Common use of Confidentiality of Contractor Information Clause in Contracts

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract Master Agreement and any SOW Agreement entered into hereunder and any and all Contractor information obtained by the State in connection with this Contract Master Agreement and any SOW Agreement entered into hereunder are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this ContractMaster Agreement and any SOW Agreement entered into hereunder; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this ContractMaster Agreement and any SOW Agreement entered into hereunder; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract Master Agreement and any SOW Agreement entered into hereunder to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with ContractorXxxxxxxxxx’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with ContractorXxxxxxxxxx’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with the performance of this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with ContractorXxxxxxxxxx’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State Purchasing Entities in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State Purchasing Entity will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State Purchasing Entity shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the StatePurchasing Entity’s receipt of any such request. Contractor agrees that it will not make any claim against the State Purchasing Entity if the State Purchasing Entity makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State Purchasing Entities for any costs or expenses incurred by the StatePurchasing Entity, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State Purchasing Entity improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State Purchasing Entity agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, STATE OF VERMONT Contract #46012 Page 18 of 24 mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such requestequest. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with ith 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of c competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. imprope The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three (3) business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, reasonable attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services Services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, reasonable attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services Services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the trademarks, trade names, logos and other State identifiers, Internet uniform resource locators, and used by Contractor hereunder, and all other rights, tangible or intangible; and (ii) all State course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.;

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State Purchasing Entity in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State Purchasing Entity will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. For clarity, any proprietary software licensed by Contractor is a trade secret. The State Purchasing Entity shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the StatePurchasing Entity’s receipt of any such request. Contractor agrees that it will not make any claim against the State Purchasing Entity if the State Purchasing Entity makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State Purchasing Entity for any costs or expenses incurred by the StatePurchasing Entity, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State Purchasing Entity improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State Purchasing Entity agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s 's receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ ' fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s 's attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s 's information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s 's information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s 's determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.

Confidentiality of Contractor Information. The Notwithstanding anything to the contrary in a Contractor Document, the Contractor acknowledges and agrees that this Contract and any and all Contractor information obtained by the State in connection with this Contract are subject to the State of Vermont Access to Public Records Act, 1 V.S.A. § 315 et seq. The State will not disclose information for which a reasonable claim of exemption can be made pursuant to 1 V.S.A. § 317(c), including, but not limited to, trade secrets, proprietary information or financial information, including any formulae, plan, pattern, process, tool, mechanism, compound, procedure, production data, or compilation of information which is not patented, which is known only to the Contractor, and which gives the Contractor an opportunity to obtain business advantage over competitors who do not know it or use it. The State shall immediately notify Contractor of any request made under the Access to Public Records Act, or any request or demand by any court, governmental agency or other person asserting a demand or request for Contractor information. Contractor may, in its discretion, seek an appropriate protective order, or otherwise defend any right it may have to maintain the confidentiality of such information under applicable State law within three business days of the State’s receipt of any such request. Contractor agrees that it will not make any claim against the State if the State makes available to the public any information in accordance with the Access to Public Records Act or in response to a binding order from a court or governmental body or agency compelling its production. Contractor shall indemnify the State for any costs or expenses incurred by the State, including, but not limited to, attorneys’ fees awarded in accordance with 1 V.S.A. § 320, in connection with any action brought in connection with Contractor’s attempts to prevent or unreasonably delay public disclosure of Contractor’s information if a final decision of a court of competent jurisdiction determines that the State improperly withheld such information and that the improper withholding was based on Contractor’s attempts to prevent public disclosure of Contractor’s information. The State agrees that (a) it will use the Contractor information only as may be necessary in the course of performing duties, receiving services or exercising rights under this Contract; (b) it will provide at a minimum the same care to avoid disclosure or unauthorized use of Contractor information as it provides to protect its own similar confidential and proprietary information; (c) except as required by the Access to Records Act, it will not disclose such information orally or in writing to any third party unless that third party is subject to a written confidentiality agreement that contains restrictions and safeguards at least as restrictive as those contained in this Contract; (d) it will take all reasonable precautions to protect the Contractor’s information; and (e) it will not otherwise appropriate such information to its own use or to the use of any other person or entity. Contractor may affix an appropriate legend to Contractor information that is provided under this Contract to reflect the Contractor’s determination that any such information is a trade secret, proprietary information or financial information at time of delivery or disclosure.