Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.
Limitation on Out-of-State Litigation Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
GOVERNING LAW AND VENUE; WAIVER OF JURY TRIAL; SPECIFIC PERFORMANCE (i) THIS AGREEMENT SHALL BE DEEMED TO BE MADE IN AND IN ALL RESPECTS SHALL BE INTERPRETED, CONSTRUED AND GOVERNED BY AND IN ACCORDANCE WITH THE LAW OF THE STATE OF DELAWARE WITHOUT REGARD TO THE CONFLICTS OF LAW PRINCIPLES THEREOF. The parties hereto hereby irrevocably submit to the personal jurisdiction of the courts of the State of Delaware and the federal courts of the United States of America located in the county of Delaware in the State of Delaware solely in respect of the interpretation and enforcement of the provisions of this Agreement and of the documents referred to in this Agreement, and in respect of the transactions contemplated hereby, and hereby waive, and agree not to assert, as a defense in any Action for the interpretation or enforcement hereof or of any such document, that it is not subject thereto or that such Action may not be brought or is not maintainable in said courts or that the venue thereof may not be appropriate or that this Agreement or any such document may not be enforced in or by such courts, and the parties hereto irrevocably agree that all claims with respect to such Action shall be heard and determined in such a Delaware state or federal court. The parties hereby consent to and grant any such court jurisdiction over the person of such parties and, to the extent permitted by law, over the subject matter of such dispute and agree that mailing of process or other papers in connection with any such action or proceeding in any manner as may be permitted by law shall be valid and sufficient service thereof.
Defense of Actions In any case in which any such action is brought against any indemnified party, and it notifies an indemnifying party of the commencement thereof, the indemnifying party will be entitled to participate therein, and, to the extent that it may wish, jointly with any other indemnifying party similarly notified, to assume the defense thereof, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party will not (so long as it shall continue to have the right to defend, contest, litigate and settle the matter in question in accordance with this paragraph) be liable to such indemnified party hereunder for any legal or other expense subsequently incurred by such indemnified party in connection with the defense thereof other than reasonable costs of investigation, supervision and monitoring (unless (i) such indemnified party reasonably objects to such assumption on the grounds that there may be defenses available to it which are different from or in addition to the defenses available to such indemnifying party, (ii) counsel to the indemnifying party has informed the indemnifying party that the joint representation of the indemnifying party and one or more indemnified parties could be inappropriate under applicable standards of professional conduct, or (iii) the indemnifying party shall have failed within a reasonable period of time to assume such defense and the indemnified party is or is reasonably likely to be prejudiced by such delay, in any such event the indemnified party shall be promptly reimbursed by the indemnifying party for the expenses incurred in connection with retaining separate legal counsel). An indemnifying party shall not be liable for any settlement of an action or claim effected without its consent (such consent not to be unreasonably withheld). The indemnifying party shall lose its right to defend, contest, litigate and settle a matter if it shall fail to diligently contest such matter (except to the extent settled in accordance with the next following sentence). No matter shall be settled by an indemnifying party without the consent of the indemnified party (which consent shall not be unreasonably withheld, it being understood that the indemnified party shall not be deemed to be unreasonable in withholding its consent if the proposed settlement imposes any obligation on the indemnified party).
Notice of Litigation, Right to Prosecute, Etc No Fund shall be liable for indemnification under this Section 5.03 unless a Person shall have promptly notified such Fund in writing of the commencement of any litigation or proceeding brought against such Person in respect of which indemnity may be sought under this Section 5.03. With respect to claims in such litigation or proceedings for which indemnity by a Fund may be sought and subject to applicable law and the ruling of any court of competent jurisdiction, such Fund shall be entitled to participate in any such litigation or proceeding and, after written notice from such Fund to any Person, such Fund may assume the defense of such litigation or proceeding with counsel of its choice at its own expense in respect of that portion of the litigation for which such Fund may be subject to an indemnification obligation; provided however, a Person shall be entitled to participate in (but not control) at its own cost and expense, the defense of any such litigation or proceeding if such Fund has not acknowledged in writing its obligation to indemnify the Person with respect to such litigation or proceeding. If such Fund is not permitted to participate or control such litigation or proceeding under applicable law or by a ruling of a court of competent jurisdiction, such Person shall reasonably prosecute such litigation or proceeding. A Person shall not consent to the entry of any judgment or enter into any settlement in any such litigation or proceeding without providing each applicable Fund with adequate notice of any such settlement or judgment, and without each such Fund's prior written consent. All Persons shall submit written evidence to each applicable Fund with respect to any cost or expense for which they are seeking indemnification in such form and detail as such Fund may reasonably request.
