Additional Tanks Sample Clauses

Additional Tanks. If Buyer or Seller determines that additional off-site storage space is needed for use in connection with the operation of the Refinery, Buyer may locate and propose to Seller proposed storage space to be used for additional Oil and/or Feedstock storage (a “Proposed Storage Site”), together with proposed terms for acquiring such Proposed Storage Site. If such Proposed Storage Site is acceptable to Seller, including, with respect to (i) Seller’s HSE standards, (ii) other site conditions, and (iii) commercial terms, then Seller may acquire such Proposed Storage Site (by lease or otherwise) for Buyer’s use on such terms as are mutually acceptable to the Parties. Seller shall complete its review in a timely manner based on then-existing circumstances. Buyer shall be responsible for all costs and expenses incurred by Seller with respect to the use of such Proposed Storage Site, including lease payments or the equivalent, and expenses and Seller’s costs incurred in negotiating the acquisition of such Proposed Storage Site for Buyer’s use, all on a pass-through basis and with prior approval of Buyer. Any Proposed Storage Site acquired by Seller pursuant to the terms of this Clause 8(b) shall become a “Statoil Storage Facility”. It is Buyer’s sole responsibility to provide adequate storage space for the storage of Oil and Feedstock purchased at the mandate of Buyer hereunder, and Seller shall not be responsible for providing additional storage space or for performing any inventory management services, except as provided in this Clause 8(b) and Clause 9(e).
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs

Related to Additional Tanks

  • Underground Tanks If underground or other storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks.

  • Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.

  • Storage Tanks If storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks. Notwithstanding anything to the contrary contained herein, Tenant shall have no right to use or install any underground storage tanks at the Project.

  • Additional Work If changes in the work seem merited by Consultant or the City, and informal consultations with the other party indicate that a change is warranted, it shall be processed in the following manner: a letter outlining the changes shall be forwarded to the City by Consultant with a statement of estimated changes in fee or time schedule. An amendment to this Agreement shall be prepared by the City and executed by both Parties before performance of such services, or the City will not be required to pay for the changes in the scope of work. Such amendment shall not render ineffective or invalidate unaffected portions of this Agreement.

  • ADDITIONAL SPECIAL CONTRACT CONDITIONS A. Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:

  • Additional Space Commencing on May 1, 2001, Sublessor herein grants unto the Sublessee a Right of First Refusal on any space that shall be and/or becomes available in the building during the remaining Term of this Sublease. Prior to May 1, 2001 and thereafter prior to the first day of May of any calendar year during the remaining Term hereof, Sublessor shall notify Sublessee by written notice of the availability of any such space in the building. Should Sublessee desire to exercise its Right of First Refusal and sublease such available space, Sublessee must notify Sublessor in writing of its desire to sublease the available space within seven (7) calendar days of Sublessee's receipt of Landlord's notice of availability. Within thirty (30) days of the receipt of Sublessee's notice exercising the right to sublease such available space, Sublessee and Sublessor shall enter into an amendment of this agreement setting forth the terms under which the additional space is subleased to Sublessee. The Base Rental shall be at a rental mutually agreed between Sublessee and Sublessor. Failure by Sublessee to exercise its Right of First Refusal within said seven (7) calendar day period, or if exercised, failure to enter into an amendment of this agreement within thirty (30) days of Sublessor's receipt of Sublessee's notice, shall be deemed a waiver of such right and Sublessor shall thereafter be free of any obligation under this Article 2.04 for a period of 12 months. Any exercise by Sublessee of this Right of First Refusal shall be for a minimum of 5,000 rental square feet.

  • Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades

  • Underground Storage Tanks In accordance with the requirements of Section 3(g) of the D.C. Underground Storage Tank Management Act of 1990, as amended by the District of Columbia Underground Storage Tank Management Act of 1990 Amendment Act of 1992 (D.C. Code § 8-113.01, et seq.) (collectively, the “UST Act”) and the applicable D.C. Underground Storage Tank Regulations, 20 DCMR Chapter 56 (the “UST Regulations”), District hereby informs the Developer that it has no knowledge of the existence or removal during its ownership of the Property of any “underground storage tanks” (as defined in the UST Act). Information pertaining to underground storage tanks and underground storage tank removals of which the D.C. Government has received notification is on file with the District Department of the Environment, Underground Storage Tank Branch, 00 X Xxxxxx, X.X., Xxxxx Xxxxx, Xxxxxxxxxx, X.X., 00000, telephone (000) 000-0000. District’s knowledge for purposes of this Section shall mean and be limited to the actual knowledge of Xxxxxx Xxxxx, Property Acquisition and Disposition Division of the Department of Housing and Community Development, telephone no. (000) 000-0000. The foregoing is set forth pursuant to requirements contained in the UST Act and UST Regulations and does not constitute a representation or warranty by District.

  • Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.

  • Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.

Time is Money Join Law Insider Premium to draft better contracts faster.