Alteration of Delivery Date Clause Samples
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE which the Arbitrator or the Arbitration Board may deem appropriate. To the maximum extent possible and provided the arbitration proceedings or the subject matter of the dispute do not affect the construction of the VESSEL, work under this CONTRACT shall continue during the arbitration of any dispute.
Alteration of Delivery Date. In the event that any dispute or difference is referred either to arbitration or to an expert, the arbitration tribunal or expert, as the case may be, shall, where the dispute requires, include a finding as to whether or not the Delivery Date of the VESSEL should, as a result of such dispute, be in any way altered thereby.
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in ARTICLE VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date or on such newly planned time of delivery of the VESSEL as declared by the SELLER. However, if the construction of the VESSEL is affected by any arbitration or court proceeding, the SELLER shall then be permitted to extend the Delivery Date as defined in ARTICLE VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date. (end of Article)
Alteration of Delivery Date. In the event of arbitration of any dispute arising from any matters occurring prior to delivery of the VESSEL EQUIPMENT, all delays in delivery of the VESSEL EQUIPMENT due to such arbitration shall be deemed to be permissible delays and the delivery date shall be automatically postponed and/or extended for the period of time occupied by such arbitration commencing with the notice to arbitrate and concluding with the publication of the award.
Alteration of Delivery Date. In the event of arbitration of any dispute arising or occurring prior to delivery of the VESSEL, an award of the arbitrators shall include a finding as to whether or not the delivery date of the VESSEL is in any way altered thereby.
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in Article VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date or on such newly planned time of delivery of the VESSEL as declared by the SELLER. However, if the construction of the VESSEL is affected by any arbitration, the SELLER shall then be permitted to extend the Delivery Date as defined in Article VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date. Shipbuilding Contract Hull No.H1596