Medium Access Control
Medium Access Control Sample Clauses
Related to Medium Access Control
Access Control Landlord shall be the sole determinant of the type and amount of any access control or courtesy guard services to be provided to the Project, if any. IN ALL EVENTS, LANDLORD SHALL NOT BE LIABLE TO TENANT, AND TENANT HEREBY WAIVES ANY CLAIM AGAINST LANDLORD, FOR (I) ANY UNAUTHORIZED OR CRIMINAL ENTRY OF THIRD PARTIES INTO THE PREMISES, THE BUILDING OR THE PROJECT, (II) ANY DAMAGE TO PERSONS, OR (III) ANY LOSS OF PROPERTY IN AND ABOUT THE PREMISES, THE BUILDING OR THE PROJECT, BY OR FROM ANY UNAUTHORIZED OR CRIMINAL ACTS OF THIRD PARTIES, REGARDLESS OF ANY ACTION, INACTION, FAILURE, BREAKDOWN, MALFUNCTION AND/OR INSUFFICIENCY OF THE ACCESS CONTROL OR COURTESY GUARD SERVICES PROVIDED BY LANDLORD, IF ANY. Tenant shall provide such supplemental security services and shall install within the Premises such supplemental security equipment, systems and procedures as may reasonably be required for the protection of its employees and invitees, provided that Tenant shall coordinate such services and equipment with any security provided by Landlord. The determination of the extent to which such supplemental security equipment, systems and procedures are reasonably required shall be made in the sole judgment, and shall be the sole responsibility, of Tenant. Tenant acknowledges that it has neither received nor relied upon any representation or warranty made by or on behalf of Landlord with respect to the safety or security of the Premises or the Project or any part thereof or the extent or effectiveness of any security measures or procedures now or hereafter provided by Landlord, and further acknowledges that Tenant has made its own independent determinations with respect to all such matters.
Network Access Control The VISION Web Site and the Distribution Support Services Web Site (the “DST Web Sites”) are protected through multiple levels of network controls. The first defense is a border router which exists at the boundary between the DST Web Sites and the Internet Service Provider. The border router provides basic protections including anti-spoofing controls. Next is a highly available pair of stateful firewalls that allow only HTTPS traffic destined to the DST Web Sites. The third network control is a highly available pair of load balancers that terminate the HTTPS connections and then forward the traffic on to one of several available web servers. In addition, a second highly available pair of stateful firewalls enforce network controls between the web servers and any back-end application servers. No Internet traffic is allowed directly to the back-end application servers. The DST Web Sites equipment is located and administered at DST’s Winchester data center. Changes to the systems residing on this computer are submitted through the DST change control process. All services and functions within the DST Web Sites are deactivated with the exception of services and functions which support the transfer of files. All ports on the DST Web Sites are disabled, except those ports required to transfer files. All “listeners,” other than listeners required for inbound connections from the load balancers, are deactivated. Directory structures are “hidden” from the user. Services which provide directory information are also deactivated.
Access Controls a. Authorized Access - DST shall have controls that are designed to maintain the logical separation such that access to systems hosting Fund Data and/or being used to provide services to Fund will uniquely identify each individual requiring access, grant access only to authorized personnel based on the principle of least privileges, and prevent unauthorized access to Fund Data.
User Access Transfer Agent shall have a process to promptly disable access to Fund Data by any Transfer Agent personnel who no longer requires such access. Transfer Agent will also promptly remove access of Fund personnel upon receipt of notification from Fund.
Site Access The Buyer agrees to RELEASE, INDEMNIFY AND HOLD HARMLESS the Seller Indemnitees from and against the entirety of any Adverse Consequences that are suffered by the Seller Indemnitees arising out of, resulting from or relating to any field visit or other due diligence activities relating to any performance of the Diligence Activities to the extent caused by acts or omissions of any Buyer Party or Buyer Diligence Representative, even if such Adverse Consequences arise out of or result from, solely or in part, the sole, active, passive, concurrent or comparative negligence, strict liability or other fault or violation of Law of or by the Seller Indemnitees, except Adverse Consequences to the extent resulting from the gross negligence or willful misconduct of the Seller Indemnitees.