WAIVER OF JURY TRIAL, PUNITIVE DAMAGES, ETC BORROWER, ADMINISTRATIVE AGENT, AND EACH BANK HEREBY (a) KNOWINGLY, VOLUNTARILY, INTENTIONALLY, AND IRREVOCABLY WAIVE, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN RESPECT OF ANY LITIGATION BASED HEREON, OR DIRECTLY OR INDIRECTLY AT ANY TIME ARISING OUT OF, UNDER OR IN CONNECTION WITH THE LOAN PAPERS OR ANY TRANSACTION CONTEMPLATED THEREBY OR ASSOCIATED THEREWITH, BEFORE OR AFTER MATURITY; (b) IRREVOCABLY WAIVE, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT IT MAY HAVE TO CLAIM OR RECOVER IN ANY SUCH LITIGATION ANY “SPECIAL DAMAGES,” AS DEFINED BELOW; (c) CERTIFY THAT NO PARTY HERETO NOR ANY REPRESENTATIVE OR AGENT OR COUNSEL FOR ANY PARTY HERETO HAS REPRESENTED, EXPRESSLY OR OTHERWISE, OR IMPLIED THAT SUCH PARTY WOULD NOT, IN THE EVENT OF LITIGATION, SEEK TO ENFORCE THE FOREGOING WAIVERS, AND (d) ACKNOWLEDGE THAT IT HAS BEEN INDUCED TO ENTER INTO THIS AGREEMENT, THE OTHER LOAN PAPERS AND THE TRANSACTIONS CONTEMPLATED HEREBY AND THEREBY BY, AMONG OTHER THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS CONTAINED IN THIS SECTION. AS USED IN THIS SECTION, “SPECIAL DAMAGES” INCLUDES ALL SPECIAL, CONSEQUENTIAL, EXEMPLARY, OR PUNITIVE DAMAGES (REGARDLESS OF HOW NAMED), BUT DOES NOT INCLUDE ANY PAYMENT OR FUNDS WHICH ANY PARTY HERETO HAS EXPRESSLY PROMISED TO PAY OR DELIVER TO ANY OTHER PARTY HERETO.
XXXXX-XXXXX AND RELATED ACT PROVISIONS This section is applicable to all Federal-aid construction projects exceeding $2,000 and to all related subcontracts and lower-tier subcontracts (regardless of subcontract size). The requirements apply to all projects located within the right-of- way of a roadway that is functionally classified as Federal-aid highway. This excludes roadways functionally classified as local roads or rural minor collectors, which are exempt. Contracting agencies may elect to apply these requirements to other projects. The following provisions are from the U.S. Department of Labor regulations in 29 CFR 5.5 “Contract provisions and related matters” with minor revisions to conform to the FHWA- 1273 format and FHWA program requirements.
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Loss Leader Prohibition If this Agreement involves the purchase of goods, this section is applicable. Contractor shall not sell or use any article or product as a “loss leader” as defined in Section 17030 of the Business and Professions Code.
Limitation on Judicial Council 's Liability The Judicial Council will not be responsible for loss or damage to any non-Judicial Council equipment or property arising from causes beyond the Judicial Council's control. In any event, the Judicial Council's responsibility for repairs and liability for damages or loss shall be limited to that made necessary by or resulting from the negligent acts or omissions of the Judicial Council or its officers, employees, or agents. The Judicial Council will not be liable for any charges incurred in connection with this Program, or any Judicial Council activities, unless expressly provided for under this Agreement.
