Weather Delay Day definition

Weather Delay Day means a Day during which: (i) wind speeds above the limits the lift plan for that specific crane interfere with and prevent the safe movement (including the lifting) of WTG components; (ii) wind speeds above the limits set forth in the Turbine Supply Agreement that interfere with and prevent the performance of work necessary to achieve WTG Mechanical Completion; or (iii) other unusually severe or not reasonably anticipated inclement weather or cumulative weather events that prevents or interferes with the performance of Contractor or any of its Subcontractors if such effect can be demonstrated by Contractor as having a material adverse effect on the Project Schedule’s Critical Path. The existence of a Weather Delay Day shall be determined in increments of half of the work day otherwise scheduled. For the purpose of clarity, such half-day increment shall be defined by Contractor or any of its Subcontractors as the number of half work day increment hours on a Day in which Work was originally scheduled. In the event the weather event continues for more than the defined number of half work day increment hours in a Day, such period will be deemed to be a full Day.
Sample 1Sample 2
Weather Delay Day means a day during which Work is scheduled but cannot be performed safely for at least one-half of the scheduled work shift due to (i) sustained wind speeds exceeding the limit specified by applicable OSHA regulations, (ii) lightning storms, or (iii) rainfall or snowfall that substantially exceeds the normal amount for the time of year. The existence of Weather Delay Days shall be determined in half-day increments.
Sample 1Sample 2
Weather Delay Day has the meaning ascribed thereto In Article 3.6. of Part B of the Agreement. "Dzień Opóźnienia z Powodu Warunków Atmosferycznych" ma znaczenie przypisane w Artykule 3.6. Części B Umowy.
Sample 1

Examples of Weather Delay Day in a sentence

  • Contractor will not be entitled to an extension of time for a Weather Delay Day to the extent Contractor is responsible for concurrent delay on that day.

  • Contractor will be entitled to a non-compensable extension of the Contract Time for each Weather Delay Day in excess of the normal Weather Delay Days within a given month as determined by reliable records, including monthly rainfall averages, for the preceding ten years (or as otherwise specified in the Special Conditions or Specifications).

  • Contractor will not be entitled to an extension of time for a Weather Delay Day to the extent Contractor is responsible for concurrent delay on that day.(G) Recoverable Costs.

  • A Weather Delay Day is a Working Day during which Contractor and its forces, including Subcontractors, are unable to perform more than forty percent (40%) of the critical path Work scheduled for that day due to adverse weather conditions which impair the ability to safely or effectively perform the scheduled critical path Work that day.

  • As a Design Professional’s Decision, Design Professional shall determine if each documented Weather Delay Day impacts the critical path.

  • CM/GC shall be entitled to an extension of Contract Time for each Abnormal Weather Delay Day verified by the CCS that Design Professional determines has delayed the critical path of Work based on the Overall Project Schedule on the condition that CM/GC complies with this Section 1.4.2, including but not limited to the requirements of documentation set forth in Section 1.4.2.1.4, and that CM/GC takes all reasonable efforts to mitigate the effects of Abnormal Weather Delay Days.

  • An Other Noncompensable Delay Event will not include a Weather Delay Day.

  • CM/GC may protest the Design Professional’s Decision as to whether each Abnormal Weather Delay Day impacts the critical path only as set forth in Section 5.2.2.5.

  • Orders shall not be deemed as accepted but upon confirmation by us or delivery having been made.

  • A Weather Delay Day may be counted if adverse weather prevents work on the project for fifty percent (50%) or more of the Contractor’s scheduled work day.


