FP Task Orders Sample Clauses
FP Task Orders. Under FP Task Orders, based upon Contractor’s reasonable business judgment, Contractor will perform those tasks necessary to efficiently and effectively perform the Required Change. If mutually agreed, the Project Plan, schedule and FP for the Task Order shall be extended and amended to provide an equitable adjustment. If the parties fail to mutually agree as to Scope or equitable adjustment in schedule or FP for the Change Order, the parties shall submit the failure to agree to dispute resolution pursuant to Section 27, and upon resolution of such proceedings, Services performed after the date of the Required Change shall be tailored in accordance with the resulting decision and a Change Order shall be executed by the parties reflecting any equitable adjustment in Scope, schedule and FP for the Task Order. Either party may call an Emergency Meeting during the pendency of the dispute resolution proceeding to discuss the Change Order, the performance of the Services and the adjusted Project Plan, schedule and FP of the Task Order during which Emergency Meeting the parties will continue to work to reach mutual agreement. It is recognized that not all Required Changes will result in an increase in the FP of a Task Order, but both parties acknowledge and agree that if a Required Change causes an increase in the cost of performance of a Task Order and/or requires additional or different time for delivery of Services, the FP of a Task Order will be equitably adjusted and/or the schedule will be equitably extended (as applicable).
FP Task Orders. Contractor will perform the Services in accordance with this Agreement and the FP Task Order.
FP Task Orders. Under FP Task Orders, the parties shall promptly submit the matter to dispute resolution in accordance with Section 27. During the pendency of such dispute resolution, Contractor will continue performance of the Services as determined by Contractor in its reasonable business judgment, performing those tasks necessary in Contractor’s judgment to mitigate further delay to the Project Plan. The Project Plan and schedule may be adjusted as necessary based upon Contractor’s reasonable business judgment during the pendency of the dispute resolution. Either party may call an Emergency Meeting during the pendency of the dispute resolution proceeding to discuss the Change Order, the performance of the Services, and/or any adjusted Project Plan, FP and schedule during which Emergency Meeting the parties will continue to work to reach mutual agreement. Upon completion of the dispute resolution proceedings, the parties shall enter into a Change Order in accordance with the dispute resolution determination that equitably compensates Contractor for the Services performed as a result of the Client Delay and equitably adjusts the Project schedule. All Services resulting from the Client Delay shall be tailored in accordance with the decision resulting from resolution of the dispute. For clarity’s sake, the amount of Fees paid to Contractor during the pendency of the dispute resolution shall reduce the amount of Fees that Contractor may collect with regard to the Client Delay. It is recognized that not all Client Delays will result in an increase in the FP of a Task Order, but both parties acknowledge and agree that if a Client Delay causes an increase in the cost of performance of a Task Order or requires additional or different time for delivery of Services, the FP of the Task Order will be equitably adjusted and/or the schedule will be equitably extended (as applicable).