Additional services provided by the Clause Samples

Additional services provided by the. Consulting Engineer a) Preparing any report or additional contract documents required for consideration of proposals for the carrying out of alternative Works. b) Carrying out work in connection with any application by the Client for any order, sanction, license, permit or other consent, approval or authorization necessary to enable the Works to proceed. c) Carrying out work arising from the failure of the Client to award a contract in due time. d) Providing or carrying out special cost investigations, detailed valuations or cost analyses for cost planning purposes. e) Preparing details of shop fabrication of structural steelwork, ductwork, metal, timber or plastic frameworks or other specialist supplied components. f) Carrying out surveys of existing works or installations or checking and advising upon any other part of the Project not designed by the Consulting Engineer. g) Carrying out work consequent upon any assignment of a contract by the Contractor or upon the failure of the Contractor properly to perform any contract or upon delay by the Client in fulfilling his obligation or in taking any other step necessary for the due performance of the Works. h) Making visits to the site in addition to those needed for basic representation of the Client on site as provided for in Clause 1.4 of this Appendix. i) Advising the Client and carrying out work following the taking of any step in or towards any litigation or arbitration relating to the Works.