or Project, and (ii) execute any other commercially reasonable form of nondisturbance and attornment agreement (or subordination, nondisturbance and attornment agreement, or subordination of the applicable mortgagee’s lien) reasonably required by any mortgagee of the Building or Project which provides comparable nondisturbance protection to Tenant in the event of a foreclosure. Following the full execution and delivery of this Lease, Landlord shall use commercially reasonable efforts to obtain from the holder of the deed of trust encumbering the property as of the date hereof (the “Lender”), a commercially reasonable subordination, non-disturbance and attornment agreement in favor of Tenant.

ARTICLE 19

DEFAULTS; REMEDIES

19.1 Events of Default. The occurrence of any of the following shall constitute a default of this Lease by Tenant:

19.1.1 Any failure by Tenant to pay any Rent or any other charge required to be paid under this Lease, or any part thereof, when due unless such failure is cured within three (3) business days after written notice that the same was not paid when due; or

19.1.2 Except where a specific time period is otherwise set forth for Tenant’s performance in this Lease, in which event the failure to perform by Tenant within such time period shall be a default by Tenant under this Section 19.1.2, any failure by Tenant to observe or perform any other provision, covenant or condition of this Lease to be observed or performed by Tenant where such failure continues for thirty (30) days after written notice thereof from Landlord to Tenant; provided that if the nature of such default is such that the same cannot reasonably be cured within a thirty (30) day period, Tenant shall not be deemed to be in default if it diligently commences such cure within such period and thereafter diligently proceeds to rectify and cure such default, but in no event exceeding a period of time in excess of thirty (30) days after written notice thereof from Landlord to Tenant; or

19.1.3 To the extent permitted by law, a general assignment by Tenant or any guarantor of the Lease for the benefit of creditors, or the taking of any corporate action in furtherance of bankruptcy or dissolution whether or not there exists any proceeding under an insolvency or bankruptcy law, or the filing by or against Tenant or any guarantor of any proceeding under an insolvency or bankruptcy law, unless in the case of a proceeding filed against Tenant or any guarantor the same is dismissed within sixty (60) days, or the appointment of a trustee or receiver to take possession of all or substantially all of the assets of Tenant or any guarantor, unless possession is restored to Tenant or such guarantor within thirty (30) days, or any execution or other judicially authorized seizure of all or substantially all of Tenant’s assets


				CHINA BASIN LANDING
		-30-		[LoopNet]

located upon the Premises or of Tenant’s interest in this Lease, unless such seizure is discharged within thirty (30) days; or

19.1.4 Abandonment or vacation of all or a substantial portion of the Premises by Tenant; or

19.1.5 The failure by Xxxxxx to observe or perform according to the provisions of Articles 5, 17 or 18 of this Lease where such failure continues for more than five (5) business days after notice from Landlord.

The notice periods provided herein are in lieu of, and not in addition to, any notice periods provided by law.

19.2 Remedies Upon Default. Upon the occurrence of any event of default by Tenant, Landlord shall have, in addition to any other remedies available to Landlord at law or in equity (all of which remedies shall be distinct, separate and cumulative), the option to pursue any one or more of the following remedies, each and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever.

19.2.1 Terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may have for possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Xxxxxx and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following:

(i) The worth at the time of award of any unpaid rent which has been earned at the time of such termination; plus

(ii) The worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(iii) The worth at the time of award of the amount by which the unpaid rent for the balance of the Lease Term after the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(iv) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Xxxxxx’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including but not limited to, brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; and

(v) At Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable law.

The term “rent” as used in this Section 19.2 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Paragraphs 19.2.1(i) and (ii), above, the “worth at the time of award” shall be computed by allowing interest at the rate set forth in Article 25 of this Lease, but in no case greater than the maximum amount of such interest permitted by law. As used in Paragraph 19.2.1(iii) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus one percent (1%).

19.2.2 Landlord shall have the remedy described in California Civil Code Section 1951.4 (lessor may continue lease in effect after xxxxxx’s breach and abandonment and recover rent as it becomes due, if xxxxxx has the right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies under this Lease, including the right to recover all rent as it becomes due.


				CHINA BASIN LANDING
		-31-		[LoopNet]

19.2.3 Landlord shall at all times have the rights and remedies (which shall be cumulative with each other and cumulative and in addition to those rights and remedies available under Sections 19.2.1 and 19.2.2, above, or any law or other provision of this Lease), without prior demand or notice except as required by applicable law, to seek any declaratory, injunctive or other equitable relief, and specifically enforce this Lease, or restrain or enjoin a violation or breach of any provision hereof.

19.3 Subleases of Tenant. Whether or not Landlord elects to terminate this Lease on account of any default by Xxxxxx, as set forth in this Article 19, Landlord shall have the right to terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Xxxxxx and affecting the Premises within ten (10) days of notice from Landlord, or may, in Landlord’s sole discretion, succeed to Xxxxxx’s interest in such subleases, licenses, concessions or arrangements. In the event of Xxxxxxxx’s election to succeed to Xxxxxx’s interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no further right to or interest in the rent or other consideration receivable thereunder.

19.4 Form of Payment After Default. Following the occurrence of an event of default by Tenant, Landlord shall have the right to require that any or all subsequent amounts paid by Tenant to Landlord hereunder, whether to cure the default in question or otherwise, be paid in the form of money order, cashier’s or certified check drawn on an institution acceptable to Landlord, or by other means reasonably approved by Landlord, notwithstanding any prior practice of accepting payments in any different form.

19.5 Efforts to Relet. No re-entry or repossession, repairs, maintenance, changes, alterations and additions, reletting, appointment of a receiver to protect Landlord’s interests hereunder, or any other action or omission by Landlord shall be construed as an election by Landlord to terminate this Lease or Tenant’s right to possession, or to accept a surrender of the Premises, nor shall same operate to release Tenant in whole or in part from any of Tenant’s obligations hereunder, unless express written notice of such intention is sent by Landlord to Tenant. Tenant hereby irrevocably waives any right otherwise available under any law to redeem or reinstate this Lease.


				CHINA BASIN LANDING
		-32-		[LoopNet]

ARTICLE 20

COVENANT OF QUIET ENJOYMENT

Landlord covenants that Tenant, on paying the Rent, charges for services and other payments herein reserved and on keeping, observing and performing all the other terms, covenants, conditions, provisions and agreements herein contained on the part of Tenant to be kept, observed and performed, shall, during the Lease Term, peaceably and quietly have, hold and enjoy the Premises subject to the terms, covenants, conditions, provisions and agreements hereof without interference by any persons lawfully claiming by or through Landlord. The foregoing covenant is in lieu of any other covenant express or implied.

ARTICLE 21

SECURITY DEPOSIT

Concurrent with Xxxxxx’s execution of this Lease, Tenant shall deposit with Landlord a security deposit (the “Security Deposit”) in the amount set forth in Section 8 of the Summary, as security for the faithful performance by Tenant of all of its obligations under this Lease. If Tenant defaults with respect to any provisions of this Lease, including, but not limited to, the provisions relating to the payment of Rent, the removal of property and the repair of resultant damage, Landlord may, without notice to Tenant, but shall not be required to apply all or any part of the Security Deposit necessary for the payment of any Rent or any other sum in default and Tenant shall, within ten (10) days following demand therefor, restore the Security Deposit to its original amount. Any unapplied portion of the Security Deposit shall be returned to Tenant, or, at Landlord’s option, to the last assignee of Xxxxxx’s interest hereunder, within sixty (60) days following the expiration of the Lease Term. Tenant shall not be entitled to any interest on the Security Deposit. Tenant hereby waives the provisions of Section 1950.7 of the California Civil Code, or any successor statute.

ARTICLE 22

INTENTIONALLY DELETED

ARTICLE 23

SIGNS

23.1 Full Floors. Subject to Landlord’s prior written approval, in its sole discretion, and provided all signs are in keeping with the quality, design and style of the Building and Project, Tenant, if the Premises comprise an entire floor of the Building, at its sole cost and expense, may install identification signage anywhere in the Premises including in the elevator lobby of the Premises, provided that such signs must not be visible from the exterior of the Building.

23.2 Multi-Tenant Floors. If other tenants occupy space on the floor on which the Premises is located, Tenant’s identifying signage shall be provided by Landlord, at Tenant’s cost, and such signage shall be comparable to that used by Landlord for other similar floors in the Building and shall comply with Landlord’s Building standard signage program.

23.3 Prohibited Signage and Other Items. Any signs, notices, logos, pictures, names or advertisements which are installed and that have not been separately approved by Landlord may be removed without notice by Landlord at the sole expense of Tenant. Tenant may not install any signs on the exterior or roof of the Project or the Common Areas. Any signs, window coverings, or blinds (even if the same are located behind the Landlord-approved window coverings for the Building), or other items visible from the exterior of the Premises or Building, shall be subject to the prior approval of Landlord, in its sole discretion.

23.4 Building Directory. Tenant shall be provided one (1) line on the Building directory located in the lobby of the Building to display Tenant’s name and location in the Building, and the names of Tenant’s principal employees and subtenants.


