Final EIS Sample Clauses

Final EIS. Following receipt of the comments on the draft EIS, WAC ▇▇▇-▇▇-▇▇▇ specifies that a final EIS will consider the public and agency comments on the draft EIS. Potential responses in the final EIS include: • Modify alternatives, including the proposed action • Develop and evaluate alternatives not previously given detailed consideration by the agency • Supplement, improve, or modify the analysis • Make factual corrections • Explain why the comments do not warrant further agency response, citing the sources, authorities, or reasons that support the agencies response and, if appropriate, indicate those circumstances that would trigger agency reappraisal or further response The work associated with the final EIS is dependent on the comments received but could include the need to conduct additional technical analysis. At a minimum, the comments must be addressed and a final EIS issued. The final EIS will consist of an update to the draft EIS with the compiled public comments. The scope of work for the final EIS may not be fully estimated until completion of the draft EIS and review of the agency and public comments on the draft EIS has been completed. A final, separate scope of work for the final EIS shall be re-evaluated after results of the public comments have been received on the draft EIS additional analysis is required a separate scope and fee can be provided. Once complete, a draft final EIS will be provided to the City for one round of review and the contractor would incorporate comments into a final EIS. The final EIS would be provided to the City in a PDF format. No action can be taken on the plan, PAO, or any other permits until seven days following completion of the final EIS.
View Source

Related to Final EIS

  • Final Evaluation IC must submit a final report and a project evaluation to the Arts Commission within thirty (30) days after the completion of the Services. Any and all unexpended funds from IC must be returned to City no later than sixty (60) days after the completion of the Services.

  • FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such 9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees. 9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from: (a) unsettled liens, (b) faulty or defective Work appearing after Substantial Completion, (c) failure of the Work to comply with the requirements of the Contract Documents, or (d) terms of any special warranties required by the Contract Documents. 9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.

  • Final Retention Subject to the terms hereof, Landlord shall deliver to Tenant a check for the Final Retention, together with any other undisbursed portion of the Allowance required to pay for the Allowance Items, within 30 days after the latest of (a) the completion of the Tenant Improvement Work in accordance with the approved plans and specifications; (b) Landlord’s receipt of (i) copies of all Tenant Improvement Contracts; (ii) copies of invoices for all labor and materials provided to the Premises; (iii) executed unconditional mechanic’s lien releases satisfying California Civil Code §8134 for all prior payments made pursuant to Section 1.2.2.1 above (to the extent not previously provided to Landlord), together with executed unconditional final mechanic’s lien releases satisfying California Civil Code § 8138 for all labor and materials provided to the Premises subject to the Final Retention; (iv) a certificate from Tenant’s architect, in a form reasonably acceptable to Landlord, certifying that the Tenant Improvement Work has been substantially completed; (v) evidence that all governmental approvals required for Tenant to legally occupy the Premises have been obtained; and (vi) any other information reasonably requested by Landlord; (c) Tenant’s delivery to Landlord of “as built” drawings (in CAD format, if requested by Landlord); or (d) Tenant’s compliance with Landlord’s standard “close-out” requirements regarding city approvals, closeout tasks. Tenant’s contractor, financial close-out matters, and Tenant’s vendors. Landlord’s payment of the Final Retention shall not be deemed Landlord’s approval or acceptance of the Tenant Improvement Work.

  • Final Payment A. Upon final completion and acceptance of the Work in accordance with Paragraph 15.06 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said Paragraph 15.06.

  • Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.