EXTENSIONS IN THE CONTRACT TIME Sample Clauses

Open Split View

Download

Share

Cite

EXTENSIONS IN THE CONTRACT TIME. BY CHANGE ORDERS ARE SUBJECT TO EXTENSION-IN-TIME AUDIT BY THE OWNER AS FOLLOWS:

Sample 1Sample 2

Save

Copy

Related to EXTENSIONS IN THE CONTRACT TIME

• Limitations in Tariffs A Party may, in its sole discretion, provide in its tariffs and contracts with its End Users and third parties that relate to any service, product or function provided or contemplated under this Agreement, that to the maximum extent permitted by Applicable Law, such Party shall not be liable to the End User or third Party for (i) any loss relating to or arising out of this Agreement, whether in contract, tort or otherwise, that exceeds the amount such Party would have charged that applicable person for the service, product or function that gave rise to such loss and (ii)

• Extensions; Waivers Any party may, for itself only, (i) extend the time for the performance of any of the obligations of any other party under this Agreement, (ii) waive any inaccuracies in the representations and warranties of any other party contained herein or in any document delivered pursuant hereto and (iii) waive compliance with any of the agreements or conditions for the benefit of such party contained herein. Any such extension or waiver will be valid only if set forth in a writing signed by the party to be bound thereby. No waiver by any party of any default, misrepresentation or breach of warranty or covenant hereunder, whether intentional or not, may be deemed to extend to any prior or subsequent default, misrepresentation or breach of warranty or covenant hereunder or affect in any way any rights arising because of any prior or subsequent such occurrence. Neither the failure nor any delay on the part of any party to exercise any right or remedy under this Agreement will operate as a waiver thereof, nor will any single or partial exercise of any right or remedy preclude any other or further exercise of the same or of any other right or remedy.

• Extensions and Waivers At any time prior to the Closing, the parties hereto entitled to the benefits of a term or provision may (a) extend the time for the performance of any of the obligations or other acts of the parties hereto, (b) waive any inaccuracies in the representations and warranties contained herein or in any document, certificate or writing delivered pursuant hereto, or (c) waive compliance with any obligation, covenant, agreement or condition contained herein. Any agreement on the part of a party to any such extension or waiver shall be valid only if set forth in an instrument or instruments in writing signed by the party against whom enforcement of any such extension or waiver is sought. No failure or delay on the part of any party hereto in the exercise of any right hereunder shall impair such right or be construed to be a waiver of, or acquiescence in, any breach of any representation, warranty, covenant or agreement.

• Waivers and Extensions Any party to this Agreement may waive any right, breach or default which such party has the right to waive, provided that such waiver will not be effective against the waiving party unless it is in writing, is signed by such party, and specifically refers to this Agreement. Waivers may be made in advance or after the right waived has arisen or the breach or default waived has occurred. Any waiver may be conditional. No waiver of any breach of any agreement or provision herein contained shall be deemed a waiver of any preceding or succeeding breach thereof nor of any other agreement or provision herein contained. No waiver or extension of time for performance of any obligations or acts shall be deemed a waiver or extension of the time for performance of any other obligations or acts.

• DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.

• Modifications in Writing 19. No change, modification, extension, termination or waiver of this Agreement, or any of the provisions herein contained, shall be valid unless made in writing and signed by a duly authorized representative of each party.

• Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.

• Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.

• Amendments, Etc. With Respect to the Obligations Each Guarantor shall remain obligated hereunder notwithstanding that, without any reservation of rights against any Guarantor and without notice to or further assent by any Guarantor, any demand for payment of any of the Obligations made by the Purchasers may be rescinded by the Purchasers and any of the Obligations continued, and the Obligations, or the liability of any other Person upon or for any part thereof, or any collateral security or guarantee therefor or right of offset with respect thereto, may, from time to time, in whole or in part, be renewed, extended, amended, modified, accelerated, compromised, waived, surrendered or released by the Purchasers, and the Purchase Agreement and the other Transaction Documents and any other documents executed and delivered in connection therewith may be amended, modified, supplemented or terminated, in whole or in part, as the Purchasers may deem advisable from time to time, and any collateral security, guarantee or right of offset at any time held by the Purchasers for the payment of the Obligations may be sold, exchanged, waived, surrendered or released. The Purchasers shall have no obligation to protect, secure, perfect or insure any Lien at any time held by them as security for the Obligations or for the guarantee contained in this Section 2 or any property subject thereto.

• Termination of Commitment to Lend Notwithstanding anything in the Loan Documents, Lender's obligation to lend the undisbursed portion of the Commitment to Borrower hereunder shall terminate on the earlier of (i) at the Lender's sole election, the occurrence and continuance of any Default or Event of Default hereunder, and (ii) the Commitment Termination Date. Notwithstanding the foregoing, Lender's obligation to lend the undisbursed portion of the Commitment to Borrower shall terminate if, in Lender's sole judgment, there has been a material adverse change in the general affairs, management, results of operations, condition (financial or otherwise) or prospects of Borrower, whether or not arising from transactions in the ordinary course of business, or there has been any material adverse deviation by Borrower from the business plan of Borrower presented to and not disapproved by Lender, since the date of this Agreement.