				CHINA BASIN LANDING
		-33-		[LoopNet]

ARTICLE 24

COMPLIANCE WITH LAW

Tenant shall not do anything or suffer anything to be done in or about the Premises or the Project which will in any way conflict with any law, statute, ordinance or other governmental rule, regulation or requirement now in force or which may hereafter be enacted or promulgated (collectively, the “Applicable Laws”). At its sole cost and expense, Tenant shall promptly comply with all such Applicable Laws which relate to (i) Tenant’s use of the Premises, (ii) the Alterations or “Tenant Improvements,” as that term is defined in Section 2.1 of the Tenant Work Letter attached hereto as Exhibit B, in the Premises, or (iii) the Base Building, but as to the Base Building, only to the extent such obligations are triggered by Tenant’s Alterations, the Tenant Improvements, or Xxxxxx’s use of the Premises for non-general office use. Should any standard or regulation now or hereafter be imposed on Landlord or Tenant by a state, federal or local governmental body charged with the establishment, regulation and enforcement of occupational, health or safety standards for employers, employees, landlords or tenants, then Tenant agrees, at its sole cost and expense, to comply promptly with such standards or regulations. Tenant shall be responsible, at its sole cost and expense, to make all alterations to the Premises as are required to comply with the governmental rules, regulations, requirements or standards described in this Article 24. The judgment of any court of competent jurisdiction or the admission of Tenant in any judicial action, regardless of whether Landlord is a party thereto, that Xxxxxx has violated any of said governmental measures, shall be conclusive of that fact as between Landlord and Tenant. Landlord shall comply with all Applicable Laws relating to the Base Building and the Common Areas, provided that compliance with such Applicable Laws is not the responsibility of Tenant under this Lease, and provided further that Landlord’s failure to comply therewith would prohibit Tenant from obtaining or maintaining a certificate of occupancy for the Premises, or would unreasonably and materially affect the safety of Tenant’s employees or create a significant health hazard for Tenant’s employees. Landlord shall be permitted to include in Operating Expenses any costs or expenses incurred by Landlord under this Article 24, but only to the extent consistent with the terms of Section 4.2.4, above.

ARTICLE 25

LATE CHARGES

If any installment of Rent or any other sum due from Tenant shall not be received by Landlord or Landlord’s designee within five (5) days after said amount is due, then Tenant shall pay to Landlord a late charge equal to (i) with respect to the first occurrence, three percent (3%) of the overdue amount; and (ii) thereafter, five percent (5%) of the overdue amount, plus, in each instance, any attorneys’ fees incurred by Landlord by reason of Tenant’s failure to pay Xxxx and/or other charges when due hereunder. The late charge shall be deemed Additional Rent and the right to require it shall be in addition to all of Landlord’s other rights and remedies hereunder or at law and shall not be construed as liquidated damages or as limiting Landlord’s remedies in any manner. In addition to the late charge described above, any Rent or other amounts owing hereunder which are not paid within ten (10) days after the date they are due shall bear interest from the date when due until paid at a rate per annum equal to the highest rate permitted by applicable law.

ARTICLE 26

LANDLORD’S RIGHT TO CURE DEFAULT; PAYMENTS BY TENANT

26.1 Landlord’s Cure. All covenants and agreements to be kept or performed by Tenant under this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any reduction of Rent, except to the extent, if any, otherwise expressly provided herein. If Tenant shall fail to perform any obligation under this Lease, and such failure shall continue in excess of the time allowed under Section 19.1.2, above, unless a specific time period is otherwise stated in this Lease, Landlord may, but shall not be obligated to, make any such payment or perform any such act on Tenant’s part without waiving its rights based upon any default of Tenant and without releasing Tenant from any obligations hereunder.

26.2 Tenant’s Reimbursement. Except as may be specifically provided to the contrary in this Lease, Tenant shall pay to Landlord, within thirty (30) days following delivery


				CHINA BASIN LANDING
		-34-		[LoopNet]

by Landlord to Tenant of statements therefor: (i) sums equal to expenditures reasonably made and obligations incurred by Landlord in connection with the remedying by Landlord of Tenant’s defaults pursuant to the provisions of Section 26.1; (ii) sums equal to all losses, costs, liabilities, damages and expenses referred to in Article 10 of this Lease; and (iii) sums equal to all expenditures made and obligations incurred by Landlord in collecting or attempting to collect the Rent or in enforcing or attempting to enforce any rights of Landlord under this Lease or pursuant to law, including, without limitation, all legal fees and other amounts so expended. Tenant’s obligations under this Section 26.2 shall survive the expiration or sooner termination of the Lease Term.

ARTICLE 27

ENTRY BY LANDLORD

Landlord reserves the right at all reasonable times and upon reasonable notice to Tenant (except in the case of an emergency) to enter the Premises to (i) inspect them; (ii) show the Premises to prospective purchasers, mortgagees or, during the last nine (9) months of the Lease Term, to tenants, or to current or prospective mortgagees, ground or underlying lessors or insurers; (iii) post notices of nonresponsibility; or (iv) alter, improve or repair the Premises, the premises of other tenants in the Building, or the Building, or for structural alterations, repairs, additions, or improvements to the Building or the Building’s systems and equipment. Notwithstanding anything to the contrary contained in this Article 27, Landlord may enter the Premises at any time to (A) perform services required of Landlord, including janitorial service; (B) take possession due to any breach of this Lease in the manner provided herein; and (C) perform any covenants of Tenant which Xxxxxx fails to perform. Landlord may make any such entries without the abatement of Rent (except as provided in Section 6.4 of this Lease) and may take such reasonable steps as required to accomplish the stated purposes; provided, however, except for (i) emergencies, (ii) repairs, alterations, improvements or additions required by governmental or quasi-governmental authorities or court order or decree, or (iii) repairs which are the obligation of Tenant, hereunder, Landlord shall use commercially reasonable efforts not to adversely interfere with Tenant’s use or access to the Premises. Tenant hereby waives any claims for damages or for any injuries or inconvenience to or interference with Xxxxxx’s business, lost profits, any loss of occupancy or quiet enjoyment of the Premises, and any other loss occasioned thereby. For each of the above purposes, Landlord shall at all times have a key with which to unlock all the doors in the Premises, excluding Tenant’s vaults, safes and special security areas designated in advance by Tenant. In an emergency, Landlord shall have the right to use any means that Landlord may deem proper to open the doors in and to the Premises. Any entry into the Premises by Landlord in the manner hereinbefore described shall not be deemed to be a forcible or unlawful entry into, or a detainer of, the Premises, or an actual or constructive eviction of Tenant from any portion of the Premises. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decorations except as otherwise expressly agreed to be performed by Landlord herein.

ARTICLE 28

TENANT PARKING

Tenant shall have the right to rent from Landlord, commencing on the Lease Commencement Date, up to the amount of parking passes set forth in Section 9 of the Summary, on a monthly basis throughout the Lease Term, which parking passes shall pertain to the Project parking facility. Tenant may change the number of unreserved parking passes rented pursuant to this Article 28 upon at least thirty (30) days prior written notice to Landlord, provided that in no event shall Tenant be entitled to rent more than the amount of unreserved parking passes set forth in Section 9 of the Summary. Tenant shall pay to Landlord for automobile parking passes on a monthly basis the prevailing rate charged from time to time at the location of such parking passes. In addition, Tenant shall be responsible for the full amount of any taxes imposed by any governmental authority in connection with the renting of such parking passes by Tenant or the use of the parking facility by Tenant. Tenant’s continued right to use the parking passes is conditioned upon Tenant abiding by all rules and regulations which are prescribed from time to time for the orderly operation and use of the parking facility where the parking passes are located, including any sticker or other identification system established by Landlord, Tenant’s cooperation in seeing that Tenant’s employees and visitors also comply with such rules and regulations and Tenant not being in default under this Lease beyond any applicable cure period


				CHINA BASIN LANDING
		-35-		[LoopNet]

set forth herein. Landlord specifically reserves the right to change the location, size, configuration, design, layout and all other aspects of the Project parking facility at any time and Tenant acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of Rent under this Lease, from time to time, close-off or restrict access to the Project parking facility for purposes of permitting or facilitating any such construction, alteration or improvements or cease providing the parking passes if space is no longer available. Landlord may delegate its responsibilities hereunder to a parking operator in which case such parking operator shall have all the rights of control attributed hereby to the Landlord. The parking passes rented by Tenant pursuant to this Article 28 are provided to Tenant solely for use by Xxxxxx’s own personnel and such passes may not be transferred, assigned, subleased or otherwise alienated by Tenant without Xxxxxxxx’s prior approval. Tenant may validate visitor parking by such method or methods as the Landlord may establish, at the validation rate from time to time generally applicable to visitor parking.

ARTICLE 29

MISCELLANEOUS PROVISIONS

29.1 Terms; Captions. The words “Landlord” and “Tenant” as used herein shall include the plural as well as the singular. The necessary grammatical changes required to make the provisions hereof apply either to corporations or partnerships or individuals, men or women, as the case may require, shall in all cases be assumed as though in each case fully expressed. The captions of Articles and Sections are for convenience only and shall not be deemed to limit, construe, affect or alter the meaning of such Articles and Sections.

