Extension of Concession Period Subject to the provisions of Clause 35.6, in the event that a material default or breach of this Agreement set forth in Clause 35.2 causes delay in achieving COD or leads to suspension of or reduction in collection of Fee, as the case may be, the Authority shall, in addition to payment of compensation under Clause 35.2, extend the Concession Period, such extension being equal in duration to the period by which COD was delayed or the collection of Fee remained suspended on account thereof, as the case may be.
RENTAL APPLICATION The Tenant acknowledges that the Landlord has relied upon the rental application, a copy of which is attached hereto, as an inducement for entering into this agreement, and the Tenant warrants to the Landlord that the facts stated in the application are true to the best of Tenant’s knowledge. If any facts stated in the rental application prove to be untrue, the Landlord shall have the right to terminate the residency immediately and to collect from the Tenant any damages resulting therefrom.
Application of Collective Agreement (a) The operation of this Article shall not be construed as a violation of the posting and/or scheduling provisions of Articles 7: Hours of Work and Scheduling Provisions and 14: Promotions, Transfers & Vacancies.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Utilisations permises de la licence et restrictions A. Licence de logiciel Apple préinstallé ou copie unique. Sous réserve des conditions générales de cette Licence, et à moins que vous ayez acquis le logiciel Apple dans le Mac App Store, par le biais d’un téléchargement automatique ou dans le cadre d’une licence ou maintenance de volume ou tout autre accord écrit passé avec Apple, une licence de non-exclusivité limitée vous est accordée pour installer, utiliser et exécuter un (1) seul exemplaire du logiciel Apple sur un seul ordinateur Apple à la fois. Par exemple, les termes de la présente Licence à copie unique s’appliquent à vous si vous avez acquis le logiciel Apple préinstallé sur un matériel de marque Apple.
Volume or Maintenance License If you obtained the Apple Software under a volume or maintenance license program with Apple, the terms of your volume or maintenance license will determine the number of copies of the Apple Software you are permitted to download, install, use and run on Apple-branded computers you own or control. Except as agreed to in writing by Apple, all other terms and conditions of this License shall apply to your use of the Apple Software obtained under a volume or maintenance license.
Withdrawal of Loan Proceeds 1. Except as ADB may otherwise agree, the following provisions of this Schedule shall apply to the withdrawal of Loan proceeds from the Loan Account.
SCOPE OF CONCESSION A. Concessionaire shall be granted, under a Concession Agreement (“Agreement”), the non- exclusive, revocable right to dispense food, non-alcoholic beverages, and novelties (hereinafter referred to as the “Concession Operation”) at Belleplain State Forest. Concessionaire’s operation shall be limited to the structure(s) or area(s) provided by Department for concession purposes and specifically designated in Exhibit A (hereinafter referred to as the “Concession Premises”).
MAINTENANCE OF CONCESSION PREMISES A. Concessionaire shall preserve and maintain the Concession Premises in good and clean condition, reasonable wear and tear excepted. Concessionaire is solely responsible for the maintenance and cleanliness of the Concession Premises.
AUDIT OF LICENSED PRODUCT USAGE Contractor shall have the right to periodically audit, no more than annually, at Contractor’s expense, use of licensed Product at any site where a copy of the Product resides provided that: (i) Contractor gives Licensee(s) at least thirty (30) days advance written notice, (ii) such audit is conducted during such party’s normal business hours, (iii) the audit is conducted by an independent auditor chosen on mutual agreement of the parties. Contractor shall recommend a minimum of three (3) auditing/accounting firms from which the Licensee will select one (1). In no case shall the Business Software Alliance (BSA), Software Publishers Association (SPA), Software and Industry Information Association (SIIA) or Federation Against Software Theft (FAST) be used directly or indirectly to conduct audits, or be recommended by Contractor; (iv) Contractor and Licensee are each entitled to designate a representative who shall be entitled to participate, and who shall mutually agree on audit format, and simultaneously review all information obtained by the audit. Such representatives also shall be entitled to copies of all reports, data or information obtained from the audit; and (v) if the audit shows that such party is not in compliance, Licensee shall be required to purchase additional licenses or capacities necessary to bring it into compliance and shall pay for the unlicensed capacity at the NYS Net Price in effect at time of audit, or if none, then at the Contractor’s U.S. Commercial list price. Once such additional licenses or capacities are purchased, Licensee shall be deemed to have been in compliance retroactively, and Licensee shall have no further liability of any kind for the unauthorized use of the software.
