Tower Owner Default. Any one or more of the following events shall constitute a default by Tower Owner (“Tower Owner Default”):
Tower Owner Default Sample Clauses
Related to Tower Owner Default
Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract.
Default by Lessor Lessor shall not be in default unless Lessor fails to perform obligations required of Lessor within a reasonable time, but in no event later than thirty (30) days after written notice by Lessee to Lessor and to the holder of any first mortgage or deed of trust covering the Premises whose name and address shall have theretofore been furnished to Lessee in writing, specifying wherein Lessor has failed to perform such obligation; provided, however, that if the nature of Lessor's obligation is such that more than thirty (30) days are required for performance then Lessor shall not be in default if Lessor commences performance within such 30-day period and thereafter diligently prosecutes the same to completion.
Default by Lessee (a) If Lessee shall make default in making any payment herein provided for and any such default shall continue for a period of ten (10) business days after written notice to Lessee, or if Lessee shall make default in the performance of any obligation of Lessee herein (other than as to payment of money) and any such default shall continue for a period of thirty (30) days after written notice to Lessee, or if Lessee shall file a voluntary petition in bankruptcy, or if Lessee shall file any petition or institute any proceedings under any Insolvency or Bankruptcy Act or any amendment thereto hereafter made, seeking to effect its reorganization or a composition with its creditors, or if, in any proceedings based on the insolvency of Lessee or relating to bankruptcy proceedings, a receiver or trustee shall be appointed for Lessee or the Leased Premises, or if any proceedings shall be commenced for the reorganization of Lessee (which, in the case of involuntary proceedings, are not dismissed or stayed within 30 days of the commencement thereof), or if the leasehold estate created hereby shall be taken on execution or by any process of law, or if Lessee shall admit in writing its inability to pay its obligations generally as they become due, then Lessor may, at its option, terminate this Lease without notice, and declare all amounts due or to become due hereunder immediately due and payable, and Lessor's agents and servants may immediately, or any time thereafter, reenter the Leased Premises by reasonably necessary force, summary proceedings, or otherwise, and remove all persons and properly therein, without being liable to indictment, prosecution, or damage therefor, and Lessee hereby expressly waives the service of any notice in writing of intention to reenter said Leased Premises. Lessor may, in addition to any other remedy provided by law or permitted herein, at its option, relet the Leased Premises (or any part thereof) on behalf of Lessee, applying any monies collected first to the payment of expenses of resuming or obtaining possession, and, second, to the payment of the costs of placing the premises in rentable condition, including any leasing commission, and, third, to the payment of rent due hereunder, and any other damages due to the Lessor. Any surplus remaining thereafter shall be paid to Lessee, and Lessee shall remain liable for any deficiency in rental, the amount of which deficiency shall be paid upon demand therefor to Lessor.
Default by Seller Except as specifically provided elsewhere in this Contract, in the event that Seller fails to consummate this Contract or if Seller fails to perform any of Seller's other material obligations hereunder either prior to or at the Closing and such failure or refusal results from any reason other than the termination of this Contract by Purchaser pursuant to a right to terminate expressly set forth in this Contract or Purchaser's failure to perform Purchaser's obligations under this Contract, Purchaser may as its only remedy either (i) terminate this Contract by giving written notice thereof to Seller prior to or at the Closing, in which event Purchaser will be entitled to a return of the Deposit Note, whereupon neither party hereto will have any further rights or obligations hereunder, except (a) that Seller will authorize the Title Company to deliver to Purchaser the Deposit Note and Title Company will deliver the Deposit Note to Purchaser free of any claims by Seller or any other person with respect thereto, (b) that Seller shall reimburse Purchaser for its out of pocket costs associated with the negotiation and preparation of this Agreement and its examination of the Property, including, the fees and disbursements of its counsel, advisers, and agents, and (c) for provisions which survive Closing by their terms or (ii) enforce specific performance of Seller's duties and obligations under this Contract, provided that the right to enforce specific performance shall not require Seller to remove any title encumbrances placed on the Property after the Effective Date or require Seller to perform any covenant beyond the then current ability of Seller. In the event Purchaser fails to file an action for specific performance of this Contract on or before ninety (90) days after the date of such non-performance, Purchaser shall be deemed to have elected to proceed under clause (i) above and shall be deemed to have waived its right to enforce specific performance of this Contract.
