Uncontrollable Events definition

Uncontrollable Events means (i) acts or omissions on the part of American or any of its Subsidiaries in conducting its respective operations other than those relating to the number of American FCC Licenses or amount of revenues in a particular market, (ii) an unremedied or unwaived material breach by American of its obligations under this Agreement, or (iii) any change in or enactment of Applicable Law by Congress and signed by the President and which (A) has the effect of decreasing the number of radio licenses which a Person may own nationally or locally or (B) materially and adversely relates to the concentration of radio licenses which a Person may own in a market, and as a result of the change or enactment referred to in either clause (A) or (B) above, Mergeparty's performance of its obligations under this Agreement would have a Material Adverse Effect on Mergeparty's radio and television broadcasting business. Mergeparty shall file with the FCC, within sufficient time to permit timely grant of the Applications, applications for consent to assign or transfer, pursuant to trust arrangements satisfying the FCC's local multiple ownership rules and policies, such radio broadcast stations as Mergeparty may designate, so that the radio broadcast stations of Mergeparty and American not designated for such trust arrangements may be held by the Surviving Corporation in compliance with the FCC's local multiple ownership rules and policies. Mergeparty shall, to the extent necessary to obtain grant of the trust applications, thereafter promptly file or cause to be filed any further applications (including applications to assign radio broadcast stations to third party purchasers for value) that may be required by the FCC. Notwithstanding the two preceding sentences, with regard to stations located in the San Jose ▇▇▇ket, the obligations of Mergeparty to submit trust or sale applications shall be excused for such stations to the extent and for the duration of the period that Mergeparty is unable to identify the stations to be placed in trust or sold because of the failure of American to notify Mergeparty of the resolution of the Antitrust Division impediment impacting the American transactions pending in the San Jose ▇▇▇ket.
View Source
Uncontrollable Events shall be defined as set forth in Subsection (A) below, and shall expressly exclude the situations set forth in Subsection (B) below:
View Source
Uncontrollable Events shall include acts of God, strikes, lockouts, or other industrial disturbances, acts of public enemies, orders or acts of governmental authorities, orders or acts of military authorities, insurrections, riots, epidemics, floods or other natural disasters, fire, civil disturbances, explosions, breakage, accident to machinery, communication line failures, power or other utility failures, failures of any computer or related equipment, or any other similar event not reasonably within the control of the party claiming an inability to perform.
View Source

Examples of Uncontrollable Events in a sentence

  • Seller shall use commercially reasonably efforts to obtain Final Approval of the Entitlements applicable to the Takedown 1 Lots on or before that date which is nine (9) months after the expiration of the Due Diligence Period, as such period may be extended pursuant to this Section 5(a)(i), or as a result of delays resulting from Uncontrollable Events.

  • Uncontrollable Events: Neither party will be liable for delays or failures in performance due to events beyond their reasonable control, including natural disasters, government actions, or regulatory changes that impact service delivery.

  • Anything herein to the contrary notwithstanding, neither the Village nor the Developer nor any successor in interest to either of them shall be considered in breach of or in default of its obligations under this Agreement in the event of any delay or nonperformance caused by Uncontrollable Events beyond the reasonable control of the Party affected which in fact interferes with the ability of such party to discharge its obligations hereunder.

  • Uncontrollable Events Neither of us will be in default under this Agreement if the default is caused by an Uncontrollable Event.

  • If the Uncontrollable Events last for ten (10) consecutive days or less, then only one notice provided within ten (10) days after the end of such occurrence will be required.

  • If Seller has not secured such Final Approval of the Entitlements applicable to the Takedown 1 Lots by the expiration of the initial nine (9) month period (subject to delays resulting from Uncontrollable Events) and neither party exercises such six-month extension, this Contract shall automatically terminate and each party hereto shall thereupon be relieved of all further obligations and liabilities under this Contract, except as otherwise provided herein, and the Deposit shall be returned to Purchaser.

  • If Seller has not secured such Final Approval of the Takedown 1 Lots by the expiration of the initial nine (9) month period (subject to delays resulting from Uncontrollable Events) and shall fail to exercise such extension, each party shall thereupon be relieved of all further obligations and liabilities under this Contract, except as otherwise provided herein, and the Deposit shall be returned to Purchaser.

  • The Purchase Price Escalator shall not accrue or be calculated during extension periods requested by Seller and in no event be calculated beyond 24 months from the previous Closing, except in the event of delays resulting from Purchaser’s actions, defaults, or as a result of Uncontrollable Events.

  • Seller shall use commercially reasonably efforts to obtain Final Approval of the Entitlements applicable to the Takedown 1 Lots on or before that date which is nine (9) months after the expiration of the Due Diligence Period, as such period may be extended pursuant to this Section 5(a), or as a result of delays resulting from Uncontrollable Events.

  • SECTION SIX - Contractual Liabilities/Commitment Except for Force Majeures or Uncontrollable Events, if GWAPO, Inc.


More Definitions of Uncontrollable Events

Uncontrollable Events means any circumstances beyond the Service Provider reasonable control, including (without limitation) any act of God, public enemy, fire, explosion, earthquake, perils of the sea, flood, storm or other adverse weather conditions, war declared or undeclared, civil war, revolution, civil commotion or other civil strife, riot, blockade, embargo, sanctions, academics, act of any government or other authority, compliance with government orders, demands or regulations, compliance with court orders, or any act or mission on the part of a third party (including South Africa Weather Services);
View Source
Uncontrollable Events. I acknowledge that certain risks are beyond the control of MTIMA and CSE, such as natural disasters, acts of war, terrorism, pandemics, or other emergencies, and agree that neither MTIMA nor CSE shall be held liable for any claims, damages, or losses arising from such uncontrollable events. • Cross-Indemnification: I further agree to indemnify, defend, and hold harmless MTIMA and CSE against any and all claims that may arise from the conduct of other volunteers, participants, or third parties over which neither organization has control.
View Source

Related to Uncontrollable Events

  • Uncontrollable Force means any cause beyond the control of the Borrower, including: (a) a hurricane, tornado, flood or similar occurrence, landslide, earthquake, fire or other casualty, strike or labor disturbance, freight embargo, act of a public enemy, explosion, war, blockade, terrorist act, insurrection, riot, general arrest or restraint of government and people, civil disturbance or similar occurrence, sabotage, or act of God (provided that the Borrower shall not be required to settle any strike or labor disturbance in which it may be involved) or (b) the order or judgment of any federal, state or local court, administrative agency or governmental officer or body, if it is not also the result of willful or negligent action or a lack of reasonable diligence of the Borrower and the Borrower does not control the administrative agency or governmental officer or body; provided that the diligent contest in good faith of any such order or judgment shall not constitute or be construed as a willful or negligent action or a lack of reasonable diligence of the Borrower.

  • Uncontrollable Circumstance means any act, event or condition that is:

  • Uncontrollable Forces means any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions.

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.