Untimely Plan Implementation Sample Clauses

Untimely Plan Implementation. If Contractor fails to achieve Plan implementation by January 1, 2023, it will pay liquidated damages of $25,000 per Calendar Day, not to exceed $500,000, unless any such delay is due to the Department’s failure to comply with the defined timeline. Contractor will pay this amount of liquidated damages for every full or partial Calendar Day until the Plan is fully implemented.
Sample 1
AutoNDA by SimpleDocs
Untimely Plan Implementation. If Contractor materially fails to achieve Plan implementation by January 1, 2016, it shall pay liquidated damages of $1,000 per Calendar Day, unless any such delay is due to the Department’s errors or omissions or failure to comply with the defined timeline. Contractor will pay this amount of liquidated damages for every full or partial Calendar Day until the Plan is fully implemented. In addition to the above, Contractor will pay the indicated amount of liquidated damages for each Calendar Day beyond the date indicated in the Contractor’s Implementation Plan, for any Implementation Plan milestone that is not materially and timely implemented, unless any such delay is the result of the Department’s errors or omissions or failure to comply with the defined timeline including but not limited to the following: Milestone Completion Date Liquidated Damages Eligibility Automation finalized October 30, 2015 $1,000/day Load open enrollment eligibility December 12, 2015 $1,000/day Load production eligibility file December 31, 2015 $1,000/day Finance Finalize billing arrangements October 10, 2015 $1,000/day
Sample 1
Untimely Plan Implementation. If Service Provider fails to achieve Plan implementation by January 1, 2015, it will pay liquidated damages of $3 million per month, unless any such delay is due to the Department’s failure to comply with the defined timeline. Service Provider will pay this amount of liquidated damages for every full or partial calendar month thereafter until the Plan is fully implemented. For example, if the Plan is implemented any day between January 2 and February 1, total damages will be $1,000 per service provider plan participant per month, not to exceed $3 million; if the Plan is implemented any day between February 2 and March 1, total damages will be $1,000 per service provider plan participant per month, not to exceed $6 million. In addition to the above, Service Provider will pay the indicated amount of liquidated damages for each calendar day beyond the date indicated in the Service Providers Implementation Plan, for any Implementation Plan milestone that is not timely implemented, including but not limited to the following: Milestone Completion Date Liquidated Damages Eligibility Automation finalized October, 30, 2014 $10,000/day Load production eligibility file December 12, 2014 $100,000/day Mail identification cards December 12, 2014 $100,000/day FinanceFinalize billing arrangements October 10, 2014 $10,000/day
Sample 1
Untimely Plan Implementation. If Service Provider fails to achieve full implementation of Services by January 1, 2013 it shall pay liquidated damages in the amount of $50,000 per month. Service Provider shall pay this amount of liquidated damages for every full or partial calendar month thereafter until the Service is fully implemented. For example, if the Service is implemented any day between January 2 and February 1, total damages shall be $50,000; if the Service is implemented any day between February 2 and March 1, total damages shall be $100,000. In addition to the above, Service Provider shall pay the indicated amount of liquidated damages for each calendar day beyond January 1, 2013, for any Implementation Plan (attached as BAFO Attachment A-3: Project Implementation Plan) milestone that is not timely implemented, including but not limited to the following: Milestone Completion Date Liquidated Damages Data Transfer ProcessEstablish secure transfer methods TBD* $5,000/day Load historical eligibility and claims files TBD* $5,000/day Create and test reporting database TBD* $5,000/day User Training Perform user training TBD* $5,000/day Assign user access (login credentials) TBD* $10,000/day OtherLevel II Background Checks TBD* $5,000/day *All Completion Dates will be determined during Negotiations.
Sample 1
Untimely Plan Implementation. If Contractor fails to achieve Plan implementation by January 1, 2016, it shall pay liquidated damages of $25,000 per Calendar Day, not to exceed $500,000, unless any such delay is due to the Department’s failure to comply with the defined timeline. Contractor will pay this amount of liquidated damages for every full or partial Calendar Day until the Plan is fully implemented. In addition to the above, Contractor will pay the indicated amount of liquidated damages for each Calendar Day beyond the date indicated in the Contractor’s Implementation Plan, for any Implementation Plan milestone that is not timely implemented, including but not limited to the following: Milestone Completion Date Liquidated Damages Eligibility Automation finalized October 30, 2015 $10,000/day Load open enrollment eligibility December 12, 2015 $10,000/day Load production eligibility file December 31, 2015 $10,000/day Finance Finalize billing arrangements October 10, 2015 $10,000/day
Sample 1

Related to Untimely Plan Implementation

  • Project Implementation 2. The Borrower shall:

  • COOPERATION IN IMPLEMENTATION On demand of the other Spouse and without undue delay or expense, each Spouse shall execute, acknowledge, or deliver any instrument, furnish any information, or perform any other acts reasonably necessary to carry out the provisions of this Agreement. If a Spouse fails to execute any document as required by this provision, the court may appoint the court clerk or his or her authorized designee to execute the document on that Xxxxxx’s behalf.

  • Implementation Program 1. The Borrower shall:

  • Implementation Plan The Authority shall cause to be prepared an Implementation Plan meeting the requirements of Public Utilities Code Section 366.2 and any applicable Public Utilities Commission regulations as soon after the Effective Date as reasonably practicable. The Implementation Plan shall not be filed with the Public Utilities Commission until it is approved by the Board in the manner provided by Section 4.9.

  • Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.

  • Proposing Integration Activities in the Planning Submission No integration activity described in section 6.3 may be proposed in a CAPS unless the LHIN has consented, in writing, to its inclusion pursuant to the process set out in section 6.3(b).

  • Performance Improvement Plan timely and accurate completion of key actions due within the reporting period 100 percent The Supplier will design and develop an improvement plan and agree milestones and deliverables with the Authority

  • Implementation of Strategic Plan Goals This Agreement supports the County’s Strategic Plan, Goal 1, Operational Effectiveness/Fiscal Sustainability. This Agreement will provide revenue reimbursement to the Department for services rendered.

  • Development Plans 4.3.1 For each Licensed Indication and corresponding Licensed Product in the Field, Licensee will prepare and deliver to Licensor a development plan and budget (each a “Development Plan”). The initial Development Plans for each Licensed Indication will be delivered within […***…] after the Grant Date for such Licensed Indication.

  • Claims Review Population A description of the Population subject to the Claims Review.

Time is Money Join Law Insider Premium to draft better contracts faster.