Improvement Plan means the plan required by the Authority from the Supplier which shall detail how the Supplier will improve the provision of the Goods and/or Services pursuant to Clause 29.1.1 (Authority Remedies);
Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.
Tenant Party means any of the following persons: Tenant; any assignees claiming by, through, or under Tenant; any subtenants claiming by, through, or under Tenant; and any of their respective agents, contractors, employees, licensees, guests and invitees.
Building Plans mean the general building plans and specifications in respect of the Development or in respect of any part or parts of the Development prepared by the Authorized Person and approved by the Building Authority and includes any approved amendments thereto;
Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).
Constructional Plan means all appliances or things of whatsoever nature required for the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work.
Tenant Improvements Defined in Exhibit B, if any.
Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).
Space Plan means the space plan to be prepared by Tenant in accordance with paragraph 2 below and approved by Landlord and Tenant, and showing the general configuration of the Tenant Improvements.
Customer Premises means premises owned, controlled or occupied by the Customer which are made available for use by the Supplier or its Sub-Contractors for provision of the Services (or any of them);
Heritage Building means a Building designated under Part IV of the Ontario Heritage Act, R.S.O. 1990, c. O.18, or any successor legislation, or a Building designated under Part V of the Ontario Heritage Act,R.S.O. 1990, c. O.18, or any successor legislation, which has been identified as a significant heritage resource in a conservation district plan and any Building listed in the Markham Register of Property of Cultural Heritage Value of Interest;
Approved Plan means plan for the building or lay out plan approved by the Authority in accordance with prescribed regulations.
this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.
Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and
Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.
Home improvement means the remodeling, altering,
Area Plan means the document submitted by the AAA to DSHS for approval every four years, with updates every two years, which sets forth goals, measurable objectives, outcomes, units of service, and identifies the planning, coordination, administration, social services and evaluation of activities to be undertaken by the AAA to carry out the purposes of the Older Americans Act, the Social Security Act, the Senior Citizens Services Act, or any other statute for which the AAA receives funds.
Substantial improvement means any combination of repairs, reconstruction, rehabilitation, addition, or other improvement of a structure, taking place during any one-year period for which the cost equals or exceeds 50 percent of the market value of the structure before the “start of construction” of the improvement. This term includes structures which have incurred “substantial damage”, regardless of the actual repair work performed. The term does not, however, include either:
Continuous Improvement Plan means a plan for improving the provision of the Goods and/or Services and/or reducing the Charges produced by the Supplier pursuant to Framework Schedule 12 (Continuous Improvement and Benchmarking);
Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).
Covered Building Service Employee means any person performing building service work for a Covered Building Service Employer, either directly or through a contract or subcontract.
Landlord’s Work means the work of constructing the Tenant Improvements.
Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.
Plan Area means the geographic area analyzed in the HCP/NCCP, located in the eastern portion of Contra Costa County, as depicted in Figure 1-1 of the HCP/NCCP. The Plan Area is further described in detail in Chapter 1.2.1 of the HCP/NCCP. The Plan Area is also referred to as the “Inventory Area” in the HCP/NCCP.
Subleased Premises means approximately -18;961 rentable square feet on the 141h floor of the Building, as more specifically depicted on Exhibit A attached hereto and made a part hereof. The Subleased Premises include all of the Leased Premises identified in the Prime Lease.