29.2 Binding Effect. Subject to all other provisions of this Lease, each of the covenants, conditions and provisions of this Lease shall extend to and shall, as the case may require, bind or inure to the benefit not only of Landlord and of Tenant, but also of their respective heirs, personal representatives, successors or assigns, provided this clause shall not permit any assignment by Tenant contrary to the provisions of Article 14 of this Lease.

29.3 No Air Rights. No rights to any view or to light or air over any property, whether belonging to Landlord or any other person, are granted to Tenant by this Lease. If at any time any windows of the Premises are temporarily darkened or the light or view therefrom is obstructed by reason of any repairs, improvements, maintenance or cleaning in or about the Project, the same shall be without liability to Landlord and without any reduction or diminution of Tenant’s obligations under this Lease.

29.4 Modification of Lease. Should any current or prospective mortgagee or ground lessor for the Building or Project reasonably require a modification of this Lease, which modification will not cause an increased cost or expense to Tenant or in any other way materially and adversely change the rights and obligations of Tenant hereunder, then and in such event, Xxxxxx agrees that this Lease may be so modified and agrees to execute whatever documents are reasonably required therefor and to deliver the same to Landlord within twenty (20) days following a request therefor. Landlord agrees that Landlord shall reimburse Tenant its reasonable costs in connection with Xxxxxx’s review and approval of such modifications (provided that reimbursement by Landlord shall in no event exceed $1,000.00). At the request of Landlord or any mortgagee or ground lessor, Xxxxxx agrees to execute a short form of Lease and deliver the same to Landlord within ten (10) days following the request therefor.

29.5 Transfer of Landlord’s Interest. Tenant acknowledges that Xxxxxxxx has the right to transfer all or any portion of its interest in the Project or Building and in this Lease, and Xxxxxx agrees that in the event of any such transfer, Landlord shall automatically be released from all liability under this Lease not accrued as of the date of the transfer, and Xxxxxx agrees to look solely to such transferee for the performance of Landlord’s obligations hereunder after the date of transfer upon agreement by such transferee to fully assume and be liable for all obligations of this Lease to be performed by Xxxxxxxx, including the return of any Security Deposit, and Tenant shall attorn to such transferee. Tenant further acknowledges that Landlord may assign its interest in this Lease to a mortgage lender as additional security and agrees that such an assignment shall not release Landlord from its obligations hereunder and that Tenant shall continue to look to Landlord for the performance of its obligations hereunder.


				CHINA BASIN LANDING
		-36-		[LoopNet]

29.6 Prohibition Against Recording. Except as provided in Section 29.4 of this Lease, neither this Lease, nor any memorandum, affidavit or other writing with respect thereto, shall be recorded by Tenant or by anyone acting through, under or on behalf of Xxxxxx.

29.7 Landlord’s Title. Xxxxxxxx’s title is and always shall be paramount to the title of Tenant. Nothing herein contained shall empower Tenant to do any act which can, shall or may encumber the title of Landlord.

29.8 Relationship of Parties. Nothing contained in this Lease shall be deemed or construed by the parties hereto or by any third party to create the relationship of principal and agent, partnership, joint venturer or any association between Landlord and Tenant.

29.9 Application of Payments. Landlord shall have the right to apply payments received from Tenant pursuant to this Lease, regardless of Tenant’s designation of such payments, to satisfy any obligations of Tenant hereunder, in such order and amounts as Landlord, in its sole discretion, may elect.

29.10 Time of Essence. Time is of the essence with respect to the performance of every provision of this Lease in which time of performance is a factor.

29.11 Partial Invalidity. If any term, provision or condition contained in this Lease shall, to any extent, be invalid or unenforceable, the remainder of this Lease, or the application of such term, provision or condition to persons or circumstances other than those with respect to which it is invalid or unenforceable, shall not be affected thereby, and each and every other term, provision and condition of this Lease shall be valid and enforceable to the fullest extent possible permitted by law.

29.12 No Warranty. In executing and delivering this Lease, Tenant has not relied on any representations, including, but not limited to, any representation as to the amount of any item comprising Additional Rent or the amount of the Additional Rent in the aggregate or that Landlord is furnishing the same services to other tenants, at all, on the same level or on the same basis, or any warranty or any statement of Landlord which is not set forth herein or in one or more of the exhibits attached hereto.

29.13 Landlord Exculpation. The liability of Landlord or the Landlord Parties to Tenant for any default by Landlord under this Lease or arising in connection herewith or with Landlord’s operation, management, leasing, repair, renovation, alteration or any other matter relating to the Project or the Premises shall be limited solely and exclusively to an amount which is equal to the interest of Landlord in the Building, provided that in no event shall such liability extend to any sales or insurance proceeds received by Landlord or the Landlord Parties in connection with the Project, Building or Premises. Neither Landlord, nor any of the Landlord Parties shall have any personal liability therefor, and Tenant hereby expressly waives and releases such personal liability on behalf of itself and all persons claiming by, through or under Tenant. The limitations of liability contained in this Section 29.13 shall inure to the benefit of Landlord’s and the Landlord Parties’ present and future partners, beneficiaries, officers, directors, trustees, shareholders, agents and employees, and their respective partners, heirs, successors and assigns. Under no circumstances shall any present or future partner of Landlord (if Landlord is a partnership), or trustee or beneficiary (if Landlord or any partner of Landlord is a trust), have any liability for the performance of Landlord’s obligations under this Lease. Notwithstanding any contrary provision herein, neither Landlord nor the Landlord Parties shall be liable under any circumstances for injury or damage to, or interference with, Xxxxxx’s business, including but not limited to, loss of profits, loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, in each case, however occurring.

29.14 Entire Agreement. It is understood and acknowledged that there are no oral agreements between the parties hereto affecting this Lease and this Lease constitutes the parties’ entire agreement with respect to the leasing of the Premises and supersedes and cancels any and all previous negotiations, arrangements, brochures, agreements and understandings, if any, between the parties hereto or displayed by Landlord to Tenant with respect to the subject matter thereof, and none thereof shall be used to interpret or construe this Lease. None of the terms, covenants, conditions or provisions of this Lease can be modified, deleted or added to except in writing signed by the parties hereto.


				CHINA BASIN LANDING
		-37-		[LoopNet]

29.15 Right to Lease. Landlord reserves the absolute right to effect such other tenancies in the Project as Landlord in the exercise of its sole business judgment shall determine to best promote the interests of the Building or Project. Tenant does not rely on the fact, nor does Landlord represent, that any specific tenant or type or number of tenants shall, during the Lease Term, occupy any space in the Building or Project.

29.16 Force Majeure. Any prevention, delay or stoppage due to strikes, lockouts, labor disputes, acts of God, inability to obtain services, labor, or materials or reasonable substitutes therefor, governmental actions, civil commotions, fire or other casualty, and other causes beyond the reasonable control of the party obligated to perform, except with respect to the obligations imposed with regard to Rent and other charges to be paid by Tenant pursuant to this Lease and except as to Tenant’s obligations under Articles 5 and 24 of this Lease (collectively, a “Force Majeure”), notwithstanding anything to the contrary contained in this Lease, shall excuse the performance of such party for a period equal to any such prevention, delay or stoppage and, therefore, if this Lease specifies a time period for performance of an obligation of either party, that time period shall be extended by the period of any delay in such party’s performance caused by a Force Majeure.

29.17 Waiver of Redemption by Xxxxxx. Tenant hereby waives, for Tenant and for all those claiming under Tenant, any and all rights now or hereafter existing to redeem by order or judgment of any court or by any legal process or writ, Xxxxxx’s right of occupancy of the Premises after any termination of this Lease.

29.18 Notices. All notices, demands, statements, designations, approvals or other communications (collectively, “Notices”) given or required to be given by either party to the other hereunder or by law shall be in writing, shall be (A) sent by United States certified or registered mail, postage prepaid, return receipt requested ( “Mail”), (B) transmitted by telecopy, if such telecopy is promptly followed by a Notice sent by Mail, (C) delivered by a nationally recognized overnight courier, or (D) delivered personally. Any Notice shall be sent, transmitted, or delivered, as the case may be, to Tenant or Landlord at the appropriate address set forth in Section 10 or 11 of the Summary, as appropriate, or to such other place as either party may from time to time designate in a Notice to the other. Any Notice will be deemed given (i) three (3) days after the date it is posted if sent by Mail, (ii) the date the telecopy is transmitted, (iii) the date the overnight courier delivery is made, or (iv) the date personal delivery is made or attempted to be made. If Tenant is notified of the identity and address of Landlord’s mortgagee or ground or underlying lessor, Tenant shall give to such mortgagee or ground or underlying lessor written notice of any default by Landlord under the terms of this Lease by registered or certified mail, and such mortgagee or ground or underlying lessor shall be given a reasonable opportunity to cure such default prior to Tenant’s exercising any remedy available to Tenant.

29.19 Joint and Several. If there is more than one Tenant, the obligations imposed upon Tenant under this Lease shall be joint and several.

