Possession of Mortgage Files The Seller does hereby sell, transfer, assign, set over and convey to the Purchaser, without recourse but subject to the terms of this Agreement, all of its right, title and interest in, to and under the Mortgage Loans, including the related Prepayment Charges. The contents of each Mortgage File not delivered to the Purchaser or to any assignee, transferee or designee of the Purchaser on or prior to the Closing Date are and shall be held in trust by the Seller for the benefit of the Purchaser or any assignee, transferee or designee of the Purchaser. Upon the sale of the Mortgage Loans, the ownership of each Mortgage Note, the related Mortgage and the other contents of the related Mortgage File is vested in the Purchaser and the ownership of all records and documents with respect to the related Mortgage Loan prepared by or that come into the possession of the Seller on or after the Closing Date shall immediately vest in the Purchaser and shall be delivered immediately to the Purchaser or as otherwise directed by the Purchaser.
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
Possession of Collateral Agent and Secured Parties appoint each Lender as agent (for the benefit of Secured Parties) for the purpose of perfecting Liens in any Collateral held or controlled by such Lender, to the extent such Liens are perfected by possession or control. If any Lender obtains possession or control of any Collateral, it shall notify Agent thereof and, promptly upon Agent’s request, deliver such Collateral to Agent or otherwise deal with it in accordance with Agent’s instructions.
Conveyance of Mortgage Loans; Possession of Servicing Files The Seller, simultaneously with the delivery of the Mortgage Loan Schedule with respect to the related Mortgage Loan Package to be purchased on each Closing Date, shall execute and deliver an Assignment and Conveyance Agreement in the form attached hereto as Exhibit H (the "Assignment and Conveyance Agreement"). The Seller shall cause the Servicing File retained by the Originator pursuant to this Agreement to be appropriately identified in the Seller's computer system and/or books and records, as appropriate, to clearly reflect the sale of the related Mortgage Loan to the Purchaser. The Seller shall cause the Originator to release from its custody the contents of any Servicing File retained by it only in accordance with this Agreement or the Servicing Agreement, except when such release is required in connection with a repurchase of any such Mortgage Loan pursuant to Subsection 9.03.
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
Possession and Use Contractor may possess, use and reproduce Confidential Information solely for the Purpose. Contractor shall not use the Confidential Information for any other purpose.
Location of the Collateral Except in the ordinary course of Grantor's business, Grantor agrees to keep the Collateral (or to the extent the Collateral consists of intangible property such as accounts or general intangibles, the records concerning the Collateral) at Grantor's address shown above or at such other locations as are acceptable to Lender. Upon Lender's request, Grantor will deliver to Lender in form satisfactory to Lender a schedule of real properties and Collateral locations relating to Grantor's operations, including without limitation the following: (1) all real property Grantor owns or is purchasing; (2) all real property Grantor is renting or leasing; (3) all storage facilities Grantor owns, rents, leases, or uses; and (4) all other properties where Collateral is or may be located.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Possession of Documents The Servicer has in its possession all original copies of the agreements that constitute or evidence the Receivables. The agreements that constitute or evidence the Receivables do not have any marks or notations indicating that they have been pledged, assigned or otherwise conveyed to any Person other than the Indenture Trustee. All financing statements filed or to be filed against the Issuer in favor of the Indenture Trustee in connection herewith describing the Receivables contain a statement to the following effect: "A purchase of or security interest in any collateral described in this financing statement will violate the rights of the Indenture Trustee."
