Products Products available under this Contract are limited to Software, including Software as a Service, products and related products as specified in Appendix C, Pricing Index. Vendor may incorporate changes to their product offering; however, any changes must be within the scope of products awarded based on the posting described in Section 1.B above. Vendor may not add a manufacturer’s product line which was not included in the Vendor’s response to the solicitation described in Section 1.B above.
Packaging Tangible product shall be securely and properly packed for shipment, storage, and stocking in appropriate, clearly labeled, shipping containers and according to accepted commercial practice, without extra charge for packing materials, cases, or other types of containers. All containers and packaging shall become and remain Customer’s property.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Labeling Upon request, Lessee will xxxx the Equipment indicating Lessor's interest with labels provided by Lessor. Lessee will keep all Equipment free from any other marking or labeling which might be interpreted as a claim of ownership.
Animals The Hirer shall ensure that no animals (including birds) except guide dogs are brought into the premises, other than for a special event agreed to by the Village Hall. No animals whatsoever are to enter the kitchen at any time.
Field The term “
Borrower Products Except as described on Schedule 5.11, no Intellectual Property owned by Borrower or Borrower Product has been or is subject to any actual or, to the knowledge of Borrower, threatened litigation, proceeding (including any proceeding in the United States Patent and Trademark Office or any corresponding foreign office or agency) or outstanding decree, order, judgment, settlement agreement or stipulation that restricts in any manner Borrower’s use, transfer or licensing thereof or that may affect the validity, use or enforceability thereof. There is no decree, order, judgment, agreement, stipulation, arbitral award or other provision entered into in connection with any litigation or proceeding that obligates Borrower to grant licenses or ownership interest in any future Intellectual Property related to the operation or conduct of the business of Borrower or Borrower Products. Borrower has not received any written notice or claim, or, to the knowledge of Borrower, oral notice or claim, challenging or questioning Borrower’s ownership in any Intellectual Property (or written notice of any claim challenging or questioning the ownership in any licensed Intellectual Property of the owner thereof) or suggesting that any third party has any claim of legal or beneficial ownership with respect thereto nor, to Borrower’s knowledge, is there a reasonable basis for any such claim. Neither Borrower’s use of its Intellectual Property nor the production and sale of Borrower Products infringes the Intellectual Property or other rights of others.
Waste Borrower shall not commit or suffer any waste of the Property or make any change in the use of the Property which will in any way materially increase the risk of fire or other hazard arising out of the operation of the Property, or take any action that might invalidate or give cause for cancellation of any Policy, or do or permit to be done thereon anything that may in any way impair the value of the Property or the security of this Security Instrument. Borrower will not, without the prior written consent of Lender, permit any drilling or exploration for or extraction, removal, or production of any minerals from the surface or the subsurface of the Land, regardless of the depth thereof or the method of mining or extraction thereof.
Exports The parties acknowledge that the export of technical data, materials or products is subject to the exporting party receiving any necessary export licenses and that the parties cannot be responsible for any delays attributable to export controls which are beyond the reasonable control of either party. Lexicon and BMS agree not to export or re-export, directly or indirectly, any information, technical data, the direct product of such data, samples or equipment received or generated under this Agreement in violation of any applicable export control Laws. Lexicon and BMS agree to obtain similar covenants from their Sublicensees and contractors with respect to the subject matter of this Section 12.11.