29.20 Authority. If Tenant is a corporation, trust or partnership, each individual executing this Lease on behalf of Tenant hereby represents and warrants that Tenant is a duly formed and existing entity qualified to do business in California and that Xxxxxx has full right and authority to execute and deliver this Lease and that each person signing on behalf of Tenant is authorized to do so. In such event, Tenant shall, within ten (10) days after execution of this Lease, deliver to Landlord satisfactory evidence of such authority and, if a corporation, upon demand by Landlord, also deliver to Landlord satisfactory evidence of (i) good standing in Tenant’s state of incorporation and (ii) qualification to do business in California.

29.21 Attorneys’ Fees. In the event that either Landlord or Tenant should bring suit for the possession of the Premises, for the recovery of any sum due under this Lease, or because of the breach of any provision of this Lease or for any other relief against the other, then all costs and expenses, including reasonable attorneys’ fees, incurred by the prevailing party therein shall be paid by the other party, which obligation on the part of the other party shall be deemed to have accrued on the date of the commencement of such action and shall be enforceable whether or not the action is prosecuted to judgment.

29.22 Governing Law: WAIVER OF TRIAL BY JURY. This Lease shall be construed and enforced in accordance with the laws of the State of California. IN ANY ACTION OR PROCEEDING ARISING HEREFROM, LANDLORD AND TENANT HEREBY


				CHINA BASIN LANDING
		-38-		[LoopNet]

CONSENT TO (I) THE JURISDICTION OF ANY COMPETENT COURT WITHIN THE STATE OF CALIFORNIA, (II) SERVICE OF PROCESS BY ANY MEANS AUTHORIZED BY CALIFORNIA LAW, AND (III) IN THE INTEREST OF SAVING TIME AND EXPENSE, TRIAL WITHOUT A JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM BROUGHT BY EITHER OF THE PARTIES HERETO AGAINST THE OTHER OR THEIR SUCCESSORS IN RESPECT OF ANY MATTER ARISING OUT OF OR IN CONNECTION WITH THIS LEASE, THE RELATIONSHIP OF LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE, OR ANY EMERGENCY OR STATUTORY REMEDY. IN THE EVENT LANDLORD COMMENCES ANY SUMMARY PROCEEDINGS OR ACTION FOR NONPAYMENT OF BASE RENT OR ADDITIONAL RENT, TENANT SHALL NOT INTERPOSE ANY COUNTERCLAIM OF ANY NATURE OR DESCRIPTION (UNLESS SUCH COUNTERCLAIM SHALL BE MANDATORY) IN ANY SUCH PROCEEDING OR ACTION, BUT SHALL BE RELEGATED TO AN INDEPENDENT ACTION AT LAW.

29.23 Submission of Lease. Submission of this instrument for examination or signature by Xxxxxx does not constitute a reservation of, option for or option to lease, and it is not effective as a lease or otherwise until execution and delivery by both Landlord and Tenant.

29.24 Brokers. Landlord and Tenant hereby warrant to each other that they have had no dealings with any real estate broker or agent in connection with the negotiation of this Lease, excepting only the real estate brokers or agents specified in Section 12 of the Summary (the “Brokers”), and that they know of no other real estate broker or agent who is entitled to a commission in connection with this Lease. Each party agrees to indemnify and defend the other party against and hold the other party harmless from any and all claims, demands, losses, liabilities, lawsuits, judgments, costs and expenses (including without limitation reasonable attorneys’ fees) with respect to any leasing commission or equivalent compensation alleged to be owing on account of any dealings with any real estate broker or agent, other than the Brokers, occurring by, through, or under the indemnifying party.

29.25 Independent Covenants. This Lease shall be construed as though the covenants herein between Landlord and Tenant are independent and not dependent and Tenant hereby expressly waives the benefit of any statute to the contrary and agrees that if Landlord fails to perform its obligations set forth herein, Tenant shall not be entitled to make any repairs or perform any acts hereunder at Landlord’s expense or to any setoff of the Rent or other amounts owing hereunder against Landlord.

29.26 Project or Building Name and Signage. Landlord shall have the right at any time to change the name of the Project or Building and to install, affix and maintain any and all signs on the exterior and on the interior of the Project or Building as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Xxxxxx in the Premises, without the prior written consent of Landlord.

29.27 Counterparts. This Lease may be executed in counterparts with the same effect as if both parties hereto had executed the same document. Both counterparts shall be construed together and shall constitute a single lease.

29.28 Confidentiality. Tenant acknowledges that the content of this Lease and any related documents are confidential information. Tenant shall keep such confidential information strictly confidential and shall not disclose such confidential information to any person or entity other than Tenant’s financial, legal, and space planning and real estate consultants.

29.29 Transportation Management. Landlord has entered into an agreement with the Department of City Planning to implement a Transportation Management Program ( “TMP”) for tenants and their employees, and to participate in a program designed to coordinate commute alternatives, marketing, and brokerage for greater downtown employees. During the term of the TMP, Xxxxxxxx agrees to provide transportation brokerage and commute assistance services to Tenant, and to assist Tenant in meeting the transportation needs of its employees. Xxxxxx agrees to cooperate with and assist Xxxxxxxx’s TMP Coordinator ( “Coordinator”), through designation of a responsible employee, to distribute to Tenant’s employees written materials encouraging the


				CHINA BASIN LANDING
		-39-		[LoopNet]

use of public transit and ridesharing, and to distribute and return to the Coordinator transportation survey questionnaire forms.

29.30 Building Renovations. It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Project, Premises or the Building, or the areas in the vicinity of the Project have been made by Landlord to Tenant except as specifically set forth herein or in the Tenant Work Letter. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the “Renovations”) the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and (iv) creating additional parking areas or occupied space within the Project,) and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Similarly, other properties in the vicinity of the Project may undergo substantial construction or renovation during the Lease Term (the “Area Renovations”), which may cause substantial disturbance to traffic and parking, and may cause dust, noise and vibrations which may affect the Project. Tenant hereby agrees that such Renovations or Area Renovations and Xxxxxxxx’s actions in connection with such Renovations or Area Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent (except as provided in Section 6.4 of this Lease). Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Xxxxxx’s business arising from the Renovations or Area Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Renovations or Area Renovations or Landlord’s actions in connection with such Renovations or Area Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Area Renovations or Landlord’s actions. Landlord shall use commercially reasonable efforts to minimize any interference with Xxxxxx’s use of and access to the Premises resulting from Renovations by Landlord.

29.31 No Violation. Tenant hereby warrants and represents that neither its execution of nor performance under this Lease shall cause Tenant to be in violation of any agreement, instrument, contract, law, rule or regulation by which Tenant is bound, and Xxxxxx shall protect, defend, indemnify and hold Landlord harmless against any claims, demands, losses, damages, liabilities, costs and expenses, including, without limitation, reasonable attorneys’ fees and costs, arising from Tenant’s breach of this warranty and representation.

29.32 Communications and Computer Lines. Tenant may install, maintain, replace, remove or use any communications or computer wires and cables (collectively, the “Lines”) at the Project in or serving the Premises, provided that (i) Tenant shall obtain Landlord’s prior written consent, which consent shall not be unreasonably withheld, use an experienced and qualified contractor reasonably approved in writing by Landlord, and comply with all of the other provisions of Articles 7 and 8 of this Lease, (ii) an acceptable number of spare Lines and space for additional Lines shall be maintained for existing and future occupants of the Project, as determined in Landlord’s reasonable opinion, (iii) the Lines therefor (including riser cables) shall be appropriately insulated to prevent excessive electromagnetic fields or radiation, and shall be surrounded by a protective conduit reasonably acceptable to Landlord, (iv) any new or existing Lines servicing the Premises shall comply with all applicable governmental laws and regulations, (v) as a condition to permitting the installation of new Lines, Landlord may require that Tenant remove existing Lines located in or serving the Premises and repair any damage in connection with such removal, and (vi) Tenant shall pay all costs in connection therewith. Landlord reserves the right to require that Tenant remove any Lines located in or serving the Premises which are installed in violation of these provisions, or which are at any time in violation of any laws or represent a dangerous or potentially dangerous condition. Landlord makes no representation or assurances with regard to the suitability, available or capacity of the Building’s


				CHINA BASIN LANDING
		-40-		[LoopNet]

telephone and communication distribution network or risers within or service to the Building for Tenant’s communication needs.

29.33 Development of the Project.

29.33.1 Subdivision. Landlord reserves the right to further subdivide all or a portion of the Project. Xxxxxx agrees to execute and deliver, upon demand by Landlord and in the form requested by Landlord, any additional documents needed to conform this Lease to the circumstances resulting from such subdivision.

29.33.2 The Other Improvements. If portions of the Project or property adjacent to the Project (collectively, the “Other Improvements”) are owned by an entity other than Landlord, Landlord, at its option, may enter into an agreement with the owner or owners of any or all of the Other Improvements to provide (i) for reciprocal rights of access and/or use of the Project and the Other Improvements, (ii) for the common management, operation, maintenance, improvement and/or repair of all or any portion of the Project and the Other Improvements, (iii) for the allocation of a portion of the Direct Expenses to the Other Improvements and the operating expenses and taxes for the Other Improvements to the Project, and (iv) for the use or improvement of the Other Improvements and/or the Project in connection with the improvement, construction, and/or excavation of the Other Improvements and/or the Project. Nothing contained herein shall be deemed or construed to limit or otherwise affect Landlord’s right to convey all or any portion of the Project or any other of Landlord’s rights described in this Lease.

