Third Party Delay definition

Third Party Delay means any unanticipated delay not caused by either of the parties and which prevents either party from achieving conditions set forth in this Lease at no fault of their own, and shall include a delay caused by the occurrence of a Force Majeure Event. Upon to the occurrence of any such delay, the parties shall promptly notify the other party in writing of such delay and shall meet to agree upon the appropriate extension of any deadlines set forth under this Lease as a result of such Delay.
Sample 1Sample 2Sample 3
Third Party Delay means a delay on part of a third party resulting in a delay of completion of any condition precedent set forth in Clause 14.1 (Conditions Precedent for the Issuer Exchange) or any condition subsequent set forth in Clause 14.2 (Conditions Subsequent for the Issuer Exchange), provided that such delay is outside the Issuer’s control.
Sample 1Sample 2Sample 3
Third Party Delay means failure by the other Party to timely perform according to any timelines required under this Agreement.
Sample 1

Examples of Third Party Delay in a sentence

  • This can be done in informal ways with very rough sketches, or even using verbal descriptions of ideas.

  • If a Party is delayed in its ability to satisfy an obligation or condition of this Agreement by a Force Majeure Event or Third Party Delay, each as defined below, then the date for performance of such obligation or satisfaction of such condition shall be deferred for the period that such Force Majeure Event or Third Party Delay continues to delay such performance or satisfaction.

  • Upon the occurrence of a Third Party Delay, the Trustee may, acting reasonably, upon request from the Issuer approve that any of the Conditions Precedent for Issuer Exchange shall be fulfilled after the Issuer Exchange instead (condition subsequent).

  • The later of: (i) August 1, 2008, or (ii) the last day of the fourteenth (14th) week after the Lease Date (as defined in Section 37 of this Lease), which date is subject to extension for delays caused by (A) Force Majeure (as defined in Section 40 of this Lease), but no more than thirty (30) days of Force Majeure delay attributable to Third Party Delay (as defined in Section 40) or (B) Landlord Delays (as such term is defined in Special Stipulation No. 5 of Exhibit C to this Lease).

  • Landlord and Tenant agree that in the event the Emergency Generator (as hereinafter defined) is not installedand fully operational by August 30, 2004, for reasons other than Tenant Delay, Third Party Delay or Unavoidable Delay, then Landlord shall pay to Tenant, within ten (10) days of demand therefor, the sum of Four Hundred and 00/100 Dollars ($400.00) for each day of such delay.


More Definitions of Third Party Delay

Third Party Delay means actual delays in the Substantial Completion of the Tenant Work or Additional Tenant Work (or such specified portions thereof) resulting from or caused by third party contractors or subcontractors that are not subject to supervision by Landlord’s construction manager under the Construction Management Agreement or otherwise, including, without limitation, the Specialized Service Providers (as hereinafter defined), or any furniture systems or partition suppliers or installers retained directly by Tenant. The parties agree that if Landlord’s construction manager is paid a fee or other remuneration under the Construction Management Agreement based on the fees paid to such third party contractors or subcontractors, Landlord’s construction manager shall, for purposes of determining whether any delay caused by a third party contractor or subcontractor constitutes “Third Party Delay” hereunder, be deemed to have supervised such third party contractor or subcontractor. Section 1.6 Pre-Term Commencement Date Occupancy. Notwithstanding anything to the contrary set forth in this Lease, Tenant shall have the right to use and occupy the Premises (or any portion thereof) at any time on or after the Substantial Completion thereof, but will not pay Rent thereon until the Term Commencement Date applicable thereto. Section 1.7 Payment of Rent. Tenant does hereby covenant and agree promptly to pay the Rent reserved as and when the same shall become due and payable, without demand therefor, and without any set-off or deduction whatsoever, except as may be herein provided, and to keep, observe and perform, and to permit no violation of, each and every of the covenants, agreements, terms, provisions and conditions herein contained on the part and on behalf of Tenant to be kept, observed and performed. Section 1.8 Measurement. In determining the rentable area of the Building and the Premises or any portion thereof pursuant to any provision of this Lease, the rentable area shall be the rentable area thereof in square feet determined in accordance with the Standard Method of Floor Measurement for Office Buildings adopted by The Real Estate Board of New York, Inc., 1981 edition. Section 1.9 (Redacted)
Sample 1
Third Party Delay means actual delays in the Substantial Completion of the Tenant Work or Additional Tenant Work (or such specified portions thereof) resulting from or caused by third party contractors or subcontractors that are not subject to supervision by Landlord’s construction manager under the Construction Management Agreement or otherwise, including, without limitation, the Specialized Service Providers (as hereinafter defined), or any furniture systems or partition suppliers or installers retained directly by Tenant. The parties agree that if Landlord’s construction manager is paid a fee or other
Sample 1
Third Party Delay means actual delays in the Substantial Completion of the Tenant Work or Additional Tenant Work (or such specified portions thereof) resulting from or caused by third party contractors or subcontractors that are not subject to supervision by Landlord’s construction manager under the Construction Management Agreement or otherwise, including, without limitation, the Specialized Service Providers (as hereinafter defined), or any furniture systems or partition suppliers or installers retained directly by Tenant. The parties agree that if Landlord’s construction manager is paid a fee or other remuneration under the Construction Management Agreement based on the fees paid to such third party contractors or subcontractors, Landlord’s construction manager shall, for purposes of determining whether any delay caused by a third party contractor or subcontractor constitutes “Third Party Delay” hereunder, be deemed to have supervised such third party contractor or subcontractor.
Sample 1

