SATELLITE DISH Subject to compliance with all applicable Legal Requirements, Tenant shall have the exclusive right to place, from time to time, satellite dishes, antennae and other communication or transmission devices (such devices being referred to as the “Satellite Dishes”) on the roof of each of the Buildings. Additionally, Tenant shall have the right to install such wire, conduits, cables and other materials as necessary to connect the Satellite Dishes to Tenant’s allied machinery and equipment in the Premises (the Satellite Dishes and any such connecting material being collectively referred to as the “Satellite Dish Facilities”). However, prior to the installation of any Satellite Dish Facilities, Tenant, at its expense, shall be required to provide Landlord with a certification by a registered professional structural engineer that the structural system of the roof is adequate to support the superimposed loads produced by any Satellite Dishes at the location on the roof of such Satellite Dishes and Tenant, at its expense, shall be required to provide Landlord with satisfactory assurance that the existing construction materials of the roof (such as the roof membrane) shall be protected from the Satellite Dishes. At the expiration or earlier termination of the Lease, Tenant, at its expense, may remove the Satellite Dish Facilities belonging to Tenant, but Tenant shall remove any Satellite Dish Facilities belonging to an unaffiliated third party. Any work required to restore the roof of any other part of the Buildings from any damage occasioned by the installation, maintenance or removal of the Satellite Dish Facilities shall be borne by Tenant, and Tenant shall indemnify and hold harmless Landlord from any costs, expenses, liabilities and the like, including reasonable attorneys’ fees, occasioned by any damage to property and injury or death to persons caused by such installation, maintenance or removal, except to the extent caused by the negligence, willful misconduct or breach of this Lease of Landlord. Tenant shall be responsible for the installation of all Satellite Dish Facilities (including the attachment thereto to the roof) and for all costs and expenses arising from and relating to the Satellite Dish Facilities and the installation, operation, maintenance and repair thereof, and, if Tenant elects to remove the Satellite Dish Facilities, or for those Satellite Dish Facilities for which removal is required, for the removal thereof. The installation, maintenance and removal of the Satellite Dish Facilities shall be performed by contractors and workers first approved by Landlord, which approval will not be unreasonably withheld or delayed. However, Landlord reserves the right to require Tenant, at Tenant’s expense, to use Landlord’s roofing contractor in connection therewith if, in Landlord’s reasonable judgment, the Landlord’s roof warranty may be affected by any such work. Landlord agrees that Tenant and engineering and maintenance personnel reasonably approved by Landlord shall have access to the Satellite Dish Facilities in order to install, operate, maintain, inspect and remove, as required, the Satellite Dish Facilities. Landlord shall not unreasonably interfere with or impair the use, operation, maintenance or repair of the Satellite Dish Facilities. Tenant may sublease to unaffiliated third parties rooftop rights for the installation of Satellite Dish Facilities, without Landlord’s consent, but Tenant shall give Landlord written notice of the existence of any such subleases from time to time upon Landlord’s request. All revenues derived from such third party subleases shall belong to Tenant. The Satellite Dish Facilities shall not be considered a part of the Premises for the purpose of determining Tenant’s rental obligations under the Lease and no Rent therefor shall be charged during the Term (including any renewal period specifically provided under this Lease). However, Tenant’s use of the Satellite Dish Facilities is otherwise subject to all of the terms and conditions of this Lease with respect to Tenant’s use and occupancy of the Premises, including, without limitation, Sections 9, 22 and 31.
System Upgrade Facilities and System Deliverability Upgrades Connecting Transmission Owner shall design, procure, construct, install, and own the System Upgrade Facilities and System Deliverability Upgrades described in Appendix A hereto. The responsibility of the Developer for costs related to System Upgrade Facilities and System Deliverability Upgrades shall be determined in accordance with the provisions of Attachment S to the NYISO OATT.
Communications Equipment Members of the board of directors or any committee thereof may participate in and act at any meeting of such board or committee through the use of a conference telephone or other communications equipment by means of which all persons participating in the meeting can hear each other, and participation in the meeting pursuant to this section shall constitute presence in person at the meeting.
Access Toll Connecting Trunk Group Architecture 9.2.1 If CBB chooses to subtend a Verizon access Tandem, CBB’s NPA/NXX must be assigned by CBB to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG.
Network Interconnection Architecture Each Party will plan, design, construct and maintain the facilities within their respective systems as are necessary and proper for the provision of traffic covered by this Agreement. These facilities include but are not limited to, a sufficient number of trunks to the point of interconnection with the tandem company, and sufficient interoffice and interexchange facilities and trunks between its own central offices to adequately handle traffic between all central offices within the service areas at P.01 grade of service or better. The provisioning and engineering of such services and facilities will comply with generally accepted industry methods and practices, and will observe the rules and regulations of the lawfully established tariffs applicable to the services provided.
Outage Repair Standard In the event of an outage or trouble in any Service being provided by a Party hereunder, the Providing Party will follow Verizon’s standard procedures for isolating and clearing the outage or trouble.
Contractor’s Equipment Payment for required equipment owned by the Construction Manager or an affiliate of the Construction Manager will be based solely on an hourly rate derived by dividing the current appropriate monthly rate by 176 hours. No payment will be made under any circumstances for repair costs, freight and transportation charges, fuel, lubricants, insurance, any other costs and expenses, or overhead and profit. Payment for such equipment made idle by delays attributable to the Government will be based on one-half the derived hourly rate under this subsection.
Network Upgrades The Transmission Owner shall design, procure, construct, install, and own the Network Upgrades described in Attachment 6 of this Agreement. If the Transmission Owner and the Interconnection Customer agree, the Interconnection Customer may construct Network Upgrades that are located on land owned by the Interconnection Customer. Unless the Transmission Owner elects to pay for Network Upgrades, the actual cost of the Network Upgrades, including overheads, shall be borne initially by the Interconnection Customer.
Workloads (a) The parties agree that patient care is enhanced if concerns relating to professional practice, patient acuity, fluctuating Work-Loads and fluctuating staffing are resolved in a timely and effective manner.
Interconnection Customer Drawings Within one hundred twenty (120) days after the date of Initial Operation, unless the Interconnection Parties agree on another mutually acceptable deadline, the Interconnection Customer shall deliver to the Transmission Provider and the Interconnected Transmission Owner final, “as-built” drawings, information and documents regarding the Customer Interconnection Facilities, including, as and to the extent applicable: a one-line diagram, a site plan showing the Customer Facility and the Customer Interconnection Facilities, plan and elevation drawings showing the layout of the Customer Interconnection Facilities, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer's step-up transformers, the facilities connecting the Customer Facility to the step-up transformers and the Customer Interconnection Facilities, and the impedances (determined by factory tests) for the associated step-up transformers and the Customer Facility. As applicable, the Interconnection Customer shall provide Transmission Provider and the Interconnected Transmission Owner specifications for the excitation system, automatic voltage regulator, Customer Facility control and protection settings, transformer tap settings, and communications.
