Substantial Delay definition

Substantial Delay in respect of any Construction Project, a delay of more than 90 days beyond the scheduled completion time for such Construction Project.
View Source
Substantial Delay means a delay of a period of more than 30 days after the agreed Installation Date;
View Source

Examples of Substantial Delay in a sentence

  • Similarly, Hill is of the view that there is no need for a viability review to be undertaken in the case of a Substantial Delay; such a review will simply further delay the development and, in reality, will only be triggered if the housing market slows down and it is no longer viable to proceed.

Related to Substantial Delay

  • Substantial disruption means without limitation that any one or more of the following occur as a result of the bullying:

  • Developmental delay means that a child has not reached developmental milestones expected for his or her chronological age as measured by qualified professionals using appropriate diagnostic instruments and/or procedures.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which: