Works Completion Certificate(s) definition

Works Completion Certificate(s) means the certificate or certificates of completion of the Works as a whole or any Section or Completed Part issued by the Project Manager in accordance with paragraph S2-15 (Certification of completion of the Works or any Section or Completed Part) of Schedule 2, in the relevant standard form;
Sample 1Sample 2Sample 3

Examples of Works Completion Certificate(s) in a sentence

  • The details on turnover, works experience (Works Completion Certificates issued by customers / clients must be enclosed), P.F, ESI registration etc., all as furnished by the tenderer shall have to be supported with documentary evidences (Xerox copies -attested).

  • Upon successful Completion of the Works, and prior to making an application to the Authority for issuance of Works Completion Certificates, the Contractor shall clear all plants, equipment, surplus materials, wreckage, rubbish and temporary work from the Site.

  • All parcels of land and easements proposed to be dedicated for public use and the conditions of each dedication.

  • If the Authority fails either to issue Works Completion Certificates or to reject the Contactor’s application within the period of 28 (twenty eight) days, and if the Completion of the Works or part thereof, as the case may be, covered under such application is substantially complete in accordance with the terms of this Contract, Works Completion Certificates shall be deemed to have been issued on the last day of that period.

  • Final payment shall only be made when all Minor Works, Completion Certificates, Periodic Inspection Reports schedules of inspection and schedules of test results, and all other associated Commissioning Certificates and any other relevant documentation have been received and that the works are acceptable to the University.

  • Pursuant to 22 Construction Works Completion Certificates issued by Guiyang Housing and Urban-Rural Development Committee, portion of the Development with a total construction scale of 923,073.31 sq m was completed.

  • With the issuing of the respective Works Completion Certificates, it shall be understood that authorization has been granted to: (i) begin the Functional Testing of the Works for each Milestone of Component 1; or (ii) begin the Start-Up of Component 2.

  • Pursuant to 12 Construction Works Completion Certificates issued by Guiyang Housing and Urban-Rural Development Committee, portion of the Development with a total construction scale of 591,288.48 sq m was completed.

  • The AD tools automatically employ a combined strategy of rerunning and checkpointing for intermediate values of active variables.

  • Upon successful Completion of the Works, and prior to making an application to the Authority for issuance of Works Completion Certificates, the Contractor shall clear all plants, equipment, surplus materials, wreckage, rubbish, and temporary work from the Site.

Related to Works Completion Certificate(s)

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Construction Completion Certificate means a document:

  • Completion Certificate means the certificate to be issued by the GIPCL when the work/ s have been completed to his satisfaction as per terms of the contract.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Satisfaction Certificate means the certificate materially in the form of the document contained in Call Off Schedule 5 (Testing) granted by the Customer when the Supplier has Achieved a Milestone or a Test;

  • Allocation Certificate shall have the meaning set forth in Section 5.20.

  • Perfection Certificates is defined in Section 5.1.

  • Occupation Certificate means any occupation certificate as referred to in s 6.4 of the Act in respect of the Development Consent;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Special Contract Attachments means any attachment to this Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Perfection Certificate Supplement means a certificate supplement in the form of Exhibit G-2 hereto or any other form approved by the Collateral Agent.

  • Punch List Items means such items (i) as are reasonably necessary or appropriate to fully complete the construction, equipping and furnishing of the Hotel in accordance with this Contract and (ii) that, unless otherwise agreed by Buyer in its sole discretion, (a) individually and in the aggregate do not and will not prohibit, cause a delay in or otherwise adversely affect, under applicable Legal Requirements, the Franchise Agreement or otherwise, the opening of the Hotel for business to the public or the continued occupancy and operation of the Hotel as contemplated under the Brand and (b) may be corrected or completed, subject to delays caused by Force Majeure, within not more than sixty (60) days.

  • Certificate of Completion means the certificate of completion given by the Engineer-in- charge pursuant to clause 40 of these conditions;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Information Certificate means the Information Certificate of Borrower constituting Exhibit A hereto containing material information with respect to Borrower, its business and assets provided by or on behalf of Borrower to Lender in connection with the preparation of this Agreement and the other Financing Agreements and the financing arrangements provided for herein.

  • Final Completion Date means the date on which Final Completion occurs.

  • Perfection Certificate is defined in Section 5.1.