Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this Subcontract, other than those subject to a good faith dispute, the Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute is being considered, arbitrated or litigated. Failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the Subcontract.
Appears in 6 contracts
Samples: Agreement, www.wohlsenconstruction.com, www.wohlsenconstruction.com
Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this Subcontract, other than those subject to a good faith dispute, the The Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute Claim is being considered, arbitrated or litigated. Failure Subcontractor agrees to comply with Contractor’s direction to proceed with work that is the subject of a good faith dispute, and failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the Subcontract.
Appears in 5 contracts
Samples: wohlsenconstruction.com, wohlsenconstruction.com, wohlsenconstruction.com
Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this Subcontract, other than those subject to a good faith dispute, the Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute is being considered, arbitrated or litigated. Failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the this Subcontract.
Appears in 3 contracts
Samples: www.wohlsenconstruction.com, www.wohlsenconstruction.com, www.wohlsenconstruction.com
Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this Subcontract, other than those subject to a good faith dispute, the The Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute Claim is being considered, arbitrated or litigated. Failure Subcontractor agrees to comply with Xxxxxxxxxx’s direction to proceed with work that is the subject of a good faith dispute, and failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the Subcontract.
Appears in 2 contracts
Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this Subcontract, other than those subject to a good faith dispute, the The Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute Claim is being considered, arbitrated or litigated. Failure Subcontractor agrees to comply with Xxxxxxxxxx’s direction to proceed with work that is the subject of a good faith dispute, and failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the Subcontract.. SAMPLE
Appears in 1 contract
Samples: wohlsenconstruction.com
Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this SubcontractAgreement, other than those subject to a good faith dispute, the Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute is being considered, arbitrated or litigated. Failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the Subcontract.this Agreement. 73504
Appears in 1 contract
Samples: Agreement
Duty to Continue Work. If the Contractor has promptly paid the Subcontractor all amounts due under this Subcontract, other than those subject to a good faith dispute, the The Subcontractor shall proceed with the Work, including any disputed portion thereof, without interruption or delay, while any claim or dispute Claim is being considered, arbitrated or litigated. Failure Subcontractor agrees to comply with Contractor’s direction to proceed with work that is the subject of a good faith dispute, and failure to continue to work diligently during the pendency of a dispute or claim shall constitute a material breach of the Subcontract.. SAMPLE
Appears in 1 contract
Samples: wohlsenconstruction.com