Unexcusable Delay definition

Unexcusable Delay means any delay of the completion of the Project beyond the expiration of the Contract Time resulting from causes other than those listed above. An Unexcusable Delay shall not entitle the Contractor to an extension of the Contract Time or an adjustment of the Contract Sum.
View Source
Unexcusable Delay shall have the meaning set forth in Section 4.6.2.
View Source
Unexcusable Delay means a delay that does not entitle the Contractor to an adjustment of the Contract Sum and does not entitle the Contractor to an adjustment of the Contract Time.
View Source

Examples of Unexcusable Delay in a sentence

  • In the absence of agreement between the parties as to the then current status of Excusable Delays and Unexcused Delays, the Owner will provide the Design/Builder with written notice of Owner's determination of the respective number of Days of Excusable Delay and/or Unexcusable Delay within ten (10) Days after receipt by the Owner of the Design/Builder's written request for such determination.

  • Pending completion of dispute resolution procedures, the Design/Builder may take such acceleration or other measures on account of the Owner's determination of Unexcusable Delay, and if completion of the dispute resolution procedures results in the Owner's determination being changed to Excusable Delay, the costs associated with such measures shall be paid by the Owner as an increase to the GMP in accordance with the Change Order provisions of this Agreement.

  • To the extent the Design/Builder is entitled to an extension of time due to an Excusable Delay, but the performance of the Work would have been suspended, delayed or interrupted by the fault or neglect of the Design/Builder or by an Unexcusable Delay, the Design/Builder shall not be entitled to any additional costs for the period of such concurrency.

  • Within thirty (30) Days after cessation of an event-giving rise to either an Excusable Delay or Unexcusable Delay, the parties will use good faith efforts to agree on the extent to which the Work has been delayed and whether the delay is an Excusable Delay or an Unexcusable Delay.

  • Pending completion of dispute resolution procedures, the Design/Builder may take such acceleration or other measures on account of the Owner's determination of Unexcusable Delay, and if completion of the dispute resolution procedures results in the Owner's determination being changed to Excusable Delay, the costs associated with such measures may be paid by the Owner as an increase to the GMP in accordance with the Change Order provisions of this Agreement.

  • In the absence of agreement between the Parties as to the then current status of Excusable Delays and Unexcused Delays, the Owner will provide the Design-Builder with written notice of its determination of the respective number of Days of Excusable Delay and/or Unexcusable Delay.

  • In the absence of agreement between the parties as to the then current status of Excusable Delays and Inexcusable Delays, CITY will provide CONTRACTOR with written notice of CITY's determination of the respective number of Days of Excusable Delay and/or Unexcusable Delay within ten (10) Days after receipt by CITY of CONTRACTOR's written request for such determination.

  • Within ten (10) Days after cessation of an event giving rise to either an Excusable Delay or Unexcusable Delay, the parties will use good faith efforts to agree on the extent to which the Work has been delayed and whether the delay is an Excusable Delay or an Unexcusable Delay.

  • The commencement or completion of any Work activity on the critical path is more than 6 days behind the date set forth in the Contract Schedule for such Work activity as a result of an Unexcusable Delay.

  • To the extent the Design-Builder is entitled to an extension of time due to an Excusable Delay, but the performance of the Work would have been suspended, delayed or interrupted by the fault or neglect of the Design-Builder or by an Unexcusable Delay, the Design-Builder shall not be entitled to any additional costs for the period of such concurrency.


More Definitions of Unexcusable Delay

Unexcusable Delay means any foreseeable delay of the completion of the Work beyond the expiration of the Job Order Completion Time caused by conditions within the control of the Contractor, including, without limitation, performance of the Contractor and Subcontractors, timely material delivery, financial inability of the Contractor or any subcontractors, and any default of any subcontractor. An Unexcusable Delay shall not entitle the Contractor to an extension of the Job Order Completion Time or an adjustment of the Job Order Price.
View Source
Unexcusable Delay means any delay of the completion of the Work beyond the expiration of the Contract Time resulting from causes other than those listed in
View Source

Related to Unexcusable Delay

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, material litigation by parties other than the Parties not caused by the Parties’ failure to perform, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable party using reasonable diligence to overcome which prevents such party from performing its specific duties or obligation hereunder in a timely manner.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.