Indemnification by the Purchaser Each Purchaser will severally and not jointly indemnify and hold harmless the Company, each of its directors, each of its officers who signed the Registration Statement and each person, if any, who controls the Company within the meaning of the Securities Act, against any losses, claims, damages, liabilities or expenses to which the Company, each of its directors, each of its officers who signed the Registration Statement or controlling person may become subject, under the Securities Act, the Exchange Act, or any other federal or state statutory law or regulation, or at common law or otherwise (including in settlement of any litigation, if such settlement is effected with the written consent of such Purchaser, which consent shall not be unreasonably withheld) insofar as such losses, claims, damages, liabilities or expenses (or actions in respect thereof as contemplated below) arise out of or are based upon (i) any failure on the part of such Purchaser to comply with the covenants and agreements contained in Sections 5.2 or 7.2 of this Agreement respecting the sale of the Shares or (ii) the inaccuracy of any representation made by such Purchaser in this Agreement or (iii) any untrue or alleged untrue statement of any material fact contained in the Registration Statement, the Prospectus, or any amendment or supplement to the Registration Statement or Prospectus, or arise out of or are based upon the omission or alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein not misleading, in each case to the extent, but only to the extent, that such untrue statement or alleged untrue statement or omission or alleged omission was made in the Registration Statement, the Prospectus, or any amendment or supplement thereto, in reliance upon and in conformity with written information furnished to the Company by or on behalf of such Purchaser expressly for use therein; provided, however, that the Purchaser shall not be liable for any such untrue or alleged untrue statement or omission or alleged omission of which the Purchaser has delivered to the Company in writing a correction before the occurrence of the transaction from which such loss was incurred, and the Purchaser will reimburse the Company, each of its directors, each of its officers who signed the Registration Statement or controlling person for any legal and other expense reasonably incurred by the Company, each of its directors, each of its officers who signed the Registration Statement or controlling person in connection with investigating, defending, settling, compromising or paying any such loss, claim, damage, liability, expense or action.
Indemnification by the Borrower The Borrower shall indemnify each Recipient, within 10 days after demand therefor, for the full amount of any Indemnified Taxes (including Indemnified Taxes imposed or asserted on or attributable to amounts payable under this Section) payable or paid by such Recipient or required to be withheld or deducted from a payment to such Recipient and any reasonable expenses arising therefrom or with respect thereto, whether or not such Indemnified Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to the Borrower by a Lender (with a copy to the Administrative Agent), or by the Administrative Agent on its own behalf or on behalf of a Lender, shall be conclusive absent manifest error.
Indemnity by Seller (a) Seller shall release, defend, indemnify and hold harmless Buyer, its directors, officers, agents, attorneys, representatives and Affiliates (“Buyer Group”) against and from any Indemnifiable Losses, which arise out of or relate to or are in any way connected with (i) the Seller’s delivery of the Product to Buyer, (ii) Seller’s or its Affiliates’ ownership, development, construction, operation and/or maintenance of the Project, including the Sites(s); (iii) Third Party Claims arising from Seller’s or its Affiliates’ actions or inactions, including Seller’s breach of this Agreement or other agreements related to the development, construction, ownership, operation or maintenance of the Project or Site; (iv) any environmental matters associated with the Project, including the disposal and transportation of Hazardous Substances by or on behalf of the Seller or at the Seller’s direction or agreement; (v) Third Party Claims arising under any agreement between Seller or its Affiliates ; or (vi) resulting from Seller’s or its Affiliates’ violation of any applicable Law, or requirements of Transmission Provider, Utility Distribution Company, NERC, WECC or Reliability Organization; in each case including any loss, claim, action or suit, for or on account of injury to, bodily or otherwise, or death of, persons, or for damage to or destruction or economic loss of property belonging to Xxxxx, Seller, Seller’s Affiliates, or others, excepting only such Indemnifiable Losses, to the extent solely caused by the willful misconduct or gross negligence of a member of the Buyer Group.
