Total Completion Date definition

Total Completion Date means the date that Total Completion has been achieved, as set out in the Total Completion Certificate;
Sample 1Sample 2Sample 3
Total Completion Date means the date upon which all of the work shall be totally completed.
Sample 1Sample 2
Total Completion Date means the date on which Total Completion occurs, as established by the Certificate of Total Completion.
Sample 1Sample 2

Examples of Total Completion Date in a sentence

  • Liquidated damages shall apply to the Total Completion Date for the Total Project Work (as may be extended under the Contract) and, when applicable, the Total Completion Date for each Project Segment (as may be extended under the Contract), in accordance with this Agreement and the Special Conditions.

  • Prior to the Total Completion Date, any such failure to fill the relevant Key Individual position shall be a Non-Compliance Event and for each such Key Individual position Project Co shall pay to the Province in respect thereof an amount equal to $7,000 per week, or part thereof commencing on the day after the last day of the 5th week that the position remains unfilled.

  • PQ5.9.1a For each month from the Effective Date until the Total Completion Date, Project Co shall prepare, and submit to the Province’s Representative within 15 Business Days of the start of the following month, a comprehensive Quality Management System report.

  • In addition, when ordering 800 Access Service ten digit customer identification the customer must specify whether the dialed 800 number or the terminating local exchange number associated with the dialed 800 number should be delivered to the customer's premises.

  • Front Street West, Suite 500 Toronto ON M5J 2L7tel 416-977-5335fax 416-977-1427email toronto@rjc.caweb rjc.ca4117 Lawrence Avenue East, Toronto, ON Shelter RenovationContract Close-Out & Substantial PerformanceMay 28, 2021 RJC No. TOR.123366.0001page 2RJC requests that a virtual meeting be held with the project team to discuss the remaining scope of work to be completed and agree upon a Total Completion Date.

  • Therefore, we recommend that the City consider increasing access to and use of diversion strategies for all City-funded homeless outreach (i.e., Navigation Team and other City- funded homeless outreach providers) to serve newly unsheltered individuals.

  • Total Completion Date for MWCC Addition and Improvements: 128 Days from HSU Notice to Proceed.

  • Part 6.9Quality Management System Reports PQ6.9(a)-1(a) Performance Measures For each month until the Total Completion Date, the Primary Contractor shall prepare and submit to the Province’s Representative within 15 Business Days of the start of the following month a comprehensive Quality Management System report.

  • Total Completion Date Total Completion Date is the date stipulated in paragraph 1.3 of Article A – 1 of the Agreement – THE WORK and means the point in time when the Work is totally performed in accordance with the Contract Documents and certified as such by the Consultant.

  • For greater certainty, Project Co will not be entitled to such compensation if: (i) the Change does not cause a delay in the Commercial Operation Date of one or more Generating Units, the Service Commencement Date, the Bypass System Completion Date or the Total Completion Date; or (ii) the Change relates to the performance of the Tunnel Work, unless the cumulative Tunnel Work Eligible Delay exceeds the Available Tunnel Float Balance.


More Definitions of Total Completion Date

Total Completion Date means the date on which Total Completion actually occurs. “Total Completion” means that the Utility Plant adheres to all performance criteria and all performance tests as specified in the EPC Contract are complete including, without limitation, complete installation of all materials and equipment in accordance with the EPC Contract requirements, completion of all required tests as specified in the EPC Contract and attainment of the Performance Guarantees, all licenses and permits required to operate the Utility Plant and other customary
Sample 1
Total Completion Date means the date when Total Completion is achieved as certified by the Independent Certifier in accordance with Section 10.2 of this Schedule;
Sample 1
Total Completion Date each have the meaning given in Schedule 4;
Sample 1
Total Completion Date means the date when Total Completion of the Work has been achieved as set out in the Certificate of Total Completion.
Sample 1
Total Completion Date means the date of Total Completion as determined by the School District’s Representative in accordance with the Contract Documents and set out in the Total Completion Certificate;
Sample 1

Related to Total Completion Date

  • Final Completion Date means the date on which Final Completion occurs.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • COMPLETION TIME means the period by date specified in the acceptance of tender for handing over the erected equipment/plant which are found acceptable by the Engineer being of required standard and conforming to the specifications of the contract.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Start-up Period means up to 7 Academy Financial Years and covers the period up to and including the first Academy Financial Year in which all age groups are present at the Academy (that is, all the pupil cohorts relevant to the age range of the Academy will have some pupils present).

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date