Permitting Delay Sample Clauses

Permitting Delay. The Guaranteed Commercial Operation Date may be extended on a day for day basis for not more than six (6) months if Seller has used commercially reasonable efforts (including Seller’s timely filing of required documents and payment of all applicable fees) to obtain permits necessary for the construction and operation of the Project, but is unable to obtain such permits and Seller has worked diligently to resolve the delay (“Permitting Delay”);
Sample 1Sample 2Sample 3See All (17)
AutoNDA by SimpleDocs
Permitting Delay. The Guaranteed Construction Start Date may be extended on a day for day basis for not more than six (6) months if Seller has used commercially reasonable efforts (including Seller’s timely filing of required documents and payment of all applicable fees) to obtain permits necessary for the construction and operation of the Project, but is unable to obtain such permits and Seller has worked diligently to resolve the delay (“Permitting Delay”);
Sample 1Sample 2Sample 3See All (4)

Related to Permitting Delay

  • Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.

  • Termination by Owner The Owner may terminate this Agreement in whole or in part, for the failure of the Consultant to:

  • Termination by ICANN (a) ICANN may, upon notice to Registry Operator, terminate this Agreement if: (i) Registry Operator fails to cure (A) any fundamental and material breach of Registry Operator’s representations and warranties set forth in Article 1 or covenants set forth in Article 2, or (B) any breach of Registry Operator’s payment obligations set forth in Article 6 of this Agreement, each within thirty (30) calendar days after ICANN gives Registry Operator notice of such breach, which notice will include with specificity the details of the alleged breach, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in fundamental and material breach of such covenant(s) or in breach of its payment obligations, and (iii) Registry Operator fails to comply with such determination and cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction.

  • TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.

  • Waiver; Deficiency Each Grantor waives and agrees not to assert any rights or privileges which it may acquire under Section 9-112 of the New York UCC. Each Grantor shall remain liable for any deficiency if the proceeds of any sale or other disposition of the Collateral are insufficient to pay its Obligations and the fees and disbursements of any attorneys employed by the Administrative Agent or any Lender to collect such deficiency.

  • Permitted Delays The Company shall be entitled to postpone the filing of any Registration Statement under Section 2.3 if (i) at any time prior to the filing of such Registration Statement the Board of Directors of the Company determines, in its good faith business judgment, that such registration and offering would materially and adversely affect any financing, acquisition, corporate reorganization or other material transaction involving the Company, and (ii) the Company delivers the Holders requesting such registration written notice thereof within 10 business days of the date of receipt of such request; provided, that all such periods of postponement may not exceed 45 days during any 365-day period.

  • Termination by CAISO Subject to Section 5.2, the CAISO may terminate this Agreement by giving written notice of termination in the event that the Participating Generator commits any material default under this Agreement and/or the CAISO Tariff which, if capable of being remedied, is not remedied within thirty (30) days after the CAISO has given, to the Participating Generator, written notice of the default, unless excused by reason of Uncontrollable Forces in accordance with Article X of this Agreement. With respect to any notice of termination given pursuant to this Section, the CAISO must file a timely notice of termination with FERC, if this Agreement was filed with FERC, or must otherwise comply with the requirements of FERC Order No. 2001 and related FERC orders. The filing of the notice of termination by the CAISO with FERC will be considered timely if: (1) the filing of the notice of termination is made after the preconditions for termination have been met, and the CAISO files the notice of termination within sixty (60) days after issuance of the notice of default; or (2) the CAISO files the notice of termination in accordance with the requirements of FERC Order No. 2001. This Agreement shall terminate upon acceptance by FERC of such a notice of termination, if filed with FERC, or thirty (30) days after the date of the CAISO’s notice of default, if terminated in accordance with the requirements of FERC Order No. 2001 and related FERC orders.

  • Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • TERMINATION BY MPS MPS further reserves the right to terminate this Contract at any time for any reason by giving Contractor written notice by Registered or Certified Mail of such termination. MPS will attempt to give Contractor 20 days’ notice, but reserves the right to give immediate notice. In the event of said termination, Contractor shall reduce its activities hereunder, as mutually agreed to, upon receipt of said notice. Upon said termination, Contractor shall be paid for all services rendered through the date of termination, including any retainage. This section also applies should the Milwaukee Board of School Directors fail to appropriate additional monies required for the completion of the Contract.

Time is Money Join Law Insider Premium to draft better contracts faster.