Indemnification by the Company The Company agrees to indemnify and hold harmless each Investor and each other holder of Registrable Securities, and each of their respective officers, employees, affiliates, directors, partners, members, attorneys and agents, and each person, if any, who controls an Investor and each other holder of Registrable Securities (within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act) (each, an “Investor Indemnified Party”), from and against any expenses, losses, judgments, claims, damages or liabilities, whether joint or several, arising out of or based upon any untrue statement (or allegedly untrue statement) of a material fact contained in any Registration Statement under which the sale of such Registrable Securities was registered under the Securities Act, any preliminary prospectus, final prospectus or summary prospectus contained in the Registration Statement, or any amendment or supplement to such Registration Statement, or arising out of or based upon any omission (or alleged omission) to state a material fact required to be stated therein or necessary to make the statements therein not misleading, or any violation by the Company of the Securities Act or any rule or regulation promulgated thereunder applicable to the Company and relating to action or inaction required of the Company in connection with any such registration; and the Company shall promptly reimburse the Investor Indemnified Party for any legal and any other expenses reasonably incurred by such Investor Indemnified Party in connection with investigating and defending any such expense, loss, judgment, claim, damage, liability or action; provided, however, that the Company will not be liable in any such case to the extent that any such expense, loss, claim, damage or liability arises out of or is based upon any untrue statement or allegedly untrue statement or omission or alleged omission made in such Registration Statement, preliminary prospectus, final prospectus, or summary prospectus, or any such amendment or supplement, in reliance upon and in conformity with information furnished to the Company, in writing, by such selling holder expressly for use therein. The Company also shall indemnify any Underwriter of the Registrable Securities, their officers, affiliates, directors, partners, members and agents and each person who controls such Underwriter on substantially the same basis as that of the indemnification provided above in this Section 4.1.
Indemnity by Buyer Buyer shall release, indemnify and hold harmless Seller, its directors, officers, agents, and representatives against and from any and all loss, Claims, actions or suits, including costs and attorney’s fees resulting from, or arising out of or in any way connected with the Product delivered by Seller under this Agreement after the Delivery Point, including any loss, Claim, action or suit, for or on account of injury to, bodily or otherwise, or death of persons, or for damage to or destruction of property belonging to Buyer, Seller, or others, excepting only such loss, Claim, action or suit as may be caused solely by the willful misconduct or gross negligence of Seller, its Affiliates, or Seller’s and Affiliates’ respective agents, employees, directors or officers.
Damages for delay by the Authority In the event that (i) the Authority does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.2 within the period specified in respect thereof, and (ii) the delay has not occurred as a result of breach of this Agreement by the Concessionaire or due to Force Majeure, the Authority shall pay to the Concessionaire Damages in an amount calculated at the rate of 0.1% (zero point one per cent) of the Performance Security for each day‟s delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:
Indemnification by the Lenders Each Lender shall severally indemnify the Administrative Agent, within 10 days after demand therefor, for (i) any Indemnified Taxes attributable to such Lender (but only to the extent that any Loan Party has not already indemnified the Administrative Agent for such Indemnified Taxes and without limiting the obligation of the Loan Parties to do so), (ii) any Taxes attributable to such Lender’s failure to comply with the provisions of Section 9.04(c) relating to the maintenance of a Participant Register and (iii) any Excluded Taxes attributable to such Lender, in each case, that are payable or paid by the Administrative Agent in connection with any Loan Document, and any reasonable expenses arising therefrom or with respect thereto, whether or not such Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to any Lender by the Administrative Agent shall be conclusive absent manifest error. Each Lender hereby authorizes the Administrative Agent to set off and apply any and all amounts at any time owing to such Lender under any Loan Document or otherwise payable by the Administrative Agent to the Lender from any other source against any amount due to the Administrative Agent under this paragraph (e).
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Indemnity by You You will indemnify Siemens, our suppliers and contractors, and each of their respective employees, officers, directors, and representatives from and against, and, at Siemens’ option, defend Siemens from, any claims, damages, liabilities, losses, costs and expenses (including reasonable attorney’s fees) arising from or in connection with: (i) Your Content; (ii) any violation of Laws or rights of others by your use of the Services; (iii) any breach by you of the DSA; (iv) operation, combination, or use of the Services in conjunction with any of Your Content and/or in conjunction with any Third Party software, materials, or services; (v) an adjustment or configuration of the Services made by you or a Third Party to which you facilitate or permit access to the Services, including Users; (vi) our compliance with designs, plans, or specifications provided to us by you or on your behalf; (vii) any claims by any User or any Third Party to which you facilitate or permit access to the Services; (viii) your use of Siemens’ trademarks, designations, and logos in breach of the authorization granted to you in a Specification Document; and (ix) the use of a Service for the operation of or within a High Risk System, if the functioning of a High Risk System depends on the proper functioning of a Service or a Service caused a High Risk System to fail. Section 7.1.1 shall apply mutatis mutandis.
