Non-Compensable Excusable Delay Sample Clauses

Non-Compensable Excusable Delay. When Excusable Delay is (i) caused by circumstances beyond the control of Contractor, its Subcontractors, suppliers and vendors; (ii) is caused by circumstances beyond the control of Town or Consultant; or (iii) is caused jointly or concurrently by Contractor or its Subcontractors, suppliers or vendors and by Town or Consultant, then Contractor shall be entitled only to a time extension and no further compensation for the delay.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Non-Compensable Excusable Delay. When Excusable Delay is (i) caused by circumstances beyond the control of Contractor, its subcontractors, material persons, suppliers and vendors; (ii) is caused by circumstances beyond the control of the County; or (iii) is caused jointly or concurrently by Contractor or its subcontractors, material persons, suppliers or vendors and by the County or Consultant, then Contractor shall be entitled to a time extension equal to the actual number of days delayed on the critical path. Extensions to the Contract Time for delays caused by the effects of inclement weather shall be submitted as a request for change in Contract Time pursuant to Section 9.1. These time extensions are justified only when rain or other inclement weather conditions or related adverse soil conditions prevent Contractor from productively performing controlling items of Work identified on the accepted schedule or updates resulting in Contractor being unable to work at least fifty (50%) of the normal workday on controlling items of Work identified on the accepted schedule or updates due to adverse weather conditions.
Sample 1Sample 2Sample 3See All (4)
Non-Compensable Excusable Delay. When Excusable Delay is not due solely to fraud, bad faith or active interference on the part of CITY or its agents, then CONTRACTOR shall be entitled only to a time extension and no further compensation for the delay.
Sample 1Sample 2
Non-Compensable Excusable Delay. When Excusable Delay is not due solely to fraud, bad faith or active interference on the part of CITY or its agents, then Construction Manager shall be entitled only to a time extension and no further compensation for the delay, other than Construction Manager’s reimbursement of Construction Manager’s General Conditions within the Guaranteed Maximum Price.
Sample 1
Non-Compensable Excusable Delay. When Excusable Delay is caused by circumstances beyond the control of CONTRACTOR, its Subcontractors, material persons, suppliers and vendors, and is also caused by circumstances beyond the control of the COUNTY, PMO, CPM or Consultant, then CONTRACTOR shall be entitled to a time extension equal to the actual number of work days delayed on the critical path of the accepted schedule. The CONTRACTOR’s General Conditions and CONTRACTOR’s Management Services costs associated with such time extension shall be considered Cost of the Work, but in no case shall CONTRACTOR be entitled to any increase in GMP nor any damages for the delay. Such costs may be compensated by a CPEAM transfer of COUNTY’s Contingency to the CONTRACTOR’s General Conditions or CONTRACTOR’s Management Services, fixed fee not included, at the CA’s sole discretion.
Sample 1
Non-Compensable Excusable Delay. 40.7.1 Contractor shall be entitled only to a time extension and no further compensation for Non-Compensable Excusable Delay.
Sample 1
Non-Compensable Excusable Delay. When Excusable Delay is (i) caused by circumstances beyond the control of the DBT, its Subconsultants/Subcontractors, material persons, suppliers and vendors, and is also caused by circumstances beyond the control of the COUNTY or (ii) is caused jointly or concurrently by the DBT or its Subconsultants/Subcontractors, material persons, suppliers or vendors and by the COUNTY or Consultants, then the DBT shall be entitled to a time extension equal to the actual number of days delayed on the critical path. The extended General Conditions costs associated with such time extension will in no case entitle the DBT to an increase the Lump Sum Amount, nor any damages for the delay.
Sample 1
AutoNDA by SimpleDocs

Related to Non-Compensable Excusable Delay

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).

Time is Money Join Law Insider Premium to draft better contracts faster.