29.33.3 Construction of Project and Other Improvements. Tenant acknowledges that portions of the Project and/or the Other Improvements may be under construction following Tenant’s occupancy of the Premises, and that such construction may result in levels of noise, dust, obstruction of access, etc. which are in excess of that present in a fully constructed project. Tenant hereby waives any and all rent offsets or claims of constructive eviction which may arise in connection with such construction.

IN WITNESS WHEREOF, Landlord and Xxxxxx have caused this Lease to be executed the day and date first above written.


“Landlord”:

PWREF/MCC-CHINA BASIN L.L.C.,
a Delaware limited liability company

By:	/s/ [ILLEGIBLE]

	Its:	Authorized Representative


“Tenant”:

LOOPNET,
a California corporation

By:	/s/ Xxxxxxx X. Xxxxx, Xx.


	Its:	PRESIDENT AND CEO


By:


	Its:


				CHINA BASIN LANDING
		-41-		[LoopNet]

EXHIBIT A

CHINA BASIN LANDING

OUTLINE OF PREMISES


		EXHIBIT A		CHINA BASIN LANDING
		-1-		[LoopNet]

EXHIBIT A-l

CHINA BASIN LANDING

FIRST OFFER SPACE


		EXHIBIT A-1		CHINA BASIN LANDING
		-1-		[LoopNet]

EXHIBIT B

CHINA BASIN LANDING

TENANT WORK LETTER

This Tenant Work Letter shall set forth the terms and conditions relating to the construction of the tenant improvements in the Premises. This Tenant Work Letter is essentially organized chronologically and addresses the issues of the construction of the Premises, in sequence, as such issues will arise during the actual construction of the Premises. All references in this Tenant Work Letter to Articles or Sections of “this Lease” shall mean the relevant portion of Articles 1 through 29 of the Office Lease to which this Tenant Work Letter is attached as Exhibit B and of which this Tenant Work Letter forms a part, and all references in this Tenant Work Letter to Sections of “this Tenant Work Letter” shall mean the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

SECTION 1

LANDLORD’S INITIAL CONSTRUCTION IN THE PREMISES

1.1 Base, Shell and Core of the Premises as Constructed by Landlord. Landlord has constructed, at its sole cost and expense, the base, shell, and core (i) of the Premises and (ii) of the floor of the Building on which the Premises is located (collectively, the “Base, Shell, and Core”). The Base, Shell and Core shall consist of those portions of the Premises which were in existence prior to the construction of the tenant improvements in the Premises for the prior tenant of the Premises.

1.2 Landlord Work. Landlord shall, at Xxxxxxxx’s sole cost and expense, prior to the Lease Commencement Date, cause the construction or installation of the following items on the floor of the Building containing the Premises (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Notwithstanding anything to the contrary contained in this Lease, in no event shall the Lease Commencement Date occur prior to the substantial completion by Landlord of the Landlord Work.

1.2.1 Public Corridor (only as to that portion of the Premises, if any, which occupies only a portion of a floor, rather than an entire floor, of the Building). The actual public corridor wall, the standard tenant entries and exits including doors, frames, hardware, and sidelight (if any), and standard tenant entry signage and exit lights (collectively, the “Public Corridor”), which Public Corridor is adjacent to the Premises.

1.2.2 Demising Walls Between Tenants (only as to that portion of the Premises, if any, which occupies only a portion of a floor, rather than an entire floor, of the Building). The demising partitions between tenants which shall include studs, acoustical insulation and dry wall ready for finish on tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Walls”), which Demising Walls are adjacent to the Premises.

1.2.3 Demolish and remove the tenant improvements existing in the Premises as of the date of this Lease in accordance with the “Demolition Plan” attached hereto as Schedule 2 to Exhibit B. Landlord shall perform the demolition work in accordance with Landlord’s standard demolition procedures.

SECTION 2

TENANT IMPROVEMENTS

2.1 Tenant Improvement Allowance. Tenant shall be entitled to a one-time tenant improvement allowance (the “Tenant Improvement Allowance”) in the amount of $25.00 per rentable square foot of the Premises for the costs relating to the design and construction of Tenant’s improvements which are permanently affixed to the Premises (the “Tenant Improvements”). Within thirty (30) days following the Lease Commencement Date, Tenant shall be entitled, pursuant to a written notice delivered to Landlord, to a one-time increase (the “Additional Allowance”) of the Tenant Improvement Allowance in an amount not to exceed $5.00 for each rentable square foot of the Premises, for the costs relating to the initial design and construction of the Tenant Improvements. In the event Tenant exercises its right to use all or any


		EXHIBIT B		CHINA BASIN LANDING
		-1-		[LoopNet]

portion of the Additional Allowance, the monthly Base Rent for the Premises shall be increased by an amount equal to the “Additional Monthly Base Rent,” as that term is defined below, in order to repay the Additional Allowance to Landlord. The “Additional Monthly Base Rent” shall be determined as the missing component of an annuity, which annuity shall have (i) the amount of the Additional Allowance which Tenant elects to utilize as the present value amount, (ii) sixty (60) as the number of payments, (iii) seventy-five one-hundredths (.75), which is equal to nine percent (9%) divided by twelve (12) months per year, as the monthly interest factor, and (iv) the Additional Monthly Base Rent as the missing component of the annuity. In the event Tenant elects to utilize all or a portion of the Additional Allowance, then (a) all references in this Tenant Work Letter to the “Tenant Improvement Allowance”, shall be deemed to include the Additional Allowance which Tenant elects to utilize, (b) the parties shall promptly execute an amendment (the “Amendment”) to this Lease setting forth the new amount of the Base Rent and Tenant Improvement Allowance computed in accordance with this Section 2.1, and (c) the additional amount of monthly Base Rent owing in accordance with this Section 2.1 for the first full month of the Lease Term which occurs after the expiration of any free rent period shall be paid by Tenant to Landlord at the time of Tenant’s execution of the Amendment. In no event shall Landlord be obligated to make disbursements pursuant to this Tenant Work Letter in a total amount which exceeds the Tenant Improvement Allowance and the Additional Allowance. All Tenant Improvements for which the Tenant Improvement Allowance has been made available shall be deemed Landlord’s property under the terms of the Lease. Notwithstanding the foregoing, upon Xxxxxx’s request, at the expiration or earlier termination of this Lease, Landlord shall negotiate with Tenant in good faith towards the purchase by Tenant of all or any portion of the Tenant Improvements, at the then-current fair market value for such Tenant Improvements. Upon Xxxxxx’s request, Landlord and Tenant shall retain an independent third party (mutually approved by Landlord and Tenant) to determine the fair market value of such Tenant Improvements. The fees of such third party shall be split evenly between Landlord and Tenant.

2.2 Disbursement of the Tenant Improvement Allowance. Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process) for costs related to the construction of the Tenant Improvements and for the following items and costs (collectively, the “Tenant Improvement Allowance Items”): (i) payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter; (ii) the cost of any changes in the Base, Shell and Core when such changes are required by the Construction Drawings; (iii) the cost of any changes to the Construction Drawings or Tenant Improvements required by all applicable building codes (the “Code”); (iv) the cost of the Landlord’s Work; and (v) the “Landlord Supervision Fee”, as that term is defined in Section 4.3.2 of this Tenant Work Letter; and (vi) costs of the purchase and installation of furniture, fixtures and equipment in the Premises (“FF&E”), provided that the cost of the FF&E shall not exceed $12.50 per rentable square feet of the Premises. Landlord shall use commercially reasonable efforts to notify Tenant as promptly as reasonably possible in the event Landlord believes, following its review of the Construction Drawings, that changes will be required as set forth in items (ii) and/or (iii) above, in order to allow Tenant to make applicable changes to the Construction Drawings.

2.3 Standard Tenant Improvement Package. Landlord has established specifications (the “Specifications”) for the Building standard components to be used in the construction of the Tenant Improvements in the Premises (collectively, the “Standard Improvement Package”), which Specifications shall be supplied to Tenant by Landlord. The quality of Tenant Improvements shall be equal to or of greater quality than the quality of the Specifications (or otherwise reasonably acceptable to Landlord), provided that Landlord may, at Landlord’s option, require the Tenant Improvements to comply with certain Specifications. Landlord may make changes to the Specifications for the Standard Improvement Package from time to time.

SECTION 3

CONSTRUCTION DRAWINGS

3.1 Selection of Architect/Construction Drawings. Tenant shall retain the architect/space planner designated by Landlord (the “Architect”) to prepare the “Construction


		EXHIBIT B		CHINA BASIN LANDING
		-2-		[LoopNet]

Drawings,” as that term is defined, in this Section 3.1. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, lifesafety, and sprinkler work of the Tenant Improvements. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications as determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in this Lease shall specifically apply to the Construction Drawings.

