Unforeseen Difficulties Sample Clauses

Unforeseen Difficulties. Except as otherwise expressly provided in Section 2.12 of the Agreement and in other Sections of the Contract Documents, the Contractor acknowledges that it has assumed the risk and that the Contract consideration includes such provisions as it deems proper for any unforeseeable obstacles or difficulties which it may encounter in the performance of the work.
AutoNDA by SimpleDocs
Unforeseen Difficulties. Except as otherwise specified in the Contract Agreement:
Unforeseen Difficulties. All loss or damage arising out of the nature of the Work to be done under this Contract, or from any unforeseen obstructions or difficulties which may be encountered during the progress of the Work and in the prosecution of the same, shall be sustained by the Design Build Entity, except as may be otherwise specifically provided by the Contract Documents.
Unforeseen Difficulties. The CONTRACTOR shall promptly notify the ENGINEER of any work site conditions per the “CHANGED CONDITIONS” Subsection of the “CONDITIONS AFFECTING THE WORK” Section of the General Conditions, in writing, upon their discovery and identification, and before they are disturbed. All loss or damage arising out of the nature of the work to be accomplished under the CONTRACT, or from any unforeseen obstructions or difficulties which may be encountered during the progress of the work and in the prosecution of the same, or from the action of elements, or from encumbrances on the line of work, shall be sustained by the CONTRACTOR for failure to notify the ENGINEER per the “CHANGED CONDITIONS” Subsection of the “CONDITIONS AFFECTING THE WORK” Section of the General Conditions and these Special Provisions.

Related to Unforeseen Difficulties

  • Unforeseen Circumstances Contractor is not responsible for any delay caused by natural disaster, war, civil disturbance, labor dispute or other cause beyond Contractor's reasonable control, provided Contractor gives written notice to County of the cause of the delay within 10 days of the start of the delay.

  • FORCE MAJEURE CIRCUMSTANCES Lithium Hosting, llc CANNOT and WILL NOT be liable for any failure or delay in doing its professional duties resulting from circumstances beyond its physical control. Such circumstances may represent acts of any governmental body, war, rebellion, sabotage, embargo, fire, flood or other natural disaster, strike or other labor disturbances, interruption of or delay in transportation, unavailability of, interruption or delay in telecommunications or third party services (including DNS propagation), failure of third party software or hardware, or inability to obtain raw materials, supplies or power used in or equipment needed for provisioning of the Services.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:

  • SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:

  • Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event.

  • Weather 6.1 No extension of time shall be granted for delays resulting from normal weather conditions prevailing in the area as defined by the average of the last ten years of weather data as recorded by the U.S. Department of Commerce, National Oceanic and Atmospheric Administration at the Fort Lauderdale Weather Station.

  • Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon, and the obligation of the party giving such notice, so far as it is affected by such Force Majeure, shall be suspended during the continuance of the inability then claimed, except as hereinafter provided, but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. Choice of Law The Agreement between the Vendor and TIPS/ESC Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. Venue, Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of the parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may now or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and determined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a copy of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the parties irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first sentence of this Section may be served on any party anywhere in the world. Venue for any dispute resolution process, other than litigation, between TIPS and the Vendor shall be located in Camp or Xxxxx County, Texas.

  • Problems To try to resolve fairly any problems, grievances and difficulties you may have while you volunteer with us. • In the event of an unresolved problem, to offer an opportunity to discuss the issues in accordance with the procedures set out in the Volunteer Involvement Policy.

  • Inclement Weather 24.1 This Inclement Weather clause sets out the full rights, obligations and entitlements of the parties and establishes the conditions under which payment for periods of inclement weather shall be made.

Time is Money Join Law Insider Premium to draft better contracts faster.