More Definitions of Weather Delay Day

Weather Delay Day means a day during which wind speeds (as measured at the Site both hand held and at crane tip) are over the speeds described here below, or there are other severe weather conditions at the Site (such as heavy snow, heavy rain or fog), and as a result the unloading, assembly and/or erection of the WTG tower, nacelle or rotor at the Site cannot be performed. 15 m/s will be used for the unloading crews 12 m/s will be used for the Turbine tower and nacelle erection crews A Weather Delay Day may only occur on days when: (a) Turbines are scheduled to be unloaded, assembled and erected; (b) wind speeds are at the levels described above or the severe weather conditions referenced above actually prevent Servicer from performing activities involving cranes or other lifting devices at the project site for a period in excess of four (4) hours during working hours within a day. The Programme and/or the Contract Price shall be adjusted in the following manner for any Weather Delay Days: The determination of whether a Weather Delay Day has occurred according to the definition of “Weather Delay Day” above must be made as soon as possible. On the day on which the wheather conditions cause such day to be the Weather Delay Day the Servicer shall immediately notify the Buyer of its determination that there is a Weather Delay Day. The Parties will agree whether there is a Weather Delay Day as soon as reasonably practical based on the data collected and documented by the Servicer. Servicer shall use commercially reasonable efforts to mitigate any adverse impact to the Programme resulting from Weather Delay Days, which may include reassignment of personnel or equipment to unaffected work. Servicer may elect to allow personnel that are not able to work on a particular day because of a Weather Delay Day to be released for the day. To the extent Servicer experiences Weather Delay Days during periods for scheduled work related to
Sample 1

Related to Weather Delay Day

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Service Failure means a failure by the Contractor to provide the Services in accordance with any individual service level described above (measured on a monthly/quarterly/annual basis)

  • Supply Failure shall have the meaning ascribed to it in Section 2.8.

  • Grace Period Business Day means a day on which commercial banks and foreign exchange markets are generally open to settle payments in the place or places and on the days specified for that purpose in the relevant Obligation and if a place or places are not so specified, in the jurisdiction of the Obligation Currency.

  • Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.

  • Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.

  • Unplanned Outage refers to the unavailable status of the units of the Power Plant other than Planned Outage. Based on the urgency of the needs of outage, the Unplanned Outage can be classified into five categories: (1) immediate outage; (2) the outage which could be delayed for a short while but the units must exit within six hours; (3) the outage which could be postponed over six hours but the units must exit within seventy-two hours; (4) the outage which could be deferred over seventy-two hours but the units must exit before the next Planned Outage; and (5) the prolonged outage which is beyond the period of the Planned Outage.

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Generator Planned Outage means the scheduled removal from service, in whole or in part, of a generating unit for inspection, maintenance or repair with the approval of the Office of the Interconnection in accordance with the PJM Manuals.

  • Scheduled Unavailability Date has the meaning specified in Section 3.03(c).

  • Volume Failure means, with respect to a particular date of determination, the aggregate daily dollar trading volume (as reported on Bloomberg) of the Common Stock on the Principal Market on any Trading Day during the twenty (20) Trading Day period ending on the Trading Day immediately preceding such date of determination (such period, the “Volume Failure Measuring Period”), is less than $2,000,000 (as adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions occurring after the Subscription Date). All such determinations to be appropriately adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions during such Volume Failure Measuring Period.

  • Epidemic Failure means a series of repeating failures or defects resulting in at least a 0.5% failure rate for the same Product or Material during any twelve-month period.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Final Availability Date means the earlier of the Revolving Termination Date and one (1) Business Day prior to the date specified in clause (a) of the definition of Revolving Termination Date.

  • Allowed Delay has the meaning set forth in Section 2(c)(ii).

  • Delay Period shall have the meaning set forth in Section 5 hereof.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Planned Outage means the removal of equipment from service availability for inspection and/or general overhaul of one or more major equipment groups. To qualify as a Planned Outage, the maintenance (a) must actually be conducted during the Planned Outage, and in Seller’s sole discretion must be of the type that is necessary to reliably maintain the Project, (b) cannot be reasonably conducted during Project operations, and (c) causes the generation level of the Project to be reduced by at least ten percent (10%) of the Contract Capacity.

  • major accident means an incident involving loss of life inside or outside the establishment or ten or more injuries inside and/or one or more injuries outside or release of toxic chemical or explosion or fire or spillage of hazardous chemical resulting in ‘on-site’ or ‘off-site’ emergencies or damage to equipment leading to stoppage of process or adverse effect to the environment;

  • Availability Date means the day after the end of the fourth fiscal quarter following the fiscal quarter that includes such Effective Time on which the Company is required to file its Form 10-Q for such fiscal quarter except that, if such fourth fiscal quarter is the last quarter of the Company’s fiscal year, “Availability Date” means the day after the end of such fourth fiscal quarter on which the Company is required to file its Form 10-K.