3.2 Final Space Plan. On or before the date set forth in Schedule 1, attached hereto, Tenant and the Architect shall prepare the final space plan for Tenant Improvements in the Premises (collectively, the “Final Space Plan”), which Final Space Plan shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein, and shall deliver the Final Space Plan to Landlord for Landlord’s approval.

3.3 Final Working Drawings. On or before the date set forth in Schedule 1, Tenant, the Architect and the Engineers shall complete the architectural and engineering drawings for the Premises, and the final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval. Landlord shall, within five (5) business days after Landlord’s receipt of the Final Working Drawings either (i) approve the Final Working Drawings, (ii) approve the Final Working Drawings subject to specified conditions to be satisfied by Tenant prior to submitting the Approved Working Drawings for permits as set forth in Section 3.4, below, if the Final Working Drawings do not comply with the Final Space Plan or contain a design problem, or (iii) disapprove and return the Final Working Drawings to Tenant with detailed requested revisions if the Final Working Drawings do not comply with the Final Space Plan or contain a design problem. If Landlord disapproves the Final Working Drawings, Tenant shall resubmit the Final Working Drawings to Landlord within five (5) business days, and Landlord shall approve or disapprove of the resubmitted Final Working Drawings within five (5) business days after Xxxxxxxx receives such resubmitted Final Working Drawings.

3.4 Permits. The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of the construction of the Tenant Improvements. Tenant shall immediately submit the Approved Working Drawings to the appropriate municipal authorities for all applicable building permits necessary to allow “Contractor,” as that term is defined in Section 4.1, below, to commence and fully complete the construction of the Tenant Improvements (the “Permits”), and, in connection therewith, Tenant shall coordinate with Landlord in order to allow Landlord, at its option, to take part in all phases of the permitting process and shall supply Landlord, as soon as possible, with all plan check numbers and dates of submittal and obtain the Permits on or before the date set forth in Schedule 1. Notwithstanding anything to the contrary set forth in this Section 3.4, Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that the obtaining of the same shall be Tenant’s responsibility; provided however that (i) Landlord shall be responsible to the extent Tenant is unable to obtain such Permits due to Landlord’s failure to perform the Landlord Work in a good and workmanlike manner; and (ii) Landlord shall, in any event, cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, provided that Landlord may withhold its consent, in its sole discretion, to any change in the Approved Working Drawings if such change would directly or indirectly delay the


		EXHIBIT B		CHINA BASIN LANDING
		-3-		[LoopNet]

“Substantial Completion” of the Premises as that term is defined in Section 5.1 of this Tenant Work Letter; provided that Landlord shall give Tenant notice of any such anticipated delays and the cost of such change to the Approved Working Drawings; and provided further that if Tenant agrees that any resulting delay would constitute a Tenant delay pursuant to Section 5 below and if Tenant agrees to pay any additional costs which arise as a result of such changes, modifications or alterations, then Landlord will not withhold its consent to such changes, modifications or alterations, unless a design problem exists.

3.5 Time Deadlines. Tenant shall use its good faith, efforts and all due diligence to cooperate with the Architect, the Engineers, and Landlord to complete all phases of the Construction Drawings and the permitting process and to receive the permits, and with Contractor for approval of the “Cost Proposal,” as that term is defined in Section 4.2 of this Tenant Work Letter, as soon as possible after the execution of the Lease, and, in that regard, shall meet with Landlord on a scheduled basis to be determined by Landlord, to discuss Xxxxxx’s progress in connection with the same. The applicable dates for approval of items, plans and drawings as described in this Section 3, Section 4, below, and in this Tenant Work Letter are set forth and further elaborated upon in Schedule 1 (the “Time Deadlines”), attached hereto. Xxxxxx agrees to comply with the Time Deadlines. Xxxxxxxx agrees to use commercially reasonable efforts to cooperate with Tenant to ensure compliance with the Time Deadlines.

SECTION 4

CONSTRUCTION OF THE TENANT IMPROVEMENTS

4.1 Contractor. A contractor designated by Landlord (“Contractor”) shall construct the Tenant Improvements.

4.2 Cost Proposal. After the Approved Working Drawings are signed by Landlord and Tenant, Landlord shall provide Tenant with a cost proposal in accordance with the Approved Working Drawings, which cost proposal shall include, as nearly as possible, the cost of all Tenant Improvement Allowance Items to be incurred by Tenant in connection with the design and construction of the Tenant Improvements (the “Cost Proposal”). Tenant shall approve and deliver the Cost Proposal to Landlord within five (5) business days of the receipt of the same, and upon receipt of the same by Landlord, Landlord shall be released by Tenant to purchase the items set forth in the Cost Proposal and to commence the construction relating to such items. The date by which Tenant must approve and deliver the Cost Proposal to Landlord shall be known hereafter as the “Cost Proposal Delivery Date”.

4.3 Construction of Tenant Improvements by Contractor under the Supervision of Landlord.

4.3.1 Over-Allowance Amount. On the Cost Proposal Delivery Date, Tenant shall deliver to Landlord cash in an amount (the “Over-Allowance Amount”) equal to the difference between (i) the amount of the Cost Proposal and (ii) the amount of the Tenant Improvement Allowance. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the Cost Proposal Delivery Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or the Tenant Improvements, any additional costs which arise in connection with such revisions, changes or substitutions or any other additional costs shall be paid by Tenant to Landlord immediately upon Xxxxxxxx’s request as an addition to the Over-Allowance Amount.

4.3.2 Landlord’s Retention of Contractor. Landlord shall independently retain Contractor, on behalf of Tenant, to construct the Tenant Improvements in accordance with the Approved Working Drawings and the Cost Proposal and Landlord shall supervise the construction by Contractor, and Tenant shall pay a construction supervision and management fee (the “Landlord Supervision Fee”) to Landlord in an amount equal to the product of (i) two percent (2%) and (ii) an amount equal to the Tenant Improvement Allowance plus the Over Allowance Amount (as such Over-Allowance Amount may increase pursuant to the terms of this Tenant Work Letter).

EXHIBIT B

CHINA BASIN LANDING
[LoopNet]

-4-

4.3.3. Contractor’s Warranties and Guaranties. Landlord hereby assigns to Tenant all warranties and guaranties by Contractor relating to the Tenant Improvements, and Tenant hereby waives all claims against Landlord relating to, or arising out of the construction of, the Tenant Improvements.

4.3.4 Tenant’s Covenants. Tenant hereby indemnifies Landlord for any loss, claims, damages or delays arising from the actions of Architect on the Premises or in the Building. Within ten (10) days after completion of construction of the Tenant Improvements, Tenant shall cause Contractor and Architect to cause a Notice of Completion to be recorded in the office of the County Recorder of the county in which the Building is located in accordance with Section 3093 of the Civil Code of the State of California or any successor statute and furnish a copy thereof to Landlord upon recordation, failing which, Landlord may itself execute and file the same on behalf of Tenant as Tenant’s agent for such purpose. In addition, immediately after the Substantial Completion of the Premises, Tenant shall have prepared and delivered to the Building a copy of the “as built” plans and specifications (including all working drawings) for the Tenant Improvements.

SECTION 5

COMPLETION OF THE TENANT IMPROVEMENTS;
LEASE COMMENCEMENT DATE

5.1 Ready for Occupancy. The Premises shall be deemed “Ready for Occupancy” upon the Substantial Completion of the Premises. For purposes of this Lease, “Substantial Completion” of the Premises shall occur upon the completion of construction of (i) the Tenant Improvements in the Premises pursuant to the Approved Working Drawings, and (ii) the Landlord Work, with the exception of any punch list items and any tenant fixtures, workstations, built-in furniture, or equipment to be installed by Tenant or under the supervision of Contractor.

5.2 Delay of the Substantial Completion of the Premises. Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:

5.2.1 Tenant’s failure to comply with the Time Deadlines; provided, however, that Xxxxxx’s failure to obtain the Permits by the date required in Schedule 1 shall not be deemed a Tenant delay to the extent such failure is caused by Xxxxxxxx’s failure to perform the Landlord work in a good and workmanlike manner;

5.2.2 Tenant’s failure to timely approve any matter requiring Xxxxxx’s approval;

5.2.3 A breach by Tenant of the terms of this Tenant Work Letter or the Lease;

5.2.4 Changes in any of the Construction Drawings after disapproval of the same by Landlord or because the same do not comply with Code or other applicable laws;

5.2.5 Xxxxxx’s request for changes in the Approved Working Drawings;

5.2.6 Tenant’s requirement for materials, components, finishes or improvements which are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Premises, as set forth in the Lease, or which are different from, or not included in, the Standard Improvement Package;

5.2.7 Changes to the Base, Shell and Core required by the Approved Working Drawings; or

5.2.8 Any other acts or omissions of Tenant, or its agents, or employees;

then, notwithstanding anything to the contrary set forth in the Lease or this Tenant Work Letter and regardless of the actual date of the Substantial Completion of the Premises, the date of the Substantial Completion of the Premises shall be deemed to be the date the Substantial

EXHIBIT B

CHINA BASIN LANDING
[LoopNet]

-5-

Completion of the Premises would have occurred if no Tenant delay or delays, as set forth above, had occurred; provided, however, that notwithstanding the foregoing, no Tenant delay shall be deemed to have occurred unless and until Landlord has provided prior written notice thereof to Tenant, specifying the action or inaction by Tenant which Landlord contends constitutes the Tenant delay.

