Uncontrollable Delay definition

Uncontrollable Delay means any delay in achieving the Initial Operation Date on or before the Expected In-Service Date that occurs solely as a result of one of more events of Uncontrollable Force.
Sample 1Sample 2
Uncontrollable Delay means a quantifiable period of delay in achieving Completion directly caused by any Uncontrollable Event as determined pursuant to good development and construction scheduling practices; provided, however, in order for SIP Member to avail itself of an Uncontrollable Delay, SIP Member must notify Dividend Member as soon as practicable after the occurrence of an event which, in the reasonable opinion of the SIP Member, constitutes an Uncontrollable Event and must notify Dividend Member of the day on which such Uncontrollable Delay ceased as soon as practicable after the end of such Uncontrollable Delay.
Sample 1Sample 2
Uncontrollable Delay means a quantifiable period of delay in achieving Completion directly caused by any Uncontrollable Event as determined pursuant to good development and construction scheduling practices; Xxxxxxx Xxxxxx Member shall notify Dividend Member at least monthly in connection with a draw request under the Construction Loan as to any Uncontrollable Delay.
Sample 1

Examples of Uncontrollable Delay in a sentence

  • Accordingly, the Estimated Base Building Work Completion Date is hereby extended from November 1, 2021 to December 15, 2021, as such date may be further extended by any Tenant Delay (including, but not limited to, the actual Tenant Delay resulting from including the Elevator Work as part of the Base Building Improvements) or by any Uncontrollable Delay (as defined in Section 5.6 of the Work Letter).

  • The Commencement Date shall be delayed one day for each day of an Uncontrollable Delay.

  • Review default Content Gateway ports: Content Gateway uses 8 ports on your server: PortAssignments: '1'Content Gateway Proxy Port8080'2'Web Interface port8081'3'Auto config port8083'4'Process manager port8084'5'Logging server port8085'6'Clustering port8086'7'Reliable service port8087'8'Multicast port8088Enterthe port assignment you wouldlike to change:‘1-8’ ‘X’‘H’[X] >- specific port changes- no change- help Change a port assignment if it will conflict with another application or process on the machine.

  • Subject to the condition that Landlord has completed the Landlord Work (as defined in Section 1 of the Tenant Work Letter), the earlier of (i) May 1, 2016, subject to any Landlord Delay or Uncontrollable Delay (as defined in Section 5.5 of the Tenant Work Letter), (ii) the date Tenant first commences to conduct business in the Premises, or (iii) the date of Substantial Completion (as defined in Section 5 of the Tenant Work Letter) of the Premises.

  • If the Base Building Improvements are not substantially complete by the Estimated Base Building Work Completion Date, as such date may be extended by any Tenant Delay (as defined in Section 1.9 below) or by any Uncontrollable Delay (as defined in Section 5.6 below), then as Tenant’s sole remedy for such failure, the Pod 5 Portion Commencement Date shall be delayed on a day-for-day basis until the Base Building Improvements are substantially complete.


