SUBCONTRACTS - ASSIGNMENT Contractor shall not subcontract or assign this Agreement, or any part thereof, or interest therein, directly or indirectly, voluntarily or involuntarily, to any person without obtaining the prior written consent by County. Contractor remains legally responsible for the performance of all contract terms including work performed by third parties under subcontracts. Any subcontracting will be subject to all applicable provisions of this Agreement. Contractor shall be held responsible by County for the performance of any subcontractor whether approved by County or not. Contractor hereby assigns to the County all rights, title, and interest in and to all causes of action it may have under Section 4 of the Xxxxxxx Act (15 U.S.C. Sec. 15) or under the Xxxxxxxxxx Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from the purchase if goods, materials, or services by the Contractor for sale to the County pursuant to this Agreement.
Subcontracts and Staff 4.1 The Contractor is fully responsible for satisfactory completion of all work on this Contract. The Contractor shall ensure and provide assurances to the Department or Customer upon request, that any subcontractor(s) or Staff provided under this Contract has the necessary qualifications and abilities to perform in accordance with the terms and conditions of this Contract. The Contractor must provide the Customer with the names of Staff considered for work on a purchase order issued under this Contract. The Customer shall retain the right to reject any Staff whose qualifications or performance, in the Customer’s exclusive judgment, is insufficient.
Compliance with Laws and Orders Buyer is not in violation of or in default under any Law or order applicable to Buyer or its Assets the effect of which, in the aggregate, would reasonably be expected to hinder, prevent or delay Buyer from performing its obligations hereunder.