Emergency Generator Tenant shall have the right to tie into and use the emergency generator to be installed by Landlord as part of the Base Building Work for use by tenants of the Unit (the “Unit Generator”). Tenant shall be responsible, at its sole cost and expense, for installing, maintaining, repairing and replacing its connection between the Premises and the Unit Generator, and all associated cabling. Tenant shall be permitted to use up to an average of three (3) xxxxx per square foot of usable area in the Premises from the Unit Generator, and at no time shall Tenant exceed that use limitation with respect to the Unit Generator. Except to the extent that Tenant ties into the Unit Generator as part of the Initial Tenant Work in accordance with the provisions of the Work Letter, installation of such tie-in and any related cabling, conduit and appurtenances will be governed by the applicable provisions of this Lease relating to Tenant Work. Tenant will submit to Landlord at least thirty (30) days prior to the proposed installation date Tenant’s proposed plans and specifications relating to the tie-in to the Unit Generator and all associated lines. Tenant may not commence any work to tie into the Unit Generator until it has received Landlord’s prior written approval (not to be unreasonably withheld, delayed or conditioned) of such plans and specifications. Tenant, at its sole cost and expense, shall comply with all applicable Legal Requirements and Title Matters and Landlord’s reasonable directives relating to the installation, operation, maintenance and repair of such tie-in, including (i) obtaining and maintaining (or causing to be obtained and maintained) and complying with the provisions of all applicable permits relating to the tie into and use of the Unit Generator. Tenant may not use the Unit Generator for any purpose other than solely in connection with Tenant’s occupancy of the Premises for the Permitted Use and in accordance with any applicable permit(s) pertaining to the Unit Generator. Except for permitted subtenants and assignees. Tenant may not use the Unit Generator to serve other occupant(s) of the Development.
Control Areas Tenant shall be allowed to utilize up to its pro rata share of the Hazardous Materials inventory within any control area or zone (located within the Premises), as designated by the applicable building code, for chemical use or storage. As used in the preceding sentence, Tenant’s pro rata share of any control areas or zones located within the Premises shall be determined based on the rentable square footage that Tenant leases within the applicable control area or zone. For purposes of example only, if a control area or zone contains 10,000 rentable square feet and 2,000 rentable square feet of a tenant’s premises are located within such control area or zone (while such premises as a whole contains 5,000 rentable square feet), the applicable tenant’s pro rata share of such control area would be 20%.
Early Access Sublandlord agrees to cooperate with Subtenant to allow Subtenant access to the Initial Premises from the day following the Consent Date to the Delivery Date and deliver exclusive possession of the Initial Premises, including the Data Room (but excluding the Lab Space), on the Delivery Date, for design and construction purposes and for the purposes of the installation of furniture, fixtures and equipment and preparing the Initial Premises for occupancy (the “Early Access Activities”), provided that Subtenant has first given Sublandlord at least one (1) business day’s prior notice of any such access (for access prior to the Delivery Date only) and has first delivered to Sublandlord a certificate of insurance evidencing compliance with the insurance obligations herein. Such access (a) shall be solely for the Early Access Activities and not for the purposes of occupancy or possession of the Initial Premises, or of conducting business therein, and (b) shall be subject to and upon all the terms and conditions of this Sublease (including without limitation Section 11 hereof), except that Subtenant shall have no obligation to pay Base Rent or Additional Rent for the period prior to the Initial Premises Commencement Date; provided, however, that if Subtenant’s pursuit of the Early Access Activities causes an increase of more than ten percent (10%) in the cost of utilities (including without limitation water, electricity, heat or air conditioning) allocable to the Initial Premises on a square-foot basis (as compared to the average cost for such utilities over the prior three (3) months), Subtenant shall reimburse Sublandlord for such increase in the cost of utilities within thirty (30) days following Sublandlord’s presentation of an invoice therefor (including reasonable supporting documentation), which invoice shall be presented to Subtenant within fifteen (15) days following each month of such Early Access Activities. The Early Access Activities shall be performed between the hours of 6:00 a.m. and 5:00 p.m. on business days, and shall be coordinated with Sublandlord. Subtenant’s early access shall not affect or alter the Initial Premises Commencement Date, the Expansion Premises Commencement Date, the Expiration Date, or the Term.
Full Access The Seller will permit representatives of the Buyer to have full access at all reasonable times, and in a manner so as not to interfere with the normal business operations of the Seller to the Property and to obtain copies of all books, records, contracts, and documents of or pertaining to the Property.
Tenant Access Landlord, in Landlord’s reasonable discretion and upon receipt of a written request from Tenant, may grant Tenant a license to have access to the Premises prior to the Completion Date to allow Tenant to do other work required by Tenant to make the Premises ready for Tenant’s use and (the “Tenant’s Pre-Occupancy Work”). It shall be a condition to the grant by Landlord and continued effectiveness of such license that:
