Software Currency. The Parties agree to maintain reasonable currency for Maintenance Releases and Versions of Software, unless CHMS determines otherwise. For purposes of this Section, "reasonable currency" shall mean that the next Maintenance Release or Version is installed not later than the longer of (a) 24 months after the date the licensor makes such Maintenance Release or Version commercially available, or (b) within 1 month after the date the licensor makes a subsequent Maintenance Release or Version commercially available which causes CHMS to be more than one Maintenance Release or Version behind. In the event CHMS requests ISSC to expedite installation of a Maintenance Release or Version or to delay upgrading of specific Software beyond such period or requires operation and maintenance of multiple versions of Software, ISSC shall do so, provided, that if ISSC reasonably determines that it will incur any Out-of-Pocket Expenses as a result of such requests (e.g., Software support costs due to withdrawal of maintenance by the licensor, multiple version charges, etc.), then ISSC January 4, 1996 Agreement - Execution Document Page 18 of 53 25 will notify CHMS of the amount of such Out-of-Pocket Expenses in writing and CHMS, at its option, will either delay installation of such Maintenance Release or Version or update the Software to the current level (as applicable) or reimburse ISSC for any demonstrable Out-of-Pocket Expenses. In addition, CHMS shall relieve ISSC from any failure to meet a Performance Standard or Minimum Service Level to the extent directly impacted by the delay of the next Maintenance Release or Version until such time as the affected Software is brought to "reasonable currency" as defined in this Section 3.10.
Software Currency. Contractor represents, warrants and covenants that, unless otherwise agreed and to the extent it has operational responsibility under this Agreement, it shall maintain the reasonable currency for Software (including Contractor’s and third party software currency to N or N-1) so that they operate in accordance with the Service Levels and their Specifications.
Software Currency. (a) Currency of Software. Subject to and in accordance with Sections 9.3, 9.4, and Exhibit 4.2 Financial Responsibility Matrix, Successful Respondent shall maintain reasonable currency for Software for which it is financially responsible under this Agreement and provide maintenance and support for Software (including new Upgrades, Major Releases, and Minor Releases) for which it is operationally responsible under this Agreement. Successful Respondent shall (i) maintain Software within one (1) Major Release of the then-current Major Release, unless otherwise specified pursuant to the Software Currency guidelines set out in Exhibit 4.2 Financial Responsibility Matrix and (ii) Successful Respondent shall install Minor Releases promptly or, if earlier, as requested by DIR.
Software Currency. Insurdata shall only use those versions of the UICI Software approved in writing by UICI to provide the Services.
Software Currency. At all times throughout the Term, HP-OMS shall upgrade or replace HP-OMS Software as necessary to satisfy its obligations under this Agreement according to Exhibit C, at no additional cost to Customer; provided, HP-OMS shall utilize at least the second to most (if not the most) updated version of such Software.
Software Currency. Following Initial Refresh, IBM shall perform all functions required to maintain all In-Scope Software currency. Unless otherwise agreed by the parties, IBM shall maintain In-Scope Software within one generation of current major release levels.
Software Currency. 45 9.8 Access to Specialized Service Provider Skills and Resources 46 9.9 Audit Rights 47 9.10 Authorization and Disbursements 51 9.11 Subcontractors 52 9.12 Technology Evolution. 53 9.13 Retained Systems and Processes 55 9.14 Annual Reviews 55 9.15 Multi-Supplier Integration and Cooperation 56
Software Currency. 66 9.7 Year 2000 Compliance ......................................... 67 9.8 Access to Specialized Amdocs Skills and Resources ............ 68 9.9
Software Currency. 19 3.10 Viruses........................................................................................20 3.11 Software - Substitutions and Additions.........................................................20 3.12
Software Currency. (a) NTT DATA will maintain reasonable currency of Maintenance Releases and Versions of NTT DATA Software and the NTT DATA Third Party Software residing on GPI Equipment. “Reasonable currency” means that Maintenance Releases and Versions are installed to the NTT DATA Software and NTT DATA Third Party Software residing on GPI Equipment to allow GPI Applications resident on GPI Equipment to function properly.