More Definitions of Uncontrollable Delay

Uncontrollable Delay means only an actual delay in the completion of the Tenant Improvements resulting from Force Majeure. The term “Landlord Delay” shall mean only an actual delay in the completion of the Tenant Improvements which is caused by (a) the failure of Landlord to provide responses to requests by Tenant for authorizations or approvals (e.g., approvals, disapprovals or conditional approvals) within the time period set forth in this Tenant Work Letter, (b) the failure by Landlord to pay the Improvement Allowance when due under this Tenant Work Letter, (c) Landlord’s failure to provide Tenant with possession of the applicable portion of the Premises for the purposes of constructing the Tenant Improvements therein after the Final Working Drawings for such portion have been approved by Landlord and Tenant and Tenant has received all Permits, or (d) Landlord’s failure to deliver the Premises at the time required by subsection (c) above with Landlord’s Work complete as required pursuant to this Tenant Work Letter. Notwithstanding anything to the contrary contained herein, neither an Uncontrollable Delay nor a Landlord Delay shall include any of the foregoing delays to the extent caused by the acts, omissions, or misconduct of Tenant or Tenant’s Agents. No Uncontrollable Delay or Landlord Delay (except for (a) above) shall be deemed to have occurred unless Tenant has given Landlord written notice that an act or omission on the part of Landlord or its agents is about to occur or has occurred (with respect to an alleged Landlord Delay) or that an event giving rise to an Uncontrollable Delay is about to occur or has occurred (with respect to an Uncontrollable Delay) which will cause a delay in the completion of the Tenant Improvements and Landlord has failed to cure such delay (with respect to a Landlord Delay) or has failed to remedy the situation giving rise to a potential Uncontrollable Delay (with respect to an Uncontrollable Delay) within one (1) business day after Landlord’s receipt of such notice, in which case the number of days of delay after such notice shall be a Landlord Delay or an Uncontrollable Delay as applicable. Any Landlord failure to provide authorization or approval under (a) above shall be an automatic Landlord Delay and shall not require notice from Tenant or any cure right for Landlord prior to being deemed as a Landlord Delay. EXHIBIT B SCHEDULE 1 TO EXHIBIT B Conceptual Plan EXHIBIT B EXHIBIT C NOTICE OF LEASE TERM DATES To:
Sample 1
Uncontrollable Delay means only an actual delay in the completion of the Improvements or Base Building Improvements resulting from lightning, earthquake, fire, storm, tornado, blizzard, flood, wash out, explosion, industry-wide strike, lockout or labor dispute, civil disturbance, riot, war, act of the public enemy, sabotage, pandemic, epidemic, states of emergency, decrees, orders, ordinances, statutes, moratorium, laws, or other governmental action or proceeding, of or other similar causes beyond the reasonable control of Tenant (but not to exceed a total of ninety (90) days).
Sample 1
Uncontrollable Delay means only an actual delay in the completion of the Tenant Improvements resulting directly from fire, earthquake, flood, acts of EXHIBIT "D" 6 Initials: ____ ____
Sample 1
Uncontrollable Delay means a delay of a Scheduled Flight for any reason that, if it resulted in the cancellation of such flight, would constitute an Uncontrollable Cancellation, or as provided in Section 2.01(e).
Sample 1

Related to Uncontrollable Delay

  • Uncontrollable Force means any cause beyond the control of the Borrower, including:

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Uncontrollable Forces means any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Uncontrollable Circumstance means any event which:

  • Controllable Operating Expenses means those Project Operating Expenses for which increases are reasonably within the control of Landlord, and shall specifically not include, without limitation, Taxes, assessments, refuse and or trash removal, insurance, collectively bargained union wages, electricity and other utilities. There shall be no limitation on the amount of increase from year to year on Project Operating Expenses which are not Controllable Operating Expenses.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Controllable Expenses means all expenses, other than Uncontrollable Expenses, incurred by the Company or any Subsidiary of the Company with respect to the Property.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Work loss means loss of income from work the injured victim would have performed if the injured victim had not been injured and expenses reasonably incurred by the injured victim in obtaining services in lieu of those the injured victim would have performed for income,

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Tenant Improvements Defined in Exhibit B, if any.

  • a work means the outcome of building or civil engineering works taken as a whole which is sufficient in itself to fulfil an economic or technical function;

  • Generator Planned Outage means the scheduled removal from service, in whole or in part, of a generating unit for inspection, maintenance or repair with the approval of the Office of the Interconnection in accordance with the PJM Manuals.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Unplanned Outage refers to the unavailable status of the units of the Power Plant other than Planned Outage. Based on the urgency of the needs of outage, the Unplanned Outage can be classified into five categories: (1) immediate outage; (2) the outage which could be delayed for a short while but the units must exit within six hours; (3) the outage which could be postponed over six hours but the units must exit within seventy-two hours; (4) the outage which could be deferred over seventy-two hours but the units must exit before the next Planned Outage; and (5) the prolonged outage which is beyond the period of the Planned Outage.