Common use of Submittals Clause in Contracts

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleunreas approval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal t schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 2.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect Engineer shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s Engineer’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review. Engineer’s professional judgment, to permit adequate review without causing delay in the Work or in the activities of the Owner, Contractor or separate contractors.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness as to cause no delay in the Work, while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate reviewxxxxxx.xxxxxx without causing delay in the Work or in the activities of the Owner, Contractor or separate contractors.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, such promptness as to cause no unreasonable delay in the absence Work or in the activities of an approved submittal schedulethe Owner, with reasonable promptness Contractor, or separate contractors while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review; but, in any event, the Architect’s action shall be taken within fourteen (14) calendar days following receipt of the submittal.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness (not exceeding fourteen (14) calendar days) while allowing sufficient time, in the Architect’s professional judgment, to permit adequate reviewreview within the Project schedule.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient timeand no longer than ten (10) calendar days from receipt, in unless the Architect’s professional judgment, to permit adequate reviewOwner is notified of the reasons for the delay and approves a longer time period.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval. The Architect must render and approval or non-approval of the scheduleContractor’s submittals within 14 calendar days of receipt unless otherwise directed by the Owner. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall promptly review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review. The Architect shall have a minimum of ten (10) business days to review submittals.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably delay or withhold approval approval. of the schedule. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 5.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.or by 10 business days from date or receipt, in the absence of good cause for extension to permit adequate review, in which case the submittals shall be reviewed with reasonable promptness taking into account such good cause.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient within five (5) days of receipt of a submittal. If additional review time is necessary, the architect is to provide notice to the Owner and CM/GC the reason for the extended review time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.. mb al design services oritect shall specify the hall certi sign

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule, , shall discuss and review the schedule with the Owner and shall not unreasonably delay or withhold approval of the scheduleschedule upon approval of the Owner. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 3.10.4.1 The Architect shall review and approve the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness promptness, while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably unrea or Payment and return , to the best of his chedule of Values. If xxx delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with such reasonable promptness as to cause no delay in the work or activities of the Owner, Contractor or separate contractors, while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, within five (5) days of receipt of a submittal. If additional review time is necessary, the architect is to provide notice to the Owner and CM/GC the reason for the extended review time. with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, but in no event more than ten (10) business days after the Architect’s receipt of the submittal unless the Architect notifies the Owner and the Contractor that in the Architect’s professional judgment, judgment more time is needed and the Owner agrees in writing to permit adequate reviewa longer period of time.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness to not cause delay in the Work while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate reviewreview within fourteen (14) calendar days.

Submittals. § 3.6.4.1 The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval approval. of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold unreaso approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the acc approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while reaso allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.. ly delay or withhold ce with the le promptness while

Submittals. § 3.6.4.1 2.6.4.1 The Architect Engineer shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s Engineer’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s Engineer’s professional judgment, to permit adequate review.

Submittals. § 3.6.4.1 The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review. Architect shall notify Owner and Contractor if a review cannot be completed within fourteen (14) calendar days.