Change of Scope. 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the Scope of the Project as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 16.3.
Change of Scope. (i) The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/ alterations to the Works (“Change of Scope”) within a period of six months counted from the Appointed Date. Upon the Authority making its intention known to the Contractor for the specific Change of Scope, be it positive or negative, the Contractor shall submit his proposal for the said Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
Change of Scope. 13.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/alterations to the Works (“Change of Scope”) before the issue of the Completion Certificate either by giving an instruction or by requesting the Contractor to submit a proposal for Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
Change of Scope. 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, during the period of 10 (ten) years post COD of Bus Terminal, require the Concessionaire to carry out any additional works ("Additional Works"), which are related and are necessary to the Bus Terminal and services which are not included in the Scope of the Project as contemplated by this Agreement (the "Change of Scope"). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause
Change of Scope. (a) The Concessioning Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the scope of the Project as contemplated by this Agreement (“Change of Scope”). Provided no such Change of Scope shall be made in the Construction Phase if it is in the reasonable judgment of the parties hereto likely to delay the completion of the Project such that the Project cannot be completed on the Scheduled Project Completion Date. Provided further, the cost of implementing a single Change of Scope shall not exceed a sum corresponding to [5% (five percent)] of the Estimated Project Cost and during the Concession Period the cumulative cost of implementing orders pertaining to Change of Scope shall not exceed a sum corresponding to [20% (twenty percent)] of the Estimated Project Cost ;
Change of Scope. 10.10.1. The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the scope of the Project as contemplated by this Agreement (“Change of Scope”). Provided no such Change of Scope shall be made in the Construction Period, if in the reasonable judgment of the Parties, it is likely to lead to delay in Project Completion or during the Operation Period, if in the reasonable judgement of the Parties, it is likely to have Material Adverse Effect on the provision of Services by the Concessionaire. The costs for carrying out required additional work as contemplated in Change of Scope shall be borne by the Authority.
Change of Scope. ARTICLE 16
Change of Scope. 13.1.1 The Employer may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/alterations to the Works (“Change of Scope”) before the issue of the Completion Certificate either by giving an instruction or by requesting the Contractor to submit a proposal for Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
Change of Scope. 15.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of upgraded technology or additional works and services in the Buses or at the Maintenance Depots, which are not included in the Scope of the Agreement as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 15 and the costs thereof shall be expended by the Operator and reimbursed to it by the Authority in accordance with this Article 15.
Change of Scope. The scope of Services set forth in any Proposal is based on facts known at the time of execution of the Proposal, including, if applicable, Client Data (defined below). As the Project progresses, facts discovered, including, but not limited to, site conditions or the existence of differing subsurface or physical conditions, may indicate that the scope, pricing, or other terms must be redefined, and the parties shall reasonably cooperate to equitably adjust the scope, pricing, or terms of this Agreement accordingly.
