Common use of Delay Payments Clause in Contracts

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s Suppliers failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s Suppliers failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Contract Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 39 (Customer Termination Rights) except Clause 41.7 39.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 46 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 34 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or the delay exceeds the number period of [one hundred (100)] days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract Lease Agreement pursuant to Clause 41 50 (Customer Termination Rights) except Clause 41.7 50.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Lease Agreement Schedule 4 (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 57 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.4 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 45 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 41. (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 48. (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 36. (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier Service Provider shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier Service Provider acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the SupplierService Provider’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the SupplierService Provider’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier Service Provider by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier Service Provider waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 45 (Customer Termination Rights) except Clause 41.7 45.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 53 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 I (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer Contracting Authority such Delay Payments (calculated as set out by the Customer Contracting Authority in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer Contracting Authority as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's Contracting Authority exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer Contracting Authority is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Contracting Authority Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Contracting Authority Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer Contracting Authority in the Implementation Plan); no payment or concession to the Supplier by the Customer Contracting Authority or other act or omission of the Customer Contracting Authority shall in any way affect the rights of the Customer Contracting Authority to recover the Delay Payments or be deemed to be a waiver of the right of the Customer Contracting Authority to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s Contracting Authority rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: : (a) the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s Suppliers failure to Achieve the corresponding Milestone; ; (b) Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s Suppliers failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or or (ii) the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Contract Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; (c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); ; (d) no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and and (e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 42. (Customer Termination Rights) except Clause 41.7 42.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 49. (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 37. (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: : (a) the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; ; (b) Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or or (ii) the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; (c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); ; (d) no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and and (e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: : (a) the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; ; (b) Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 42 (Customer Termination Rights) except Clause 41.7 42.7 (Termination Without Cause); or or (ii) the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Contract Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; (c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); ; (d) no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 49 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and and (e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 37 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract Lease Agreement pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Lease Agreement Schedule 4 (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.4 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 41. (Customer Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or the delay exceeds the number period of [one hundred (100)] days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 48. (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 36. (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 50 (Customer Termination Rights) except Clause 41.7 50.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 57 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 45 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s Suppliers failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s Suppliers failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 51 (Customer Termination Rights) except Clause 41.7 51.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Contract Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 58 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 46 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 43 (Customer Termination Rights) except Clause 41.7 43.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 50 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 7.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 38 (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer Contracting Authority such Delay Payments (calculated as set out by the Customer Contracting Authority in the Implementation Plan) and the following provisions shall apply: : (a) the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer Contracting Authority as a result of the Supplier’s failure to Achieve the corresponding Milestone; ; (b) Delay Payments shall be the CustomerContracting Authority's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer Contracting Authority is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Contracting Authority Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or or (ii) the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; (c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer Contracting Authority in the Implementation Plan); ; (d) no payment or concession to the Supplier by the Customer Contracting Authority or other act or omission of the Customer Contracting Authority shall in any way affect the rights of the Customer Contracting Authority to recover the Delay Payments or be deemed to be a waiver of the right of the Customer Contracting Authority to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the CustomerContracting Authority’s rights to claim Delay Payments; and and (e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 41.3 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 47 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 42 (Customer Termination Rights) except Clause 41.7 42.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 49 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 7.