Seller Default If a Seller, prior to the Closing, defaults in its representations, warranties, covenants, or obligations under this Agreement, including to sell its Property as required by this Agreement and such default continues for more than ten (10) days after written notice from Purchaser, then, at Purchaser’s election, Purchaser may either (i) if Purchaser has closed on the remaining Properties for which there has been no default alleged, seek specific performance of the defaulting Seller’s obligations pursuant to this Agreement (but not damages); or (ii) give a Termination Notice to Sellers’ Representative of Purchaser’s decision to terminate this Agreement for the Properties for which there was such a default, proceed to Closing on the remaining Properties, and the applicable Seller shall pay to Purchaser an amount equal to the Applicable Share of the Deposit for the terminated Properties, Return on Deposit on the Applicable Share amount (or credit the same to Purchaser against the Base Purchase Price for the other Properties for which this Agreement has not been terminated), an amount equal to the actual third party costs incurred by Purchaser relating to breaking Purchaser’s rate lock with respect to the terminated Properties (provided Sellers’ liability for such costs to Purchaser related to breaking the rate lock shall not exceed $2,000,000 in the aggregate regardless of the number of terminated Properties), and, if Sellers’ default under this Agreement resulted from an intentional action or inaction of Sellers taken in bad faith (excluding any action or inaction a Seller reasonably takes or refuses to take in response to a request or requirement of any Lender) that causes one (1) or more of the Closings not to occur solely as a result of such action or inaction, a termination fee of $8,000,000 (the “Termination Fee”) (provided Purchaser has otherwise performed it obligations under this Agreement with respect to the other remaining Properties, including delivery of the Purchase Price therefor, and Sellers have been afforded notice and an opportunity to cure as provided above but have failed to so cure). The amount of the Termination Fee that may be collected by Purchaser shall be limited to $8,000,000, regardless of the number of Sellers alleged to have defaulted hereunder. Purchaser shall be entitled to execute on the Guaranty for any of the Applicable Share of the Deposit, Return on Deposit, and Termination Fee if the same are not returned within one (1) day after termination of the Agreement with respect to the Property or Properties in question.
Default by Owner If one or more of the following Events of Default shall occur and be continuing, that is to say:
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
Borrower Default Unless the Administrative Agent shall have received notice from Borrower prior to the date on which any payment is due to the Administrative Agent for the account of the Lenders or the Issuing Bank hereunder that Borrower will not make such payment, the Administrative Agent may assume that Borrower has made such payment on such date in accordance herewith and may, in reliance upon such assumption, distribute to the Lenders or the Issuing Bank, as the case may be, the amount due. In such event, if Borrower has not in fact made such payment, then each of the Lenders or the Issuing Bank, as the case may be, severally agrees to repay to the Administrative Agent forthwith on demand the amount so distributed to such Lender or the Issuing Bank with interest thereon, for each day from and including the date such amount is distributed to it to but excluding the date of payment to the Administrative Agent, at the greater of the Federal Funds Effective Rate and a rate determined by the Administrative Agent in accordance with banking industry rules on interbank compensation.
Default by Tenant (a) This Lease is made upon the condition that the Tenant shall punctually and faithfully perform all of the covenants and agreements by it to be performed as herein set forth. If any of the following events shall occur, to-wit: (i) if any installment of Fixed Base Rent, Percentage Rent, or any other sums required to be paid by Tenant hereunder, or any part thereof, shall at any time be in arrears and unpaid for ten (10) days after the date due, or (ii) if there be any default on the part of the Tenant in the observance or performance of any of the other covenants, agreements or conditions of said Lease on the part of Tenant to be kept and performed and said default shall continue for a period of fifteen (15) days after written notice thereof from Landlord to Tenant (unless such default cannot reasonably be cured within fifteen (15) days and in such case, Tenant shall have commenced to cure said default within said fifteen (15) days and thereafter continues diligently to pursue to completion the curing of same) or (iii) if Tenant shall file a petition in bankruptcy or be adjudicated a bankrupt, or file any petition or answer seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief for itself under any present or future federal, state or other statute, law or regulation, or make an assignment for the benefit of creditors, or (iv) if any trustee, receiver or liquidator of Tenant or of all or any substantial part of its properties shall be appointed in any action, suit or proceeding by or against Tenant and such proceeding or action shall not have been dismissed within thirty (30) days after such appointment, or (v) if the leasehold estate hereby created shall be taken by execution or by other process of law, or (vi) if Tenant shall fail to operate and conduct business as required in Section 8 hereinabove, then, in any such event, Landlord, at Landlord's option and without limiting Landlord in the exercise of any other right or remedy Landlord may have on account of any default by Tenant, may either:
Servicer Default If any one of the following events (a “Servicer Default”) shall occur and be continuing:
