Changes to Contract Time Sample Clauses

The "Changes to Contract Time" clause defines the process by which the agreed-upon timeline for completing contractual obligations can be modified. Typically, this clause outlines the circumstances under which a party may request an extension or reduction of the contract duration, such as delays caused by unforeseen events, changes in project scope, or force majeure. It usually requires formal notice and supporting documentation to justify any adjustment. The core function of this clause is to provide a structured mechanism for managing and documenting changes to the project schedule, thereby reducing disputes and ensuring both parties have a clear understanding of their time-related obligations.
Changes to Contract Time. The Contract Time may only be changed pursuant to a Change Order or a written amendment to the Contract Documents. Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the party making the claim to the other party. Notice of the extent of the claim with supporting data shall be delivered within fifteen (15) days from detection or beginning of such occurrence and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled to because of the occurrence of said event. The Contract time will be extended in an amount equal to time lost due to delays beyond the control of Contractor. Such delays shall include, but not be limited to, acts or neglect by Owner or others performing additional Work; or to fires, floods, epidemics, abnormal weather conditions or acts of God. Failure to deliver a written notice of claim within the requisite 15-day period shall constitute a waiver of the right to pursue said claim.
View SourceView Similar (2)
Changes to Contract Time. The Contract Time may only be changed pursuant to a Change Order or a written amendment to the Contract Documents. Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the party making the claim to the other party. Notice of the extent of the claim with supporting data
View Source
Changes to Contract Time. The Contract Time may only be changed pursuant to a Change Order or a written amendment to the Contract Documents. Any claim for an
View Source
Changes to Contract Time 
View SourceView Similar (5)

Related to Changes to Contract Time

  • CHANGES TO CONTRACT No amendment to the provisions of this Contract, other than a change to the Services in accordance with the procedure and provisions set out at Clause 29, shall be effective unless made in accordance with the procedures set out in this Clause 28 (“Change Control Procedure”). Subject to Clause 29.1, either Party may request a contract change by completing and sending a draft Contract Change Note in the form set out at Schedule 1 (“the Contract Change Note”) to the other Party giving sufficient information to enable the other Party to assess the extent of the change and any additional cost that may be incurred. The Party requesting the contract change shall bear the costs of preparation of the Contract Change Note. The Party receiving the request for a contract change shall respond to the request within five (5) Working Days (or such other period as may be agreed by the Parties) and if applicable, the Parties shall enter into discussions to discuss the proposed change and neither Party shall unreasonably withhold or delay consent to the other Party’s proposed changes to this Contract. Where the Customer has proposed a contract change and the Supplier is unable to provide the change, including where the Parties are unable to agree a change to the Contract Charges, the Customer may terminate this Contract with immediate effect. Following execution of the final Contract Change Note, the Supplier shall implement such change and be bound by the same provisions so far as is applicable, as though such change was stated in this Contract.

  • Notice to Contractor The Contractor is required to submit Certificates of Insurance acceptable to the State as evidence of insurance coverage requirements prior to commencing work under this Contract. Contractor shall not commence work under the contract until they have obtained all the insurance described below and the State has approved such insurance. Contractor shall maintain such insurance in force and effect throughout the term of this Contract, unless otherwise specified in this Contract The failure of the Contractor to provide a Certificate of Insurance, for the policies required under this Contract or renewals thereof, or failure of the insurance company to notify the State of the cancellation of policies required under this Contract shall not constitute a waiver by the State to the Contractor to provide such insurance. The State reserves the right to immediately terminate this Contract if the Contractor is not in compliance with the insurance requirements and retains all rights to pursue any legal remedies against the Contractor. All insurance policies must be open to inspection by the State, and copies of policies must be submitted to the State’s Authorized Representative upon written request.

  • Payment to Contractor The TOWN agrees to pay at the rates specified for SERVICES satisfactorily performed in accordance with this contract. Unless otherwise specified, the CONTRACTOR shall submit an itemized invoice to the TOWN by the end of the month during which SERVICES are performed. Payment will be processed promptly upon receipt and approval by the TOWN of the invoice.

  • Amendments to Contract a. Except as provided in condition 31 all amendments to this Contract shall be serially numbered, in writing, issued only by the Authority’s Representative (Commercial), and agreed by both Parties. b. Where the Authority or the Contractor wishes to introduce a change which is not minor or which is likely to involve a change to the Contract Price, the provisions of Schedule 4 (Contract Change Control Procedure) shall apply. The Contractor shall not carry out any work until any necessary change to the Contract Price has been agreed and a written amendment in accordance with clause 6.a above has been issued.

  • Parties to Contract Any contract of the character described in Sections 4.1 and 4.2 of this Article IV or in Article VII hereof may be entered into with any Person, although one or more of the Trustees, officers or employees of the Trust may be an officer, director, trustee, shareholder, or member of such other party to the contract, and no such contract shall be invalidated or rendered voidable by reason of the existence of any such relationship, nor shall any Person holding such relationship be liable merely by reason of such relationship for any loss or expense to the Trust under or by reason of said contract or accountable for any profit realized directly or indirectly therefrom, provided that the contract when entered into was reasonable and fair and not inconsistent with the provisions of this Article IV or the By-Laws. The same Person may be the other party to contracts entered into pursuant to Sections 4.1 and 4.2 above or Article VII, and any individual may be financially interested or otherwise affiliated with Persons who are parties to any or all of the contracts mentioned in this Section 4.3.