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 37 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s Suppliers failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s Suppliers failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Key Milestone has not been achieved Achieved by the its relevant Milestone Date, the Supplier provisions of Paragraph 1 of Part C of Schedule 7.1 (Charges and Invoicing) shall pay apply in relation to the Customer such payment of Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Payments. Delay Payments shall be the CustomerBuyer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Key Milestone by its Milestone Date except where: the Customer Buyer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights33.1(b) except Clause 41.7 (Termination Without Causeby the Buyer); or the delay Delay exceeds the number Delay Deduction Period. REMEDIAL ADVISER If: any of days the Intervention Trigger Events occur; or the Buyer reasonably believes that any of the Intervention Trigger Events are likely to occur, (each an “Intervention Cause”), the Buyer may give notice to the Supplier (an “Delay Period LimitIntervention Notice”) specified giving reasonable details of the Intervention Cause and requiring: a meeting between the Buyer Representative and the Supplier Representative to discuss the Intervention Cause; and/or the appointment as soon as practicable by the Supplier of a Remedial Adviser, as further described in Call Off Schedule 4 this Clause 29. For the avoidance of doubt, if the Intervention Cause is also a Supplier Termination Event, the Buyer has no obligation to exercise its rights under this Clause 29.1 prior to or instead of exercising its right to terminate this Contract. If the Buyer gives notice that it requires the appointment of a Remedial Adviser: the Remedial Adviser shall be: a person selected by the Supplier and approved by the Buyer; or if none of the persons selected by the Supplier have been approved by the Buyer (Implementation Planor no person has been selected by the Supplier) within 10 Working Days following the date on which the Intervention Notice is given, a person identified by the Buyer; the terms of engagement and start date agreed with the Remedial Adviser must be approved by the Buyer; and any right of the Buyer to terminate this Contract pursuant to Clause 33.1(b) (Termination by the Buyer) for the purposes occurrence of that Intervention Cause shall be suspended for 60 Working Days from (and including) the date of the Intervention Notice (or such other period as may be agreed between the Parties)(the “Intervention Period”). The Remedial Adviser’s overall objective shall be to mitigate the effects of, and (to the extent capable of being remedied) to remedy, the Intervention Cause and to avoid the occurrence of similar circumstances in the future. In furtherance of this subobjective (but without diminishing the Supplier’s responsibilities under this Contract), the Parties agree that the Remedial Adviser may undertake any one or more of the following actions: observe the conduct of and work alongside the Supplier Personnel to the extent that the Remedial Adviser considers reasonable and proportionate having regard to the Intervention Cause; gather any information the Remedial Adviser considers relevant in the furtherance of its objective; write reports and provide information to the Buyer in connection with the steps being taken by the Supplier to remedy the Intervention Cause; make recommendations to the Buyer and/or the Supplier as to how the Intervention Cause might be mitigated or avoided in the future; and/or take any other steps that the Buyer and/or the Remedial Adviser reasonably considers necessary or expedient in order to mitigate or rectify the Intervention Cause. The Supplier shall: work alongside, provide information to, co-Clauseoperate in good faith with and adopt any reasonable methodology in providing the Services recommended by the Remedial Adviser; ensure that the Remedial Adviser has all the access it may require in order to carry out its objective, commencing on including access to the Assets; submit to such monitoring as the Buyer and/or the Remedial Adviser considers reasonable and proportionate in respect of the Intervention Cause; implement any reasonable recommendations made by the Remedial Adviser that have been approved by the Buyer within the timescales given by the Remedial Adviser; and not terminate the appointment of the Remedial Adviser prior to the end of the Intervention Period without the prior consent of the Buyer (such consent not to be unreasonably withheld). The Supplier shall be responsible for: the costs of appointing, and the fees charged by, the Remedial Adviser; and its own costs in connection with any action required by the Buyer and/or the Remedial Adviser pursuant to this Clause 29. If: the Supplier: fails to perform any of the steps required by the Buyer in an Intervention Notice; and/or is in Default of any of its obligations under Clause 29.4; and/or the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone Intervention Trigger Event is Achieved (unless otherwise specified not rectified by the Customer in end of the Implementation PlanIntervention Period, (each a “Remedial Adviser Failure”); no payment or concession , the Buyer shall be entitled to the Supplier terminate this Contract pursuant to Clause 33.1(b) (Termination by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (LiabilityBuyer).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 52 (Customer Termination Rights) except Clause 41.7 52.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 59 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 47 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 40 (Customer Termination Rights) except Clause 41.7 40.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 47 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 35 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 53 (Customer Termination Rights) except Clause 41.7 53.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 60 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 7.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 48 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 54 (Customer Termination Rights) except Clause 41.7 54.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 61 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 49 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 44 (Customer Termination Rights) except Clause 41.7 44.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 51 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 39 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation theProject Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Project Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 42 (Customer Termination Rights) except Clause 41.7 42.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Project Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Project Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 49 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 37 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer Contracting Authority such Delay Payments (calculated as set out by the Customer Contracting Authority in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer Contracting Authority as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the CustomerContracting Authority's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer Contracting Authority is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Contracting Authority Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer Contracting Authority in the Implementation Plan); no payment or concession to the Supplier by the Customer Contracting Authority or other act or omission of the Customer Contracting Authority shall in any way affect the rights of the Customer Contracting Authority to recover the Delay Payments or be deemed to be a waiver of the right of the Customer Contracting Authority to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the CustomerContracting Authority’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 46. (Customer Termination Rights) except Clause 41.7 46.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 53. (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 11.1.9 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 41. (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s Suppliers failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s Suppliers failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Contract Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 56 (Customer Termination Rights) except Clause 41.7 56.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 63 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 51 (Liability).

