Typical Sections The Engineer shall prepare typical sections for all proposed and existing roadways and structures. Typical sections must include width of travel lanes, shoulders, outer separations, border widths, curb offsets, managed lanes, and ROW. The typical section must also include Proposed Profile Gradeline (PGL), centerline, pavement design, longitudinal joints, side slopes, sodding or seeding limits, concrete traffic barriers and sidewalks, if required, station limits, common proposed and existing structures including retaining walls, existing pavement removal, riprap, limits of embankment and excavation, etc.
The following sections of Section 4 OGS Centralized Contract Terms and Conditions have been renumbered as depicted in the following chart: Current Amended Section Title 4.25 4.26 Severability 4.26 4.27 Entire Agreement
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
PROCEDURES FOR SUPPLEMENTAL PAYMENT CALCULATIONS All calculations required by this Article VI, including but not limited to: (i) the calculation of the Applicant’s Stipulated Supplemental Payment Amount; (ii) the determination of both the Annual Limit and the Aggregate Limit; (iii) the effect, if any, of the Aggregate Limit upon the actual amount of Supplemental Payments eligible to be paid to the District by the Applicant; and (iv) the carry forward and accumulation of any of the Applicant’s Stipulated Supplemental Payment Amounts unpaid by the Applicant due to the Aggregate Limit in previous years, shall be calculated by the Third Party selected pursuant to Section 4.3.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
CONTRACT EXHIBIT I PREFERRED PRICING AFFIDAVIT This preferred-pricing affidavit is entered into in accordance with section 216.0113, F.S., and as required by Contract No. 80101507-21-STC-ITSA (“Contract”) between (“Contractor”) and the Department of Management Services. As the person authorized by Contractor to sign this affidavit, I attest that the Contractor is in full compliance with the preferred-pricing clause of the Contract. Contractor’s Name: By: Signature Printed Name/Title Date: STATE OF COUNTY OF Sworn to (or affirmed) and subscribed before me this day of , by . Signature of Notary Vendor Name: FEIN# Vendor’s Authorized Representative Name and Title: Address: City, State, and Zip code: Phone Number: ( ) - E-mail: CORPORATE SEAL (IF APPLICABLE) (Print, Type, or Stamp Commissioned Name of Notary Public) [Check One] Personally Known OR Produced the following I.D.
Tax Law Section 5-A Section 5-a of the Tax Law, requires certain Contractors awarded State Contracts for commodities, services and technology valued at more than $100,000 to certify to the NYS Department of Taxation and Finance (DTF) that they are registered to collect New York State and local sales and compensating use taxes. The law applies to Contracts where the total amount of such Contractors’ sales delivered into New York State are in excess of $300,000 for the four quarterly periods immediately preceding the quarterly period in which the certification is made, and with respect to any affiliates and subcontractors whose sales delivered into New York State exceeded $300,000 for the four quarterly periods immediately preceding the quarterly period in which the certification is made. A Vendor is required to file the completed and notarized Form ST-220-CA with OGS certifying that the Vendor filed the ST-220-TD with the NYS Department of Taxation and Finance (DTF). Please note that the NYS Department of Taxation and Finance should receive the completed Form ST-220-TD, not OGS. OGS should only receive the Form ST-220-CA. Proposed Contractors should complete and return the certification forms within five (5) business days of request (if the forms are not completed and returned with Vendor Submission). Failure to make either of these filings may render a Vendor non- responsive and non-responsible. Each Vendor shall take the necessary steps to provide properly certified forms within a timely manner to ensure compliance with the law. Website links to the Contractor certification forms and instructions are provided below. Form No. ST- 220-TD must be filed with and returned directly to DTF and can be found at xxxx://xxx.xxx.xx.xxx/pdf/current_forms/st/st220td_fill_in.pdf. Unless the information upon which the ST-220-TD is based changes, this form only needs to be filed once with DTF. If the information changes for the Contractor, its affiliate(s), or its subcontractor(s), a new Form No. ST-220-TD must be filed with DTF. Form ST-220-CA must be submitted to OGS. This form provides the required certification that the Contractor filed the ST-220-TD with DTF. This form can be found at xxxx://xxx.xxx.xx.xxx/pdf/current_forms/st/st220ca_fill_in.pdf. Vendors may call DTF at 000-000-0000 for any and all questions relating to §5-a of the Tax Law and relating to a company's registration status with the DTF. For additional information and frequently asked questions, please refer to the DTF web site: xxxx://xxx.xxx.xx.xxx.
Appendix No 4: The proposed fee(s) submitted by this contractor in response to the RFP, or any negotiated fee(s) that resulted thereto, which fee(s) shall apply to each procurement that ensues from this contract;
GEOGRAPHIC AREA AND SECTOR SPECIFIC ALLOWANCES, CONDITIONS AND EXCEPTIONS The following allowances and conditions shall apply where relevant: Where the company does work which falls under the following headings, the company agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
