Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.
Proposed Change Order (PCO means a document that informs Contractor of a proposed change in the Work and appropriately describes or otherwise documents such change including Contractor’s response of pricing for the proposed change.
Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.
Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Scope Change means any change to the scope of a contract to accommodate a need not originally provided for in the contract and which may include the acquisition of additional deliverables or the extension of the term of the contract and which may require an adjustment to the contract price;
Product Schedule means PTC’s standard order form entitled “PTC Product Schedule” (including all schedules, attachments and other document(s) specifically referenced therein) or such alternative order form as may be submitted by Customer and accepted by PTC, in each case that specifies (i) the Licensed Products and/or Services ordered; and (ii) for Licensed Products, the installation address (including the Designated Country) and the Licence Term.
Unilateral Change Order (ULCO means a Change Order issued by Owner without the complete agreement of Contractor, as to cost and/or time.
Shift Schedule means a projection of Employees’ shifts with regard to days worked and days off, including shift starting and terminating times.
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Benchmark Replacement Conforming Changes means, with respect to any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Business Day,” the definition of “Interest Period,” timing and frequency of determining rates and making payments of interest, timing of borrowing requests or prepayment, conversion or continuation notices, the applicability and length of lookback periods, the applicability of breakage provisions, and other technical, administrative or operational matters) that the Administrative Agent decides may be appropriate to reflect the adoption and implementation of such Benchmark Replacement and to permit the administration thereof by the Administrative Agent in a manner substantially consistent with market practice (or, if the Administrative Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Administrative Agent determines that no market practice for the administration of such Benchmark Replacement exists, in such other manner of administration as the Administrative Agent decides is reasonably necessary in connection with the administration of this Agreement and the other Loan Documents).
Contract Schedule means a schedule to this Contract;
Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.
Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.
Major modification means any physical change in or change in the method of operation of a major stationary source that would result in a significant emissions increase of a regulated NSR pollutant and a significant net emissions increase of that pollutant from the major stationary source.
Specification Schedule means the Schedule containing details of the Specification.
Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.
The Work Order means the order placed by the Purchaser on the Supplier signed by the Purchaser including all attachments and appendices thereto and all documents incorporated by reference therein. The Work order shall be deemed as "Contract" appearing in the document.
MSAA Indicator Technical Specifications document means, as the context requires, either or both of the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Indicator Technical Specifications November 5, 2018 Version 1.3” and the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Target and Corridor-Setting Guidelines” as they may be amended or replaced from time to time;
Proposed Change has the meaning assigned to such term in Section 9.02(c).
Development Schedule shall have the meaning set forth in Section 1.1.
Delivery Schedule means the schedule for the delivery of Services as set forth in attached Annex 3.
Program change means any elimination, curtailment or reorganization of a curriculum offering, program or school operation or a reorganization or closing of a school or consolidation of two or more individual schools or school districts that is unrelated to financial exigency.
Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.
Major Change means: The implementation of a change that could have an effect on the security of an IT Resource or Institutional Information. The scope includes changes to architectures, processes, tools, metrics, and documentation, as well as changes to IT services and other configuration items. These include changes related to:
Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.