Delay Payments. 6.1.9 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: : (a) the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; ; (b) Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or or (ii) the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; (c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); ; (d) no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and and (e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: : (a) the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; ; (b) Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or or (ii) the delay exceeds the number of days (the “Delay Period Limit”) specified in Part A of Call Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; (c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); ; (d) no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and and (e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s Suppliers failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s Suppliers failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 (Customer Termination Rights) except Clause 41.7 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Contract Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability). 7. GOODS AND/ OR SERVICES 7.1 Provision of the Goods and/or Services 7.1.1 The Supplier acknowledges and agrees that the Customer relies on the skill and judgment of the Supplier in the provision of the Goods and/or Services and the performance of its obligations under this Contract. 7.1.2 The Supplier shall ensure that the Goods and/or Services: comply in all respects with the description of the Goods and/or Services in Contract Schedule 2 (Goods and/or Services) or elsewhere in this Contract; and are supplied in accordance with the provisions of this Contract Tender. 7.1.3 The Supplier shall perform its obligations under this Contract in accordance with: (a) all applicable Law; Good Industry Practice; the Standards; the Security Policy; the ICT Policy (if so required by the Customer); and the Suppliers own established procedures and practices to the extent the same do not conflict with the requirements of Clauses 7.1.3(a) to 7.1.3(e). 7.1.4 The Supplier shall: at all times allocate sufficient resources with the appropriate technical expertise to supply the Deliverables and to provide the Goods and/or Services in accordance with this Contract; subject to Clause 22.1 (Variation Procedure), obtain, and maintain throughout the duration of this Contract, all the consents, approvals, licences and permissions (statutory, regulatory contractual or otherwise) it may require and which are necessary for the provision of the Goods and/or Services; ensure that any goods and/or services recommended or otherwise specified by the Supplier for use by the Customer in conjunction with the Deliverables and/or the Goods and/or Services shall enable the Deliverables and/or the Goods and/or the Services to meet the requirements of the Customer; ensure that the Supplier Assets will be free of all encumbrances (except as agreed in writing with the Customer); ensure that the Goods and/or Services are fully compatible with any Customer Property or Customer Assets described in Contract Schedule 4 (Implementation Plan) (or elsewhere in this Contract) or otherwise used by the Supplier in connection with this Contract; minimise any disruption to the Sites and/or the Customer's operations when providing the Goods and/or Services; ensure that any Documentation and training provided by the Supplier to the Customer are comprehensive, accurate and prepared in accordance with Good Industry Practice; co-operate with the Other Suppliers and provide reasonable information (including any Documentation), advice and assistance in connection with the Goods and/or Services to any Other Supplier and, on the Contract Expiry Date for any reason, to enable the timely transition of the supply of the Goods and/or Services (or any of them) to the Customer and/or to any Replacement Supplier; assign to the Customer, or if it is unable to do so, shall (to the extent it is legally able to do so) hold on trust for the sole benefit of the Customer, all warranties and indemnities provided by third parties or any Sub-Contractor in respect of any Deliverables and/or the Goods and/or Services. Where any such warranties are held on trust, the Supplier shall enforce such warranties in accordance with any reasonable directions that the Customer may notify from time to time to the Supplier; provide the Customer with such assistance as the Customer may reasonably require during the Contract Period in respect of the supply of the Goods and/or Services; deliver the Goods and/or Services in a proportionate and efficient manner; ensure that neither it, nor any of its Affiliates, embarrasses the Customer or otherwise brings the Customer into disrepute by engaging in any act or omission which is reasonably likely to diminish the trust that the public places in the Customer, regardless of whether or not such act or omission is related to the Suppliers obligations under this Contract; and gather, collate and provide such information and co-operation as the Customer may reasonably request for the purposes of ascertaining the Suppliers compliance with its obligations under this Contract. 7.1.5 An obligation on the Supplier to do, or to refrain from doing, any act or thing shall include an obligation upon the Supplier to procure that all Sub-Contractors and Supplier Personnel also do, or refrain from doing, such act or thing.

