Commitment Charge; Credit; Maturity Premium (a) The Borrower shall pay a commitment charge on the unwithdrawn amount of the Loan at the rate and on the terms specified in the Loan Agreement.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
MAINTENANCE OF THE SAID BUILDING / APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of the allottees. The cost of such maintenance has been included in the Total Price of the [Apartment/Plot]. [Insert any other clauses in relation to maintenance of project, infrastructure and equipment]
CREDIT AND COLLATERAL REQUIREMENTS The applicable credit and collateral requirements are specified on the Cover Sheet.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
MAINTENANCE OF THE BUILDING /APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the Association upon the issuance of the completion certificate of the Project. The cost of such maintenance has been included in the Total Extras and Deposits as mentioned in clause 1.2.
Application of Miscellaneous Proceeds upon Condemnation, Destruction, or Loss in Value of the Property In the event of a total taking, destruction, or loss in value of the Property, all of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument, whether or not then due, with the excess, if any, paid to Borrower. In the event of a partial taking, destruction, or loss in value of the Property (each, a “Partial Devaluation”) where the fair market value of the Property immediately before the Partial Devaluation is equal to or greater than the amount of the sums secured by this Security Instrument immediately before the Partial Devaluation, a percentage of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument unless Borrower and Lender otherwise agree in writing. The amount of the Miscellaneous Proceeds that will be so applied is determined by multiplying the total amount of the Miscellaneous Proceeds by a percentage calculated by taking (i) the total amount of the sums secured immediately before the Partial Devaluation, and dividing it by (ii) the fair market value of the Property immediately before the Partial Devaluation. Any balance of the Miscellaneous Proceeds will be paid to Borrower. In the event of a Partial Devaluation where the fair market value of the Property immediately before the Partial Devaluation is less than the amount of the sums secured immediately before the Partial Devaluation, all of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument, whether or not the sums are then due, unless Borrower and Lender otherwise agree in writing.
Access to Property, Property’s Management, Property Lender, and Property Tenants Potential Investor agrees to not seek to gain access to any non-public areas of the Property or communicate with Property’s management employees, the holder of any financing encumbering the Property, the Property’s tenants, and the Owner’s partners in the ownership of the Property, without the prior consent of Owner or HFF, which consent may be withheld in the Owner’s sole discretion.
ADDITIONAL SPECIAL CONTRACT CONDITIONS A. Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