SECTION 6

MISCELLANEOUS

6.1 Tenant’s Entry Into the Premises Xxxxx.xx Substantial Completion. Provided that Tenant and its agents do not interfere with Contractor’s work in the Building and the Premises, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing overstandard equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.1, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry. Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Xxxxxx’s actions pursuant to this Section 6.1.

6.2 Freight Elevators. Landlord shall, consistent with its obligations to other tenants of the Building, make the freight elevator reasonably available to Tenant in connection with initial decorating, furnishing and moving into the Premises.

6.3 Tenant’s Representative. Tenant has designated Xxxxxxx Xxxxx as its sole representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Landlord, shall have full authority and responsibility to act on behalf of the Tenant as required in this Tenant Work Letter.

6.4 Landlord’s Representative. Xxxxxxxx has designated General Manager as its sole representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Tenant, shall have full authority and responsibility to act on behalf of the Landlord as required in this Tenant Work Letter.

6.5 Tenant’s Agents. All subcontractors, laborers, materialmen, and suppliers retained directly by Tenant shall all be union labor in compliance with the then existing master labor agreements.

6.6 Time of the Essence in This Tenant Work Letter. Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. In all instances where Tenant is required to approve or deliver an item, if no written notice of approval is given or the item is not delivered within the stated time period, at Landlord’s sole option, at the end of such period the item shall automatically be deemed approved or delivered by Tenant and the next succeeding time period shall commence.

6.7 Tenant’s Lease Default. Notwithstanding any provision to the contrary contained in this Lease, if an event of default as described in the Lease, or a default by Tenant under this Tenant Work Letter, has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as set forth in Section 5 of this Tenant Work Letter), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease.

EXHIBIT B

CHINA BASIN LANDING
[LoopNet]

-6-

SCHEDULE 1 TO EXHIBIT B

TIME DEADLINES


	Dates	Actions to be Performed
A.	January 14, 2003	Final Space Plan to be completed by Xxxxxx and delivered to Landlord.

B.	January 24, 2003	Tenant to deliver Final Working Drawings to Landlord.

C.	February 10, 2003	Tenant to deliver Permits to Contractor.

D.	Five (5) business days after the receipt of the Cost Proposal by Tenant	Tenant to approve Cost Proposal and deliver Cost Proposal to Landlord.

SCHEDULE 1 TO
EXHIBIT B

CHINA BASIN LANDING
[LoopNet]

-1-

SCHEDULE 2 TO EXHIBIT B

DEMOLITION PLAN

SCHEDULE 2 TO
EXHIBIT B

CHINA BASIN LANDING
[LoopNet]

-1-

EXHIBIT C

CHINA BASIN LANDING

NOTICE OF LEASE TERM DATES


To:


		Re:		Office Lease dated , 20 between , a
				(“Landlord”), and , a
				(“Tenant”) concerning Suite on floor(s)
				of the office building located at ,
				San Francisco, California.

Gentlemen:

In accordance with the Office Lease (the “Lease”), we wish to advise you and/or confirm as follows:

1. The Lease Term shall commence on or has commenced on for a term of ending on .

2. Rent commenced to accrue on , in the amount of .

3. If the Lease Commencement Date is other than the first day of the month, the first billing will contain a pro rata adjustment. Each billing thereafter, with the exception of the final billing, shall be for the full amount of the monthly installment as provided for in the Lease.

4. Your rent checks should be made payable to at .

5. The exact number of rentable/usable square feet within the Premises is square feet.

6. Tenant’s Share as adjusted based upon the exact number of usable square feet within the Premises is %.


“Landlord”:
		,


a


By:

	Its:

Agreed to and Accepted
as of , 20 .

“Tenant”:



a


By:

		Its:


		EXHIBIT C		CHINA BASIN LANDING
		-1-		[LoopNet]

EXHIBIT D

CHINA BASIN LANDING

RULES AND REGULATIONS

Tenant shall faithfully observe and comply with the following Rules and Regulations. Landlord shall not be responsible to Tenant for the nonperformance of any of said Rules and Regulations by or otherwise with respect to the acts or omissions of any other tenants or occupants of the Project. In the event of any conflict between the Rules and Regulations and the other provisions of this Lease, the latter shall control.

1. Tenant shall not alter any lock or install any new or additional locks or bolts on any doors or windows of the Premises without obtaining Landlord’s prior written consent. Tenant shall bear the cost of any lock changes or repairs required by Tenant. Two keys will be furnished by Landlord for the Premises, and any additional keys required by Tenant must be obtained from Landlord at a reasonable cost to be established by Landlord. Upon the termination of this Lease, Tenant shall restore to Landlord all keys of stores, offices, and toilet rooms, either furnished to, or otherwise procured by, Tenant and in the event of the loss of keys so furnished, Tenant shall pay to Landlord the cost of replacing same or of changing the lock or locks opened by such lost key if Landlord shall deem it necessary to make such changes.

2. Landlord reserves the right to close and keep locked all entrance and exit doors of the Building during such hours as are customary for comparable buildings in the vicinity of the Building. Tenant, its employees and agents must be sure that the doors to the Building are securely closed and locked when leaving the Premises if it is after the normal hours of business for the Building. Any tenant, its employees, agents or any other persons entering or leaving the Building at any time when it is so locked, or any time when it is considered to be after normal business hours for the Building, may be required to sign the Building register. Access to the Building may be refused unless the person seeking access has proper identification or has a previously arranged pass for access to the Building. Xxxxxxxx will furnish passes to persons for whom Xxxxxx requests same in writing. Tenant shall be responsible for all persons for whom Tenant requests passes and shall be liable to Landlord for all acts of such persons. The Landlord and his agents shall in no case be liable for damages for any error with regard to the admission to or exclusion from the Building of any person. In case of invasion, mob, riot, public excitement, or other commotion, Landlord reserves the right to prevent access to the Building or the Project during the continuance thereof by any means it deems appropriate for the safety and protection of life and property.

3. No furniture, freight or equipment of any kind shall be brought into or removed from the Building without prior notice to Landlord. All moving activity into or out of the Building shall be scheduled with Landlord and done only at such time and in such manner as Landlord designates. Landlord shall have the right to prescribe the weight, size and position of all safes and other heavy property brought into the Building and also the times and manner of moving the same in and out of the Building. Safes and other heavy objects shall, if considered necessary by Landlord, stand on supports of such thickness as is necessary to properly distribute the weight. Landlord will not be responsible for loss of or damage to any such safe or property in any case. Any damage to any part of the Building, its contents, occupants or visitors by moving or maintaining any such safe or other property shall be the sole responsibility and expense of Tenant.

4. No sign, advertisement, notice or handbill shall be exhibited, distributed, painted or affixed by Tenant on any part of the Premises or the Building without the prior written consent of the Landlord. Tenant shall not disturb, solicit, peddle, or canvass any occupant of the Project and shall cooperate with Landlord and its agents of Landlord to prevent same.

5. The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they were constructed, and no foreign substance of any kind whatsoever shall be thrown therein. The expense of any breakage, stoppage or damage resulting from the violation of this rule shall be borne by the tenant who, or whose servants, employees, agents, visitors or licensees shall have caused same.

EXHIBIT D

CHINA BASIN LANDING
[LoopNet]

-1-

6. Tenant shall not overload the floor of the Premises, nor mark, drive nails or screws, or drill into the partitions, woodwork or drywall or in any way deface the Premises or any part thereof without Xxxxxxxx’s prior written consent. Tenant shall not purchase spring water, ice, towel, linen, maintenance or other like services from any person or persons not approved by Landlord.

7. Except for vending machines intended for the sole use of Tenant’s employees and invitees, no vending machine or machines other than fractional horsepower office machines shall be installed, maintained or operated upon the Premises without the written consent of Landlord.

8. Tenant shall not use or keep in or on the Premises, the Building, or the Project any kerosene, gasoline, explosive material, corrosive material, material capable of emitting toxic fumes, or other inflammable or combustible fluid chemical, substitute or material. Tenant shall provide material safety data sheets for any Hazardous Material used or kept on the Premises.

9. Tenant shall not use, keep or permit to be used or kept, any foul or noxious gas or substance in or on the Premises, or permit or allow the Premises to be occupied or used in a manner offensive or objectionable to Landlord or other occupants of the Project by reason of noise, odors, or vibrations, or interfere with other tenants or those having business therein, whether by the use of any musical instrument, radio, phonograph, or in any other way. Tenant shall not throw anything out of doors, windows or skylights or down passageways.

10. Tenant shall not bring into or keep within the Project, the Building or the Premises any animals, birds, aquariums, or, except in areas designated by Landlord, bicycles or other vehicles.

