Equitable Adjustment The Department may, in its sole discretion, make an equitable adjustment in the Term Contract terms or pricing if pricing or availability of supply is affected by extreme and unforeseen volatility in the marketplace, that is, by circumstances that satisfy all the following criteria: (1) the volatility is due to causes wholly beyond the Contractor’s control, (2) the volatility affects the marketplace or industry, not just the particular Term Contract source of supply, (3) the effect on pricing or availability of supply is substantial, and (4) the volatility so affects the Contractor that continued performance of the Term Contract would result in a substantial loss.
Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Additional Adjustment If, in Dealer’s commercially reasonable judgment, the actual cost to Dealer (or an affiliate of Dealer), over any 10 consecutive Scheduled Trading Day period, of borrowing a number of Shares equal to the Number of Shares to hedge in a commercially reasonable manner its exposure to the Transaction exceeds a weighted average rate equal to 25 basis points per annum, the Calculation Agent shall reduce the Forward Price to compensate Dealer for the amount by which such cost exceeded a weighted average rate equal to 25 basis points per annum during such period. The Calculation Agent shall notify Counterparty prior to making any such adjustment to the Forward Price. Extraordinary Events: In lieu of the applicable provisions contained in Article 12 of the Equity Definitions, the consequences of any Extraordinary Event (including, for the avoidance of doubt, any Merger Event, Tender Offer, Nationalization, Insolvency, Delisting, or Change In Law) shall be as specified below under the headings “Acceleration Events” and “Termination Settlement” in Paragraphs 7(f) and 7(g), respectively. Notwithstanding anything to the contrary herein or in the Equity Definitions, no Additional Disruption Event will be applicable except to the extent expressly referenced in Paragraph 7(f)(iv) below. The definition of “Tender Offer” in Section 12.1(d) of the Equity Definitions is hereby amended by replacing “10%” with “20%.” Dividends: No adjustment shall be made if, on any day occurring after the Trade Date, Counterparty declares a distribution, issue or dividend to existing holders of the Shares of (i) any cash dividend (other than an Extraordinary Dividend) to the extent all cash dividends having an ex-dividend date during the period from and including any Forward Price Reduction Date (with the Trade Date being a Forward Price Reduction Date for purposes of this clause (i) only) to but excluding the next subsequent Forward Price Reduction Date differs from, on a per Share basis, the Forward Price Reduction Amount set forth opposite the first date of any such period on Schedule I, (ii) share capital or securities of another issuer acquired or owned (directly or indirectly) by Counterparty as a result of a spin-off or other similar transaction or (iii) any other type of securities (other than Shares), rights or warrants or other assets, for payment (cash or other consideration) at less than the prevailing market price as determined by Dealer. Non-Reliance: Applicable Agreements and Acknowledgments: Regarding Hedging Activities: Applicable Additional Acknowledgments: Applicable Hedging Party: Dealer Transfer: Notwithstanding anything to the contrary herein or in the Agreement, Dealer may assign, transfer and set over all rights, title and interest, powers, obligations, privileges and remedies of Dealer under the Transaction, in whole or in part, to (A) a wholly-owned subsidiary of Dealer, whose obligations hereunder are fully and unconditionally guaranteed by Dealer, or (B) any other wholly-owned direct or indirect subsidiary of Dealer with a long-term issuer rating equal to or better than the credit rating of Dealer at the time of transfer after obtaining Counterparty’s consent (which shall not be unreasonably withheld or delayed); provided that, (i) at the time of such assignment or transfer, Counterparty would not, as a result of such assignment or transfer, designation or delegation, reasonably be expected at any time (A) to be required to pay (including a payment in kind) to Dealer or such transferee or assignee or designee an amount in respect of an Indemnifiable Tax greater than the amount Counterparty would have been required to pay to Dealer in the absence of such assignment, transfer, designation or delegation, or (B) to receive a payment (including a payment in kind) after such assignment or transfer that is less than the amount Counterparty would have received if the payment were made immediately prior to such assignment or transfer, (ii) prior to such assignment or transfer, Dealer shall have caused the assignee, transferee, or designee to make such Payee Tax Representations and to provide such tax documentation as may be reasonably requested by Counterparty to permit Counterparty to determine that the transfer complies with the requirements of clause (i) in this Paragraph, and (iii) at all times, Dealer or any transferee or assignee or other recipient of rights, title and interest, powers, obligations, privileges and remedies shall be eligible to provide a U.S. Internal Revenue Service Form W-9 or W-8ECI, or any successor thereto, with respect to any payments or deliveries under the Agreement.
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
Proportional Adjustment In the event the Corporation shall at any time after the issuance of any share or shares of Series A Participating Preferred Stock (i) declare any dividend on Common Stock of the Corporation ("COMMON STOCK") payable in shares of Common Stock, (ii) subdivide the outstanding Common Stock or (iii) combine the outstanding Common Stock into a smaller number of shares, then in each such case the Corporation shall simultaneously effect a proportional adjustment to the number of outstanding shares of Series A Participating Preferred Stock.
