Failure to Agree. If the Contractor claims entitlement to a change in the Contract, and the Department does not agree that any action or event has occurred to justify any change in time or compensation, or if the parties fail to agree upon the appropriate amount of the adjustment in time or compensation, the Department will unilaterally make such changes, if any, to the Contract, as it determines are appropriate pursuant to the Contract. The Contractor shall proceed with the Work and the Department's directives, without interruption or delay, and shall make a claim as provided in Article 12. Failure to proceed due to a dispute over a change request shall constitute a material breach of the Contract and entitle the Department to all available remedies for such breach, including, without limitation, termination for default.
Failure to Agree. Where the parties do not reach agreement within sixty (60) days after the date on which the Union has received notification from the College of its intention of introduction of the technological change, and various matters remain unresolved, the parties shall refer such matters to arbitration within twenty-one (21) calendar days of failure to agree.
Failure to Agree. (a) If the Parties are unable to agree either (i) as between themselves upon the material terms of the Transaction or the Debt Financing for the Transaction, or (ii) with the Special Committee on the material terms of a Transaction which the Special Committee agrees to recommend to the public shareholders of the Target, or (b) a Party is not satisfied with the results of its due diligence investigation, then, subject to Section 5.3(a), (I) a Party may cease its participation in the Transaction by delivery of a written notice to the other Parties and (II) this Agreement shall terminate with respect to such withdrawing Party.
Failure to Agree. If the Design-Builder claims entitlement to a change in the Agreement, and the Department does not agree that any action or event has occurred to justify any change in time or compensation, or if the Parties fail to agree upon the appropriate amount of the adjustment in time or compensation, the Department will unilaterally make such changes, if any, to the Agreement, as it determines are appropriate pursuant to the Agreement. The Design-Builder shall proceed with the Work and the Department's directives, without interruption or delay, and shall make a claim as provided in Article 18 herein. Failure to proceed due to a dispute over a change request shall constitute a material breach of the Contract and entitle the Department to all available remedies for such breach, including, without limitation, termination for default.
Failure to Agree. If the Parties cannot agree on the extent of any delay incurred or relief from the Development Entity’s obligations under this PPA, or the Department disagrees that a Relief Event has occurred (or as to its consequences), or that the Development Entity is entitled to relief under this Article 12 (Supervening Events), the Parties shall resolve the matter in accordance with the Dispute Resolution Procedures.
Failure to Agree. In the event of the failure of the CONTRACTOR and the OWNER to agree, as provided herein, upon the whole amount to be paid to the CONTRACTOR by reason of the termination of work pursuant to this section, the OWNER shall determine, on the basis of information available to it, the amount, if any, due to the CONTRACTOR by reason of the termination and shall pay to the CONTRACTOR the amounts determined. No amount shall be due for lost or anticipated profits.
Failure to Agree. 5.1 In the event that the Party requesting a Change believes that the requested Change is required or necessary, the requesting Party shall inform the other Party in writing of such nature of the proposed Change. In the event that the other Party does not agree to implement the Change, the requesting Party shall be entitled to consider the other Party's failure to agree to implement the Change as a Dispute, and the requesting Party may escalate such Dispute for resolution in accordance with the Dispute Resolution Schedule and the Agreement.
Failure to Agree. If the Parties cannot agree the extent of any compensation, delay incurred, relief from the Contractor’s obligations under this Contract, or the Authority disagrees that a Compensation Event has occurred (or as to its consequences), or that the Contractor is entitled to relief under this clause 15 (Compensation Events), the Parties shall resolve the matter in accordance with the Dispute Resolution Procedure.
Failure to Agree. In the event that the Parties fail to agree on the choice of an Arbitrator, they shall forthwith request the Director of the Collective Agreement Arbitration Bureau to appoint an Arbitrator.
