Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.
Giving Notice Except as otherwise permitted by Section 2.14 with respect to borrowing notices, all notices and other communications provided to any party hereto under this Agreement or any other Loan Document shall be in writing or by telex or by facsimile and addressed or delivered to such party at its address set forth below its signature hereto or at such other address (or to counsel for such party) as may be designated by such party in a notice to the other parties. Any notice, if mailed and properly addressed with postage prepaid, shall be deemed given when received; any notice, if transmitted by telex or facsimile, shall be deemed given when transmitted (answerback confirmed in the case of telexes).
Notification of Delay The Design Professional shall immediately notify the City in writing if Design Professional experiences or anticipates experiencing a delay in performing the Professional Services within the time frames set forth in the Task Order. The written notice shall include an explanation of the cause for, and a reasonable estimate of the length of, the delay. If in the opinion of the City, the delay affects a material part of the Task, the City may exercise its rights under Sections 2.5-2.7 of this Agreement.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Lay-off Notice In cases of lay-off, the Company will give as much notice as possible.
STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
