Constructability and Design Review; Value Engineering Sample Clauses

Constructability and Design Review; Value Engineering. The District reserves the right to conduct, or cause to be conducted, constructability reviews and/or value engineering of the Design Development Documents. If the District elects to conduct either constructability reviews or value engineering, the District shall notify the Architect of the same and the Architect shall submit Design Development Documents to the District for such constructability reviews and/or value engineering. The District and Architect will confer and consult with each other to arrive at mutual understandings and agreements as to which of the constructability review and/or value engineering comments are to be incorporated into the Design Development Documents. The Design Development Documents shall incorporate mutually agreed upon comments and the Architect shall submit Design Development Documents to the District for approval. Architect shall revise Design Development Documents as necessary to obtain the District’s reasonable approval thereof.
Sample 1See All (4)
AutoNDA by SimpleDocs
Constructability and Design Review; Value Engineering. Upon completion of Preliminary Design Development Documents, or such earlier intervals as may be mutually agreed between the District and Architect, the Architect shall submit Preliminary Design Development Documents to the District for review and comment, including constructability reviews and/or value engineering comments.
Sample 1Sample 2
Constructability and Design Review; Value Engineering. The District reserves the right to conduct or cause to be conducted, constructability reviews and/or value engineering of the Schematic Design Documents. If the District elects to conduct either constructability reviews or value engineering, the District shall notify the Architect of the same and thereupon at Architect’s completion of Schematic Design Documents, the Architect shall submit Schematic Design Documents to the District for such constructability reviews and/or value engineering. The District and Architect will confer and consult with each other to arrive at mutual understandings and agreements as to which of the constructability review and/or value engineering comments are to be incorporated into the Schematic Design Documents. The Schematic Design Documents shall incorporate mutually agreed upon comments and the Architect shall submit revised Schematic Design Documents to the District for approval. Architect shall revise Schematic Design Documents as necessary to obtain the District’s reasonable approval thereof.
Sample 1
Constructability and Design Review; Value Engineering. If, during development of construction documents, it is determined that the project is exceeding project construction budget, the District reserves the right to conduct a constructability review and/or value engineering of the Construction Documents. If the District elects to conduct either a constructability review or value engineering, the District shall notify the Architect of the same and thereupon at Architect’s completion of the Construction Documents for the Project to seventy five percent (75%) and one hundred percent (100%), the Construction Documents shall be submitted to the District for constructability and design review and value engineering comments. The District and Architect will confer and consult with the other to arrive at mutual understandings and agreements as to which of the constructability, design and value engineering comments are to be incorporated into the Construction Documents. Architect’s Construction Documents for the Project shall incorporate such mutually agreed upon comments and the Architect shall submit revised Construction Documents for the Project to the District for review and approval. Architect shall revise Construction Documents as necessary to obtain the District’s reasonable approval thereof.
Sample 1
Constructability and Design Review; Value Engineering. The District reserves the right to conduct, or cause to be conducted, Constructability reviews and/or Value Engineering of the Construction Documents. If the District elects to conduct either Constructability reviews or value engineering, the District shall notify the Architect of the same and thereupon at Architect’s preparation of Construction Documents for the Project at the fifty percent (50%), ninety percent (90%) and Final completion, the Architect shall submit Construction Documents to the District for such constructability reviews and/or value engineering. The District and Architect will confer and consult with each other to arrive at mutual understandings and agreements as to which of the constructability review and/or value engineering comments are to be incorporated into the Construction Documents. The Construction Documents shall incorporate mutually agreed upon comments and the Architect shall submit revised Construction Documents to the District for approval Architect shall revise Construction Documents as necessary to obtain the District’s reasonable approval thereof. Should the District direct the Architect to incorporate constructability review and/or value engineering comments that would require design effort beyond the original scope, the Architect may be entitled to compensation for extra services, in accordance with Section 3.11.2.
Sample 1

Related to Constructability and Design Review; Value Engineering

  • Value Engineering The Supplier may prepare, at its own cost, a value engineering proposal at any time during the performance of the contract. The value engineering proposal shall, at a minimum, include the following;

  • Constructability Review Prepare detailed interdisciplinary constructability review within Fourteen (14) days of receipt of the plans from the District that:

  • Geotechnical Engineer « »« » « » « » « » « »

  • Engineering Forest Service completed survey and design for Specified Roads prior to timber sale advertisement, unless otherwise shown in A8 or Purchaser survey and design are specified in A7. On those roads for which Forest Service completes the design during the contract, the design quantities shall be used as the basis for revising estimated costs stated in the Schedule of Items and adjusting Timber Sale Account. Forest Service engineering shall be completed according to the schedule in A8. Should Forest Service be unable to perform the designated survey and design by the completion date or other agreed to time, upon written agreement, Purchaser shall assume responsibility for such work. In such event, Contracting Officer shall revise:

  • Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.

  • Reverse Engineering The Customer must not reverse assemble or reverse compile or directly or indirectly allow or cause a third party to reverse assemble or reverse compile the whole or any part of the software or any products supplied as a part of the Licensed System.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Information Systems Acquisition Development and Maintenance Security of System Files. To protect City Information Processing Systems and system files containing information, Service Provider will ensure that access to source code is restricted to authorized users whose specific job function necessitates such access.

  • Project Implementation 2. The Borrower shall:

Time is Money Join Law Insider Premium to draft better contracts faster.