Related to Third Party Delay

  • Third Party Contractor as used in the Student Data Protection Act and “Operator” as used in COPPA. De-Identified Information (DII): De-Identification refers to the process by which the Contractor removes or obscures any Personally Identifiable Information (“PII”) from Education Records in a way that removes or minimizes the risk of disclosure of the identity of the individual and information about them.

  • Third Party Costs means all such third party costs (including legal and other professional fees) in respect of each Individual Scheme as a Partner reasonably and properly incurs in the proper performance of its obligations under this Agreement and as agreed by the Partnership Board. Working Day means 8.00am to 6.00pm on any day except Saturday, Sunday, Christmas Day, Good Friday or a day which is a bank holiday (in England) under the Banking & Financial Dealings Act 1971.

  • Third Party Contract means a contract between Metrolinx and any other Person which is in any way related to, impacts or is impacted by the Services and/or the Consultant’s acts or omissions, whether expressly identified to the Consultant or not.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Third Party IP Claim has the meaning given to it in clause E8.7 (Intellectual Property Rights).

  • Third Party Subcontract means a subcontract at any tier entered into by Contractor or subcontractor, financed in whole or in part with Federal assistance originally derived from FEMA.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Third Party Consent means any Consent of a Person other than a Governmental Authority.

  • Third Party Data has the meaning set forth in Section 9.3(a).

  • Third Party Content means all software, data, text, images, audio, video, photographs and other content and material, in any format, that are obtained or derived from third party sources outside of Oracle that You may access through, within, or in conjunction with Your use of, the Services. Examples of Third Party Content include data feeds from social network services, rss feeds from blog posts, Oracle data marketplaces and libraries, dictionaries, and marketing data. Third Party Content includes third-party sourced materials accessed or obtained by Your use of the Services or any Oracle-provided tools.

  • Third Party Royalties means royalties payable by either Party to a Third Party in connection with the manufacture, use or sale of Franchise Products.

  • Third Party Licensor means the relevant licensor of any Third Party Data or any Third Party Trade Xxxx;

  • Third Party Vendor means any person or entity that provides SaaS, third party software and/or related intellectual property. “Work” means any additional work the Customer requests Singtel to perform in relation to the Service.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Third Party Claim Notice shall have the meaning set forth in Section 6.5(a).

  • Third Party Claims has the meaning set forth in Section 11.1.

  • Third Party Material means software, software development tools, methodologies, ideas, methods, processes, concepts and techniques owned by, or licensed to a third party and used by the Service Provider in the performance of the Services;

  • Third Party Payment means payment through an instrument issued from a bank account other than that of the beneficiary investor. In case of payments from a joint bank account, the first named investor/holder of the mutual fund folio has to be one of the joint holders of the bank account from which payment is made.

  • Third Party IPR means any Intellectual Property Rights not belonging to either party to this Agreement but used by the Supplier in the creation of the Deliverables and/or in the course of or in connection with the Project.

  • Third Party Contracts means any agreements entered into by the Retailer and/or the Customer with any third parties, such as the Transmission Licensee and the MSSL, to enable the Retailer to retail electricity to Contestable Consumers. For the purposes of this Electricity Agreement, Third Party Contracts shall include, but is not limited to, the Retailer Use of Systems Agreement, the Market Support Services Agreement, and the Power System Operator•Market Participant Agreement (as defined under the Market Rules);

  • Third Party Hardware means the third party hardware, if any, identified in the Investment Summary.

  • Third Party IP means the Intellectual Property Rights of any third party that is not a party to this Contract, and that is not a Subcontractor.

  • Third Party License means licenses from third parties governing third party software embedded or used in the Trading Platform.

  • Third Party Components means software and interfaces, licensed by RIM from a third party for incorporation into a RIM software product, or for incorporation into firmware in the case of RIM hardware products, and distributed as an integral part of that RIM product under a RIM brand, but shall not include Third Party Software.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Third Party Agreement has the meaning set forth in Section 6(a) hereof.