Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:
Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.
Notice and contest of claims In the event that either Party receives a claim or demand from a third party in respect of which it is entitled to the benefit of an indemnity under this Article 38 (the "Indemnified Party") it shall notify the other Party (the "Indemnifying Party") within 15 (fifteen) days of receipt of the claim or demand and shall not settle or pay the claim without the prior approval of the Indemnifying Party, which approval shall not be unreasonably withheld or delayed. In the event that the Indemnifying Party wishes to contest or dispute the claim or demand, it may conduct the proceedings in the name of the Indemnified Party, subject to the Indemnified Party being secured against any costs involved, to its reasonable satisfaction.
Release and Waiver of Claims In consideration of the severance payments and other benefits to which I have become entitled, pursuant to that certain letter agreement between Corsair Memory, Inc., a Delaware corporation (the “Company”), and myself dated , 20 (the “Severance Agreement”), in connection with the termination of my employment, I, , hereby furnish the Company with the following release and waiver (“Release and Waiver”). I hereby release and forever discharge the Company, its officers, directors, agents, employees, stockholders, successors, assigns and affiliates from any and all claims, liabilities, demands, causes of action, costs, expenses, attorney fees, damages, indemnities and obligations of every kind and nature, in law, equity or otherwise, known and unknown, suspected and unsuspected, disclosed and undisclosed, arising from or relating to my employment with the Company and the termination of that employment, including (without limitation) claims of wrongful discharge, emotional distress, defamation, fraud, breach of contract, breach of the covenant of good faith and fair dealing, discrimination claims based on sex, age, race, national origin, disability or any other basis under Title VII of the Civil Rights Act of 1964, as amended, the California Fair Employment and Housing Act, the Federal Age Discrimination in Employment Act of 1967, as amended (“ADEA”), the Americans with Disability Act, contract claims, tort claims, and wage or benefit claims, including but not limited to, claims for salary, bonuses, commissions, stock grants, stock options, vacation pay, fringe benefits, severance pay or any other form of compensation (other than the severance payments and benefits to which I am, pursuant to the express provisions of the Severance Agreement, entitled in connection with my termination of employment, my vested rights under the Company’s Section 401(k) Plan and any worker’s compensation benefits under any Company workers’ compensation insurance policy or fund). In releasing claims unknown to me at present, I am waiving all rights and benefits under Section 1542 of the California Civil Code, and any law or legal principle of similar effect in any jurisdiction: “A general release does not extend to claims which the creditor does not know or suspect to exist in his favor at the time of executing the release, which if known by him must have materially affected his settlement with the debtor.” This Release and Waiver does not pertain to any claims which may subsequently arise in connection with the Company’s default in any severance payment obligations under the Severance Agreement. I acknowledge that, among other rights subject to this Release and Waiver, I am hereby waiving and releasing any rights I may have under ADEA, that this release and waiver is knowing and voluntary, and that the consideration given for this release and waiver is in addition to anything of value to which I was already entitled as an executive of the Company. I further acknowledge that I have been advised, as required by the Older Workers Benefit Protection Act, that: (a) the release and waiver granted herein does not relate to claims which may arise after this release and waiver is executed; (b) I have the right to consult with an attorney prior to executing this release and waiver (although I may choose voluntarily not to do so); and if I am over 40 years old upon execution of this; (c) I have twenty-one (21) days from the date of termination of my employment with the Company in which to consider this release and waiver (although I may choose voluntarily to execute this release and waiver earlier); (d) I have seven (7) days following the execution of this release and waiver to revoke my consent to this release and waiver; and (e) this release and waiver shall not be effective until the seven (7)-day revocation period has expired. Date: Signature: Print Name:
ASSIGNMENT OF CLAIM Contractor hereby assigns to the State any and all claims for overcharges associated with this Contract that may arise under the antitrust laws of the United States, 15 USC Section 1, et. seq. and the antitrust laws of the State of New York, General Business Law Section 340, et. seq.
Waiver of Claim for Attorney’s Fees The defendant waives all of his claims under the Hyde Amendment, 18 U.S.C. § 3006A, for attorney’s fees and other litigation expenses arising out of the investigation or prosecution of this matter.
Claim Form i. Within 15 days after receiving a notice of a claim, you or your Dental Provider will be provided with a Claim Form to make claim for Benefits. To make a claim, the form should be completed and signed by the Provider who performed the services, and by the patient (or the parent or guardian if the patient is a minor), and submitted to the address above.
Waiver of Claims 9.1. The CONTRACTOR's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the CITY arising out of this Agreement or otherwise related to the Project, except those previously made in writing and identified by the CONTRACTOR as unsettled at the time of the final payment. Neither the acceptance of the CONTRACTOR's services nor payment by the CITY shall be deemed to be a waiver of any of the CITY's rights against the CONTRACTOR.
Defense of Claims Subject to the provisions of applicable policies of directors’ and officers’ liability insurance, if any, the Company shall be entitled to participate in the defense of any Indemnifiable Claim or to assume or lead the defense thereof with counsel reasonably satisfactory to the Indemnitee; provided that if Indemnitee determines, after consultation with counsel selected by Indemnitee, that (a) the use of counsel chosen by the Company to represent Indemnitee would present such counsel with an actual or potential conflict, (b) the named parties in any such Indemnifiable Claim (including any impleaded parties) include both the Company and Indemnitee and Indemnitee shall conclude that there may be one or more legal defenses available to him or her that are different from or in addition to those available to the Company, (c) any such representation by such counsel would be precluded under the applicable standards of professional conduct then prevailing, or (d) Indemnitee has interests in the claim or underlying subject matter that are different from or in addition to those of other Persons against whom the Claim has been made or might reasonably be expected to be made, then Indemnitee shall be entitled to retain separate counsel (but not more than one law firm plus, if applicable, local counsel in respect of any particular Indemnifiable Claim for all indemnitees in Indemnitee’s circumstances) at the Company’s expense. The Company shall not be liable to Indemnitee under this Agreement for any amounts paid in settlement of any threatened or pending Indemnifiable Claim effected without the Company’s prior written consent. The Company shall not, without the prior written consent of the Indemnitee, effect any settlement of any threatened or pending Indemnifiable Claim which the Indemnitee is or could have been a party unless such settlement solely involves the payment of money and includes a complete and unconditional release of the Indemnitee from all liability on any claims that are the subject matter of such Indemnifiable Claim. Neither the Company nor Indemnitee shall unreasonably withhold its consent to any proposed settlement; provided that Indemnitee may withhold consent to any settlement that does not provide a complete and unconditional release of Indemnitee.
Sending a Claim Notice Before beginning a lawsuit, mediation or arbitration, you and we agree to send a written notice (a claim notice) to each party against whom a claim is asserted, in order to provide an opportunity to resolve the claim informally or through mediation. Go to xxxxxxxxxxxxxxx.xxx/ claim for a sample claim notice. The claim notice must describe the claim and state the specific relief demanded. Notice to you may be provided by your billing statement or sent to your billing address. Notice to us must include your name, address and Account number and be sent to American Express ADR c/o CT Corporation System, 00 Xxxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000. If the claim proceeds to arbitration, the amount of any relief demanded in a claim notice will not be disclosed to the arbitrator until after the arbitrator rules.