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 44 (Customer Termination Rights) except Clause 41.7 44.8 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 51 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 39 (Liability).

Delay Payments. 6.4.1 If Delay Payments have been included in the Implementation Plan and (if any) then, if a Milestone has not been achieved by the relevant Milestone Date, Date the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the : a) The Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; ; b) Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: : (i) the Customer is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 31 (Customer Termination Rights) except Clause 41.7 31.6 (Termination Without Cause); or or (ii) the delay exceeds the number period of [one hundred (100)] days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; ; c) the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); ; d) no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 38 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and and e) the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 (Liability)26.

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer such Delay Payments (calculated as set out by the Customer in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the Customer's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer is otherwise entitled to or does terminate this Call Call-Off Contract pursuant to Clause 41 3851 (Customer Termination Rights) except Clause 41.7 38.754.1.2 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Part A of Call-Off Schedule 4 4: (Implementation Plan, Customer Responsibilities and Key Personnel) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer in the Implementation Plan); no payment or concession to the Supplier by the Customer or other act or omission of the Customer shall in any way affect the rights of the Customer to recover the Delay Payments or be deemed to be a waiver of the right of the Customer to recover any such damages unless such waiver complies with Clause 48 45 (Waiver and Cumulative Remedies) and refers specifically to a waiver of the Customer’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 6.1.11 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 33 (Liability).

Delay Payments. If Delay Payments have been included in the Implementation Plan and a Milestone has not been achieved by the relevant Milestone Date, the Supplier shall pay to the Customer Contracting Authority such Delay Payments (calculated as set out by the Customer Contracting Authority in the Implementation Plan) and the following provisions shall apply: the Supplier acknowledges and agrees that any Delay Payment is a price adjustment and not an estimate of the Loss that may be suffered by the Customer Contracting Authority as a result of the Supplier’s failure to Achieve the corresponding Milestone; Delay Payments shall be the CustomerContracting Authority's exclusive financial remedy for the Supplier’s failure to Achieve a corresponding Milestone by its Milestone Date except where: the Customer Contracting Authority is otherwise entitled to or does terminate this Call Off Contract pursuant to Clause 41 41. (Customer Contracting Authority Termination Rights) except Clause 41.7 41.6 (Termination Without Cause); or the delay exceeds the number of days (the “Delay Period Limit”) specified in Call Off Schedule 4 (Implementation Plan) for the purposes of this sub-Clause, commencing on the relevant Milestone Date; the Delay Payments will accrue on a daily basis from the relevant Milestone Date and shall continue to accrue until the date when the Milestone is Achieved (unless otherwise specified by the Customer Contracting Authority in the Implementation Plan); no payment or concession to the Supplier by the Customer Contracting Authority or other act or omission of the Customer Contracting Authority shall in any way affect the rights of the Customer Contracting Authority to recover the Delay Payments or be deemed to be a waiver of the right of the Customer Contracting Authority to recover any such damages unless such waiver complies with Clause 48 48. (Waiver and Cumulative Remedies) and refers specifically to a waiver of the CustomerContracting Authority’s rights to claim Delay Payments; and the Supplier waives absolutely any entitlement to challenge the enforceability in whole or in part of this Clause 6.4.1 and Delay Payments shall not be subject to or count towards any limitation on liability set out in Clause 36 36. (Liability).