11. No cooking shall be done or permitted on the Premises, nor shall the Premises be used for the storage of merchandise, for lodging or for any improper, objectionable or immoral purposes. Notwithstanding the foregoing, Underwriters’ laboratory-approved equipment and microwave ovens may be used in the Premises for heating food and brewing coffee, tea, hot chocolate and similar beverages for employees and visitors, provided that such use is in accordance with all applicable federal, state, county and city laws, codes, ordinances, rules and regulations.

12. The Premises shall not be used for manufacturing or for the storage of merchandise except as such storage may be incidental to the use of the Premises provided for in the Summary. Tenant shall not occupy or permit any portion of the Premises to be occupied as an office for a messenger-type operation or dispatch office, public stenographer or typist, or for the manufacture or sale of liquor, narcotics, or tobacco in any form, or as a medical office, or as a xxxxxx or manicure shop, or as an employment bureau without the express prior written consent of Landlord. Tenant shall not engage or pay any employees on the Premises except those actually working for such tenant on the Premises nor advertise for laborers giving an address at the Premises.

13. Landlord reserves the right to exclude or expel from the Project any person who, in the judgment of Landlord, is intoxicated or under the influence of liquor or drugs, or who shall in any manner do any act in violation of any of these Rules and Regulations.

14. Tenant, its employees and agents shall not loiter in or on the entrances, corridors, sidewalks, lobbies, courts, halls, stairways, elevators, vestibules or any Common Areas for the purpose of smoking tobacco products or for any other purpose, nor in any way obstruct such areas, and shall use them only as a means of ingress and egress for the Premises.

15. Tenant shall not waste electricity, water or air conditioning and agrees to cooperate fully with Landlord to ensure the most effective operation of the Building’s heating and air conditioning system, and shall refrain from attempting to adjust any controls. Tenant shall participate in recycling programs undertaken by Landlord.

16. Tenant shall store all its trash and garbage within the interior of the Premises. No material shall be placed in the trash boxes or receptacles if such material is of such nature that it may not be disposed of in the ordinary and customary manner of removing and disposing of trash and garbage in San Francisco, California without violation of any law or ordinance governing such disposal. All trash, garbage and refuse disposal shall be made only through entry-ways and

EXHIBIT D

CHINA BASIN LANDING
[LoopNet]

-2-

elevators provided for such purposes at such times as Landlord shall designate. If the Premises is or becomes infested with vermin as a result of the use or any misuse or neglect of the Premises by Tenant, its agents, servants, employees, contractors, visitors or licensees, Tenant shall forthwith, at Tenant’s expense, cause the Premises to be exterminated from time to time to the satisfaction of Landlord and shall employ such licensed exterminators as shall be approved in writing in advance by Landlord.

17. Tenant shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any governmental agency.

18. No awnings or other projection shall be attached to the outside walls of the Building without the prior written consent of Landlord, and no curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises other than Landlord standard drapes. All electrical ceiling fixtures hung in the Premises or spaces along the perimeter of the Building must be fluorescent and/or of a quality, type, design and a warm white bulb color approved in advance in writing by Landlord. Neither the interior nor exterior of any windows shall be coated or otherwise sunscreened without the prior written consent of Landlord. Tenant shall be responsible for any damage to the window film on the exterior windows of the Premises and shall promptly repair any such damage at Tenant’s sole cost and expense. Tenant shall keep its window coverings closed during any period of the day when the sun is shining directly on the windows of the Premises. Prior to leaving the Premises for the day, Tenant shall draw or lower window coverings and extinguish all lights. Tenant shall abide by Xxxxxxxx’s regulations concerning the opening and closing of window coverings which are attached to the windows in the Premises, if any, which have a view of any interior portion of the Building or Building Common Areas.

19. Tenant hereby acknowledges that Landlord shall have no obligation to provide guard service or other security measures for the benefit of the Premises, the Building or the Project. Tenant hereby assumes all responsibility for the protection of Tenant and its agents, employees, contractors, invitees and guests, and the property thereof, from acts of third parties, including keeping doors locked and other means of entry to the Premises closed, whether or not Landlord, at its option, elects to provide security protection for the Project or any portion thereof. Tenant further assumes the risk that any safety and security devices, services and programs which Landlord elects, in its sole discretion, to provide may not be effective, or may malfunction or be circumvented by an unauthorized third party, and Tenant shall, in addition to its other insurance obligations under this Lease, obtain its own insurance coverage to the extent Tenant desires protection against losses related to such occurrences. Tenant shall cooperate in any reasonable safety or security program developed by Landlord or required by law.

20. No auction, liquidation, fire sale, going-out-of-business or bankruptcy sale shall be conducted in the Premises without the prior written consent of Landlord.

21. No tenant shall use or permit the use of any portion of the Premises for living quarters, sleeping apartments or lodging rooms.

Landlord reserves the right at any time to change or rescind any one or more of these Rules and Regulations, or to make such other and further reasonable Rules and Regulations as in Landlord’s judgment may from time to time be necessary for the management, safety, care and cleanliness of the Premises, Building, the Common Areas and the Project, and for the preservation of good order therein, as well as for the convenience of other occupants and tenants therein. Landlord may waive any one or more of these Rules and Regulations for the benefit of any particular tenants, but no such waiver by Landlord shall be construed as a waiver of such Rules and Regulations in favor of any other tenant, nor prevent Landlord from thereafter enforcing any such Rules or Regulations against any or all tenants of the Project. Tenant shall be deemed to have read these Rules and Regulations and to have agreed to abide by them as a condition of its occupancy of the Premises.

EXHIBIT D

CHINA BASIN LANDING
[LoopNet]

-3-

EXHIBIT E

CHINA BASIN LANDING

FORM OF TENANT’S ESTOPPEL CERTIFICATE

The undersigned as Tenant under that certain Office Lease (the “Lease”) made and entered into as of , 200 by and between as Landlord, and the undersigned as Tenant, for Premises on the floor(s) of the office building located at , San Francisco, California , certifies as follows:

1. Attached hereto as Exhibit A is a true and correct copy of the Lease and all amendments and modifications thereto. The documents contained in Exhibit A represent the entire agreement between the parties as to the Premises and the project of which the Premises are a part.

2. The undersigned currently occupies the Premises described in the Lease, the Lease Term commenced on , and the Lease Term expires on , and the undersigned has no option to terminate or cancel the Lease or to purchase all or any part of the Premises, the Building and/or the Project.

3. Base Rent became payable on .

4. The Lease is in full force and effect and has not been modified, supplemented or amended in any way except as provided in Exhibit A.

5. Tenant has not transferred, assigned, or sublet any portion of the Premises nor entered into any license or concession agreements with respect thereto except as follows:

6. Tenant shall not modify the documents contained in Exhibit A without the prior written consent of Xxxxxxxx’s mortgagee.

7. All monthly installments of Base Rent, all Additional Rent and all monthly installments of estimated Additional Rent have been paid when due through . The current monthly installment of Base Rent is $ .

8. All conditions of the Lease to be performed by Landlord necessary to the enforceability of the Lease have been satisfied and Landlord is not in default thereunder. In addition, the undersigned has not delivered any notice to Landlord regarding a default by Landlord thereunder.

9. No rental has been paid more than thirty (30) days in advance and no security has been deposited with Landlord except as provided in the Lease.

10. As of the date hereof, there are no existing defenses or offsets, to the undesigned’s knowledge, claims or any basis for a claim, that the undersigned has against Landlord.

11. If Tenant is a corporation or partnership, each individual executing this Estoppel Certificate on behalf of Tenant hereby represents and warrants that Tenant is a duly formed and existing entity qualified to do business in California and that Tenant has full right and authority to execute and deliver this Estoppel Certificate and that each person signing on behalf of Tenant is authorized to do so.

12. There are no actions pending against the undersigned or any guarantor of the Lease under the bankruptcy or similar laws of the United States or any state.

EXHIBIT E

CHINA BASIN LANDING
[LoopNet]

-1-

13. Other than in compliance with all applicable laws and incidental to the ordinary course of the use of the Premises, the undersigned has not used or stored any hazardous substances in the Premises.

14. To the undersigned’s knowledge, all tenant improvement work to be performed by Landlord under the Lease has been completed in accordance with the Lease and has been accepted by the undersigned and all reimbursements and allowances due to the undersigned under the Lease in connection with any tenant improvement work have been paid in full.

The undersigned acknowledges that this Estoppel Certificate may be delivered to Landlord or to a prospective mortgagee or prospective purchaser, and acknowledges that said prospective mortgagee or prospective purchaser will be relying upon the statements contained herein in making the loan or acquiring the property of which the Premises are a part and that receipt by it of this certificate is a condition of making such loan or acquiring such property.

Executed at on the ___ day of , 20___.


“Tenant”:
		,

a


By:

	Its:


By:

	Its:


Exhibit F		CHINA BASIN LANDING
		[LoopNet]

- 2 -

Document Metadata

Table of Contents

OFFICE LEASE CHINA BASIN LANDING PWREF/MCC-CHINA BASIN L.L.C., a Delaware limited liability company, as Landlord, and LOOPNET, a California corporation, as Tenant.

Document Metadata